Time and Manner of Construction. (a) The time of Completion of Construction set forth in the Contractor's Proposal shall be extended for the period of any reasonable delay which is due exclusively to causes beyond the control and without the fault of the Contractor, including acts of God, fires, floods, inability to obtain materials, and acts or omissions of the Owner with respect to matters for which the Owner is solely responsible: Provided, however, that no such extension of time for completion shall be granted the Contractor unless within ten (10) days after the happening of any event relied upon by the Contractor for such an extension of time the Contractor shall have made a request therefor in writing to the Owner, and provided further, that no delay in such time of completion or in the progress of the work which results from any of the above causes except acts or omissions of the Owner shall result in any liability on the part of the Owner.
Time and Manner of Construction. 1.1. The Contractor agrees to commence construction of the Project within 11 days of the Effective Date (the “Commencement Date”). However, in no event may Contractor commence construction of the Project more than 19 days from the Effective Date. Commencement of construction after this period will result in a breach of this Contract. The Contractor further agrees to prosecute diligently and to complete construction in strict accordance with the Plans, Specifications and Construction Drawings within 180 (60 for Streetlight Unit Repair) calendar days after Commencement Date. Provided however, that the Contractor will not be required to dig holes, set poles, install anchors, install underground conduit, perform any plowing for the installation of underground cable, or dig trenches if there are more than six (6) inches of frost on the ground nor to perform any construction on such days when in the judgment of the Engineer snow, rain, or wind, or the results of snow, rain, or frost make it impracticable to perform any operation of construction; provided further that the Contractor will not be required to perform any plowing for the installation of underground cable on public roads or highways if there are more than two (2) inches of frost in the ground. To the extent of the time lost due to the conditions described herein and approved in writing by the Engineer, the time of completion set out above will be extended if the Contractor makes a written request therefore to BEMC as provided in subsection b of this Section 1.
Time and Manner of Construction. Once construction has commenced, Borrower shall cause such construction to be carried on continuously, and to be completed in a satisfactory manner, and the Final Certificate of Occupancy for all of the Improvements or equivalents issued on or before the end of the Construction Period. Borrower and General Contractor shall comply with all laws, ordinances, and applicable rules and requirements of public authorities applying to and affecting the construction work and shall give the proper authorities all requisite notices relative to such work and cause to be obtained all necessary licenses and permits with respect thereto without cost or expense to Lender. In the event any necessary license or permit is threatened or revoked or subjected to attack by action before any court or other governmental agency having jurisdiction, Lender may refuse to make further Advances hereunder until such license or permit is reinstated or such action before any court or other governmental agency having jurisdiction is terminated. If any such permit or license is revoked and not reinstated within sixty (60) days from its revocation, it shall be deemed an Event of Default. Borrower shall also cause any construction to be carried out in accordance with the requirements of the Lease.
