We use cookies on our site to analyze traffic, enhance your experience, and provide you with tailored content.

For more information visit our privacy policy.

Txxxxx Xxxxx Sample Clauses

Txxxxx Xxxxx. Txxxxx Xxxxx has authorized the issuance of 50,000,000 shares of common stock, of which 10,000,000 shares are issued and outstanding as of the date of this Agreement, all of which have been issued to and are held by the Company. All shares of common stock have been duly authorized, have been validly issued, are fully paid and nonassessable and are free of any liens or encumbrances. There are no authorized or outstanding options, warrants, preemptive rights, rights of first refusal or other rights to purchase any capital stock of Txxxxx Xxxxx or any equity or debt securities convertible into or exchangeable or exercisable for capital stock of Txxxxx Xxxxx.
Sample 1Sample 2Sample 3
Txxxxx Xxxxx. Any of the following types of delay in the completion of construction of Landlord's TI Work (but in each instance, only to the extent that any of the following has actually and proximately caused substantial completion of Landlord's TI Work to be delayed): (i) Any delay resulting from Txxxxx's failure to furnish, in a timely manner, information reasonably requested by Landlord or by Landlord's Project Manager in connection with the design or construction of Landlord's TI Work, or from Tenant's failure to approve in a timely manner any matters requiring approval by Txxxxx; (ii) Any delay resulting from Tenant Change Requests initiated by Txxxxx, including any delay resulting from the need to revise any drawings or obtain further governmental approvals as a result of any such Tenant Change Request; or (iii) Any delay caused by Tenant (or Txxxxx's contractors, agents or employees) materially interfering with the performance of Landlord's TI Work, provided that Landlord shall have given Tenant prompt notice of such material interference and, before the first time a Tenant Delay is deemed to have occurred as a result of such delay, such interference has continued for more than twenty-four (24) hours after Txxxxx’s receipt of such notice.
Sample 1
Txxxxx Xxxxx s/ E. Txxxxx Xxxxx Date: December 1, 2017 By: /s/ Txxxxx X. Xxxxx Name: Txxxxx X. Xxxxx Title: President & CEO Date: December 1, 2017 By: /s/ Txxxxx X. Xxxxx Name: Txxxxx X. Xxxxx Title: President & CEO Date: December 1, 2017 FOR VALUABLE CONSIDERATION, including the payment to the Executive of certain severance benefits pursuant to the agreement between Columbia Financial, Inc., Columbia Bank and the Executive, dated December 1, 2017 (the “Employment Agreement”), the Executive hereby makes this Release of All Claims (“Release”) in favor of Columbia Financial, Inc. and Columbia Bank (including all their subsidiaries and affiliates) (collectively, “Company”) and its agents as set forth herein. 1. The Executive releases, waives and discharges the Company and its agents (as defined below) from all claims, whether known or unknown, arising out of the Executive’s employment relationship with the Company, the termination of that relationship, and all other events, incidents, or actions occurring before the date on which this Release is signed. Claims released herein include, but are not limited to, discrimination claims based on age, race, sex, religion, national origin, disability, veteran status, or any other employment claim, including claims arising under The Civil Rights Act of 1866, 42 U.S.C. § 1981; Title VII of the Civil Rights Act of 1964; the Americans with Disabilities Act; the Age Discrimination in Employment Act of 1967; the Federal Rehabilitation Act of 1973; the Older Workers’ Benefits Protection Act; the Employee Retirement Income Security Act of 1974; the Fair Labor Standards Act; the Family and Medical Leave Act (to the extent that FMLA claims may be released under governing law), any Federal or State wage and hour laws and all other similar Federal or State statutes; and any and all tort or contract claims, including, but not limited to, breach of contract, breach of good faith and fair dealing, infliction of emotional distress, defamation, or wrongful termination or discharge; provided, however, that the release set forth in this Section 1 shall not apply to (a) the payment and/or benefit obligations of the Company under the Employment Agreement, (b) any claims the Executive may have under any plans or programs not covered by the Employment Agreement in which the Executive participated and under which the Executive has accrued and become entitled to a benefit, and (c) any indemnification or other rights the Executive may have under the Employ...
Sample 1
Txxxxx Xxxxx. Any of the following types of delay in the completion of construction of Landlord’s TI Work (but in each instance, only to the extent that any of the following has actually and proximately caused substantial completion of Landlord’s TI Work to be delayed): (i) Any delay resulting from Txxxxx’s failure to furnish, in a timely manner, information reasonably requested by Landlord or by Landlord’s Project Manager in connection with the design or construction of Landlord’s TI Work, or from Tenant’s failure to approve in a timely manner any matters requiring approval by Txxxxx, where such failure continues for more than three (3) business days after Txxxxx’s receipt of written notice from Landlord specifying same; (ii) Any delay resulting from Tenant Change Requests initiated by Txxxxx, including any delay resulting from the need to revise any drawings or obtain further governmental approvals as a result of any such Tenant Change Request (unless Tenant timely abandons the Tenant Change Request upon learning of the potential delay); or (iii) Any delay caused by Tenant (or Tenant’s contractors, agents or employees) materially interfering with the performance of Landlord’s TI Work, provided that Landlord shall have given Tenant prompt notice of such material interference and Tenant shall thereafter fail to remedy same within three (3) business days. (iv) Any delay caused by Txxxxx’s failure to comply with the Time Deadlines (including any value engineering by Tenant outside of the Value Engineering Period).
Sample 1

Related to Txxxxx Xxxxx

  • Xxxx-Xxxxx-Xxxxxx Notwithstanding any other provision in this Agreement, in the event the Xxxx Xxxxx Xxxxxx Antitrust Improvements Act of 1976, as amended (the “HSR Act”), is applicable to any Member by reason of the fact that any assets of the Company will be distributed to such Member in connection with the dissolution of the Company, the distribution of any assets of the Company shall not be consummated until such time as the applicable waiting periods (and extensions thereof) under the HSR Act have expired or otherwise been terminated with respect to each such Member.

  • Xxxx Xxxxxx Purchase Order and Sales Contact Email 2 2 Purchase Order and Sales Contact Phone 2 3 Company Website 4 Entity D/B/A's and Assumed Names 5 Primary Address 2 6 Primary Address City 7 Primary Address State 2 8 Primary Address Zip 9 Search Words Identifying Vendor Certification of Vendor Residency (Required by the State of Texas)

  • Xxxxx Xxxxx Associates is a specialist foreign direct investment practice, providing corporate establishment, business advisory, tax advisory and compliance, accounting, payroll, due diligence and financial review services to multinationals investing in emerging Asia.

  • Xxxxx Xxxxxx Purchase Order and Sales Contact Email 2 Purchase Order and Sales Contact Phone 2 3 Company Website 4 Entity D/B/A's and Assumed Names 5 Primary Address 2 Primary Address City 7 Primary Address State 2 8 Primary Address Zip 9 Search Words Identifying Vendor Certification of Vendor Residency (Required by the State of Texas)

  • Xxxxxx Xxxxx Purchase Order and Sales Contact Email 2 2 Purchase Order and Sales Contact Phone 2 3 Company Website 4 Entity D/B/A's and Assumed Names 5 Primary Address 2 Primary Address City 7 Primary Address State 2 8 Primary Address Zip 9 Search Words Identifying Vendor Certification of Vendor Residency (Required by the State of Texas)

  • Xx Xxxxxx No waiver or modification of this Agreement or any of its terms is valid or enforceable unless reduced to writing and signed by the party who is alleged to have waived its rights or to have agreed to a modification.

  • Xxxx Xxxxx Where the parties cannot agree on an arbitrator, one of the above named will be chosen at random.

  • Xxx Xxxxxx If the Customer requests any on-site or on-site maintenance service (except for any error/problem caused by the Company’s system, equipment/accessories), the Company shall charge a service fee of HK$400 or such amount as determined by the Company at its sole discretion.

  • Xxx Xxxxx Chairman

  • Xxxx Xxxxxxx Purchase Order and Sales Contact Email 2 Purchase Order and Sales Contact Phone 2 3 Company Website 4 Entity D/B/A's and Assumed Names 5 Primary Address 2 Primary Address City 7 Primary Address State 2 8 Primary Address Zip 9 Search Words Identifying Vendor Certification of Vendor Residency (Required by the State of Texas)

Most Referenced Clauses

Most Referenced Definitions