Completion of Concrete Pours and Emergency Work (a) Except as provided in this sub-clause an Employee shall nor work or be required to work in the rain.
(b) Employees shall not be required to start a concrete pour in Inclement Weather.
(c) Where a concrete pour has been commenced prior to the commencement of a period of Inclement Weather Employees may be required to complete such concrete pour to a practical stage and for such work shall be paid at the rate of double time calculated to the next hour, and in the case of wet weather shall be provided with adequate wet weather gear.
(d) If an Employee’s clothes become wet as a result of working in the rain during a concrete pour the Employee shall, unless the Employee has a change of dry working clothes available, be allowed to go home without loss of pay.
(e) The provisions of clauses 32.7(c) and 32.7(d) hereof shall also apply in the case of emergency work where the Employees concerned and their delegates agree that the work is of an emergency nature and can start and/or proceed.
Construction of the Project Highway (i) The Contractor shall construct the Project Highway as specified in Schedule- B and Schedule-C, and in conformity with the Specifications and Standards set forth in Schedule-D. The Contractor shall be responsible for the correct positioning of all parts of the Works, and shall rectify any error in the positions, levels, dimensions or alignment of the Works. The [650th (six hundred and fiftieth) day] from the Appointed Date shall be the scheduled completion date (the “Scheduled Completion Date”) and the Contractor agrees and undertakes that the construction shall be completed on or before the Scheduled Completion Date, including any extension thereof.
(ii) The Contractor shall construct the Project Highway in accordance with the Project Completion Schedule set forth in Schedule-J. In the event that the Contractor fails to achieve any Project Milestone or the Scheduled Completion Date within a period of 30 (thirty) days from the date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, it shall pay Damages to the Authority of a sum calculated at the rate of 0.05% (zero point zero five percent) of the Contract Price for delay of each day reckoned from the date specified in Schedule –J and until such Project Milestone is achieved or the Project Highway is completed; provided that if the period for any or all Project Milestones or the Scheduled Completion Date is extended in accordance with the provisions of this Agreement, the dates set forth in Schedule-J shall be deemed to be modified accordingly and the provisions of this Agreement shall apply as if Schedule-J has been amended as above; provided further that in the event the Project Highway is completed within or before the Scheduled Completion Date including any Time Extension, applicable for that work or section, the Damages paid under this Clause 10.3 (ii) shall be refunded by the Authority to the Contractor, but without any interest thereon. The Parties agree that for determining achievement or delays in completion of the Project Milestones or the Project on the due date, the works affected due to delay in providing the site for which time extension has been granted beyond the Scheduled Completion Date will be excluded. For example on the due date to achieve the Project Milestone-I (i.e., Stage Payments of 10% (ten percent) of Contract Price on 180th (one hundred and eighty) day from the Appointed Date), if 5% (five percent) of the project length corresponding to the Project Milestone-I is not handed over or lately handed over resulting in the extension of completion of this 5% (five percent) length beyond Scheduled Completion Date, Stage Payment of 10% X 0.95 = 9.5% only is to be achieved by 180th (one hundred and eighty) day. For the avoidance of doubt, it is agreed that recovery of Damages under this Clause 10.3 (ii) shall be without prejudice to the rights of the Authority under this Agreement including the right of Termination thereof. The Parties further agree that Time Extension hereunder shall only be reckoned for and in respect of the affected Works as specified in Clause 10.5 (ii).
(iii) The Authority shall notify the Contractor of its decision to impose Damages in pursuance with the provisions of this Clause 10.3. Provided that no deduction on account of Damages shall be effected by the Authority without notifying the Contractor of its decision to impose the Damages, and taking into consideration the representation, if any, made by the Contractor within 20 (twenty) days of such notice. The Parties expressly agree that the total amount of Damages under Clause 10.3 (ii) shall not exceed 10% (ten percent) of the Contract Price. If the damages exceed 10% (ten percent) of the Contract Price, the Contractor shall be deemed to be in default of this agreement having no cure and the Authority shall be entitled to terminate this Agreement by issuing a Termination Notice in accordance with the provisions of Clause 23.1 (ii).
(iv) In the event that the Contractor fails to achieve the Project Completion within a period of 90 (ninety) days from the Schedule Completion Date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, the contractor shall be deemed to be ineligible for bidding any future projects of the Authority, both as the sole party or as one of the parties of Joint Venture/ Consortium during the period from Scheduled Completion Date to issuance of Completion Certificate. This restriction is applicable if the contract value of the delayed project is not less than Rs. 300 Crore.
Installation, Maintenance, Testing and Repair Unless otherwise agreed in writing by the Parties, to the extent required by Applicable Law, Interconnection provided by a Party shall be equal in quality to that provided by such Party to itself, any subsidiary, affiliates or third party. If either Party is unable to fulfill its obligations under this Section 14.2, it shall notify the other Party of its inability to do so and will negotiate alternative intervals in good faith. The Parties agree that to the extent required by Applicable Law, the standards to be used by a Party for isolating and clearing any disconnections and/or other outages or troubles shall be at parity with standards used by such Party with respect to itself, any subsidiary, affiliate or third party.
Unsafe Work Conditions No Employee shall be disciplined for refusal to work on a job which in the opinion of:
(a) A member of a safety committee; or
(b) A person designated by a safety committee; or
(c) A safety officer after an on-site inspection and following discussion with a representative of the Employer, does not meet the standards established pursuant to the Workers' Compensation Act.
Unsafe Working Conditions Employees shall be recognized by the Employer to have the competence to determine what constitutes unsafe working conditions within their discipline. No employee shall be disciplined for refusal to work in a situation which is deemed unsafe beyond the reasonable requirements of the employee's job.
Supervisors Working (a) The Employer agrees that the function of supervisors is the supervision of Employees and not the performance of the work of the employees they supervise. Accordingly, the Employer agrees that supervisors or other employees of the Employer who are not members of the bargaining unit shall not perform any bargaining unit work, except to train employees or demonstrate safety, or as otherwise provided in the applicable Supplement, Rider or Addendum. However, in the case of Acts of God, supervisors shall comply with the procedures in subsections (b) and (c) and may only perform bargaining unit work until bargaining unit employees are available. The Employer shall make every reasonable effort to maintain a sufficient workforce to staff its operations with bargaining unit employees. The Employer also agrees that supervisors or other employees of the Employer who are not members of the bargaining unit shall not perform bargaining unit work in preparing the work areas before the start of the Employer’s hub, preload or reload operation, nor shall the Employer send any bargaining unit employee home and then have such employee’s work performed by a supervisor or other employees of the Employer who are not a member of the bargaining unit.
(b) When additional employees are necessary to complete the Employer’s operations on any shift or within any classification, the supervisor shall exhaust all established local practices to first use bargaining unit employees including where applicable, double shifting, early call-in, and overtime.
(c) If there is no established local practice, the following shall apply with regard to inside work. Within each building, each operation will maintain appropriate list(s), by seniority, of those part-time employees requesting coverage work. It will be the employees’ responsibility to sign up on the appropriate list. The Company shall post such lists and employees who are interested in adding their names to the lists shall do so on the first working day of each month. It will be the employee’s responsibility to make sure his/her their contact information is correct. Employees who are unavailable to work on three (3) separate occasions within a calendar month shall have their names removed from the coverage list. Those employees shall be eligible to re-sign the list the following month. When coverage work is available, the Company will use the appropriate list to fill the required positions, and such employees will work as assigned. The employee must be qualified for the available work and double shift employees shall have seniority among themselves. No employee is allowed to work more than two (2) shifts in any twenty-four (24) hour period. Local call verification practices and procedures shall remain in place. Nothing contained in this Section shall change existing practices or procedures covering full-time work.
(d) If it is determined at any step of the grievance and/or arbitration procedure that this Section, or a “supervisor working” provision in a Supplement, Rider or Addendum, has been violated, the aggrieved employee will be paid as follows: (i) if the actual hours worked by the supervisor amounts to two (2) hours or less, the aggrieved employee will be paid for the actual hours worked by the supervisor at the rate of double time the employee’s rate of pay at the time of the incident; or (ii) if the supervisor works more than two (2) hours, the aggrieved employee shall be paid four (4) hours at straight time or actual hours worked at double time the employee’s rate of pay at the time of the incident, whichever is greater. If no aggrieved employee can be identified, the payment will be made to the grievant. Such remedy shall be in addition to any other remedies sought by the Union in the appropriate grievance procedure. If a Supplement, Rider, or Addendum does not have a provision requiring notice to the xxxxxxx when a supervisor works the following shall be incorporated: “In the event a supervisor does perform bargaining unit work, the Employer shall notify the appropriate shop xxxxxxx as soon as possible.” In the event that any individual supervisor is found to be in violation of the first paragraph of this Subsection three (3) times in any nine (9) month rolling period, the grievance shall be paid at triple quadruple time the employee’s rate of pay for the hours specified in the first paragraph of this subsection.
Heating, Ventilating and Air Conditioning General Office Area: The building shall be equipped with a combination heating, ventilation and air conditioning system. The system shall have ducted supply and return air. The space above the ceiling shall not be used as a supply or return plenum. The systems shall be sized in accordance with the
Weighing and Scaling Costs Purchaser agrees to pay for all weighing costs for logs delivered regardless if logs are purchased on a weight or scale basis. In addition, Purchaser agrees to pay for all scaling costs for logs delivered on a scale basis. Purchaser also agrees to pay for all costs associated with the transmission and reporting of scale or weight data.
Completion of the Work The Contractor must obtain Material Completion as defined in Section 6.1.2 below prior to any occupancy of the Project.
Interconnection Customer Drawings Within one hundred twenty (120) days after the date of Initial Operation, unless the Interconnection Parties agree on another mutually acceptable deadline, the Interconnection Customer shall deliver to the Transmission Provider and the Interconnected Transmission Owner final, “as-built” drawings, information and documents regarding the Customer Interconnection Facilities, including, as and to the extent applicable: a one-line diagram, a site plan showing the Customer Facility and the Customer Interconnection Facilities, plan and elevation drawings showing the layout of the Customer Interconnection Facilities, a relay functional diagram, relaying AC and DC schematic wiring diagrams and relay settings for all facilities associated with the Interconnection Customer's step-up transformers, the facilities connecting the Customer Facility to the step-up transformers and the Customer Interconnection Facilities, and the impedances (determined by factory tests) for the associated step-up transformers and the Customer Facility. As applicable, the Interconnection Customer shall provide Transmission Provider and the Interconnected Transmission Owner specifications for the excitation system, automatic voltage regulator, Customer Facility control and protection settings, transformer tap settings, and communications.
