Written Order Required. In any disciplinary action to dismiss, suspend, temporarily reduce the pay of, or demote an employee having permanent status in a position in the merit system, after having complied with the Xxxxxx requirements where applicable, the appointing authority shall make an order in writing stating specifically the causes for the action.
Written Order Required. The College reserves the right, at any time whatsoever, whether the Work or any part thereof shall or shall not have been completed, to make changes, additions and/or deletions in the Work as the College may deem necessary upon written order (“Change Order” or “Field Directive”) to the Contractor. The Contractor acknowledges and agrees that it shall make no claim for extra or additional compensation on account of any such work, unless same shall have been done pursuant to a written order, signed by Xxxx Xxxxxxx, the authorized representative(s) of the College having the authority to order such extra Work. In the event the College directs the Contractor to perform any item of Work, which the Contractor claims involves extra or additional Work that has not been authorized by a Change Order or Field Directive, the Contractor shall, within three (3) days after receipt of such direction, and before proceeding therewith, make a written claim to the College, giving in detail the basis of its contention that the Work is extra or additional, together with a detailed breakdown showing separately the additional cost of each item of labor and material. The Contractor shall then proceed with this Work. A failure to make written notice of claim within the time specified, and in the manner as herein provided, shall constitute a waiver of such claim and no recovery may be had by the Contractor on account of such work. The failure of the Contractor to perform the Work immediately after giving written notice of its claim, or on the fourth day subsequent to being directed to perform this Work, whichever is less, shall constitute a material breach of this Agreement, regardless of the legitimacy of the Contractor’s contentions, as it is specifically understood and agreed that the progress of the Work may not be delayed by reason of any controversy between the parties. No change order will be permitted which materially adversely affects the value of the project or its intended use.
Written Order Required. In no event, shall Subcontractor proceed with changed or extra work without a fully executed Change Order or a written Change Directive from WINTER XXXXXXX. WINTER XXXXXXX shall not be liable for any additional costs incurred or delays encountered in the performance of such work without such prior written order.
Written Order Required. A communication or contact agreement is not legally enforceable unless the terms of the agreement are contained in a written court order entered pursuant to these rules, which shall be separate from the findings of fact, conclusions of law, order for judgment, and adoption decree issued pursuant to Rule 45. The order shall be filed in the adoption file and shall be issued before or at the time of the granting of the decree of adoption. For children under guardianship of the Commissioner of Human Services, when there is a written communication or contact agreement between prospective adoptive parents and birth relatives other than birth parents it must be included in the final adoption decree unless all the parties to the communication or contact agreement agree to omit it. If the adoptive parents or birth relatives do not comply with the communication or contact agreement, the court shall determine the terms of the communication and contact agreement. (Amended effective January 1, 2007; amended effective July 1, 2014.)
