Force Majeure Cause definition

Force Majeure Cause has the meaning as defined in Section 3.5.1 to this Agreement;
Sample 1Sample 2Sample 3
Force Majeure Cause means circumstances beyond the control of the party affected thereby (including its subcontractors) including, but not limited to, act of God, declared or undeclared war, riot, pandemic, civil commotion, restrictions or directions from any government or governmental body or authority, peril of the sea, earthquakes, explosion, fire, flood, storm, riot, strike or other industrial action (including without limitation strike or other industrial action by the employees of the party claiming the benefit of this clause), failure by any statutory undertaker, utility company, local authority or like body to provide services, any failure, shortage of power, fuel, raw material, goods bought from third parties or transport, and any act or omission of any third party to the extent that performance of any obligation of the party claiming the benefit of the clause relies thereon.
Sample 1Sample 2
Force Majeure Cause is any cause that is beyond the reasonable control of that party. Such causes include, but are not limited to: power failure, internet service provider failure, industrial action, civil unrest, fire, flood, storms, earthquakes, acts of terrorism, acts of war, governmental action or any other event that is beyond the control of the party in question.
Sample 1

Examples of Force Majeure Cause in a sentence

  • An informational picket line shall not be deemed a Force Majeure Cause.

  • Landlord shall give Tenant prompt notice of the occurrence of any Force Majeure Cause and shall use diligent efforts to overcome any such Force Majeure Cause, including, without limitation, the performance of such work on an overtime or premium-pay basis to the extent required of a Unit Owner under the Declaration.

  • In no event shall lack of funds be deemed a Force Majeure Cause, nor shall any matter be deemed to be beyond Tenant's reasonable control if the same could be remedied by the satisfaction of a lien, judgment or other monetary obligation.

  • In the event the Conference has commenced, at the time of the Force Majeure Cause, or SAP has incurred expenses which under the Agreement are the responsibility of Exhibitor, then for the period of use until the time of termination, and to the extent SAP has incurred such expenses, Exhibitor shall be liable to SAP, unless reimbursement is waived by SAP.

  • Notwithstanding anything in this Development Agreement to the contrary, the parties hereto shall be excused from their obligations hereunder to the extent and for so long as such party shall be prevented from compliance by reason of "Force Majeure Causes", provided notice of such inability to comply is given to the other party to this Development Agreement within ten (10) days after the occurrence of the applicable Force Majeure Cause.

  • In the event of nonperformance due to a Force Majeure Cause, such party claiming nonperformance shall immediately notify the other party and make reasonable efforts to cure such Force Majeure Cause and resume performance at the earliest possible date; provided, further, that during the pendency of any Force Majeure Cause, the party not claiming nonperformance shall have the right to sell or purchase, as that case may be, the Products or substitute Products in any manner.

  • In no event shall lack of funds be deemed a Force Majeure Cause, nor shall any matter be deemed to be beyond Tenant’s reasonable control if the same could be remedied by the satisfaction of a lien, judgment or other monetary obligation.

  • In no event shall lack of funds be deemed a Force Majeure Cause, nor shall any matter be deemed to be beyond a party’s reasonable control if the same could be remedied by the satisfaction of a lien, judgment or other monetary obligation.

  • Licensee’s obligations hereunder, including its obligations to pay any amounts, shall xxxxx with respect to Home Games played in other stadiums and Licensor shall refund to Licensee an aliquot portion of fees already paid by Licensee based on the rights lost by Licensee as a result of the Force Majeure Cause or War Cause.

  • Licensor shall have, and hereby reserves, the right to use the Stadium for any purpose, other than professional baseball, with the consent of Licensee during any period that Licensee is prevented by any Force Majeure Cause or War Cause from playing Home Games in the Stadium.


More Definitions of Force Majeure Cause

Force Majeure Cause means any cause beyond Landlord's control, including but not limited to, acts of God, strikes or labor troubles, inclement weather, fuel or energy shortages, utility failures, or governmental preemption or curtailment in connection with a national emergency or in connection with any rule, order, guideline or regulation of any department or governmental agency. If Tenant shall fail to exercise its right to terminate this Lease within ten (10) days following any date on which such right may first be exercised, Tenant shall be deemed to have waived its right of termination with respect to such date as granted by this Section.
Sample 1
Force Majeure Cause means any one or more events or circumstances beyond the reasonable control of the Party whose performance is affected thereby that, alone or in combination, adversely and materially affects the operation of the Hotel whether or not such events or circumstances occur geographically in a location remote from the Hotel, including, without limitation, casualties, war, invasion, insurrection, acts of terrorism, sabotage, failure of transportation, outbreak of disease, inability to procure or general shortage of labor, equipment, facilities, materials or supplies in the open market, actions of labor unions, and governmental actions (but excluding (i) causes which can be controlled by the reasonable expenditure of money in accordance with usual business practices, (ii) any conditions precipitated by Manager, and (iii) any conditions precipitated by Owner). MANAGEMENT FEES AND REMITTANCES TO OWNER Reserved – to come from selected proposal Basic Fee Reserved to come from selected proposal Incentive Fee Reserved to come from selected proposal BOOKS AND RECORDS; GROSS RECEIPTS; FF&E FUND
Sample 1
Force Majeure Cause means a cause that falls within Clause 7 of this Agreement;
Sample 1
Force Majeure Cause means a cause falling within the meaning of that expression in Sub-Clause 7.1 above.
Sample 1
Force Majeure Cause has the meaning as stated in section 4.7 of this Agreement;
Sample 1
Force Majeure Cause means any one or more events or circumstances beyond the reasonable control of the party whose performance is affected thereby that, alone or in combination, adversely affects the operation of the Hotel whether or not such events or circumstances occur geographically in a location remote from the Hotel, including, without limitation, casualties, war, invasion, insurrection, acts of terrorism, sabotage, failure of transportation, inability to procure or general shortage of labor, equipment, facilities, materials or supplies in the open market, actions of labor unions, and governmental actions (but excluding causes which can be controlled by the reasonable expenditure of money in accordance with usual business practices).
Sample 1

Related to Force Majeure Cause

  • Force Majeure Period has the meaning specified in Section 13.1.

  • Force Majeure Delay means with respect to the Servicer, any cause or event which is beyond the control and not due to the negligence of the Servicer, which delays, prevents or prohibits such Person’s delivery of the reports required to be delivered or the performance of any other duty or obligation of the Servicer under the Indenture, as the case may be, including, without limitation, computer, electrical and mechanical failures, acts of God or the elements and fire; provided, that no such cause or event shall be deemed to be a Force Majeure Delay unless the Servicer shall have given the Indenture Trustee written notice thereof as soon as practicable after the beginning of such delay.

  • Force Majeure means an event beyond the control of the supplier and not involving the supplier’s fault or negligence and not foreseeable. Such events may include, but is not restricted to, acts of the purchaser in its sovereign capacity, wars or revolutions, fires, floods, epidemics, quarantine restrictions and freight embargoes.

  • Force Majeure Delays means any actual delay in the construction of the Tenant Improvements, which is beyond the reasonable control of Landlord or Tenant, as the case may be, as described in Paragraph 33 of the Lease.

  • Force Majeure Notice means a notice to be given by the Affected Party to the other party stating that a Force Majeure Event has occurred;

  • Force Majeure Event means an event beyond the reasonable control of any party including an outbreak of a serious disease or epidemic, or quarantine or other public health emergencies, fire, flood, earthquake, explosion or other casualty or accident or act of God, or war or other violence, strike, lock-out, labour dispute, acts of any governmental body, war, insurrection, sabotage, embargo, interruption of or delay in transportation, unavailability of or interruption or delay in telecommunications or inability to obtain raw materials, supplies or power.

  • Force Majeure Exception means any failure or delay in the performance of the Fund’s reporting obligation pursuant to Section 2.3 arising out of or caused, directly or indirectly, by circumstances beyond its reasonable control, including, without limitation, acts of God; earthquakes; flood; terrorism; wars and other military disturbances; sabotage; epidemics; riots; loss or malfunctions of utilities, computer (hardware or software) or communication services; accidents; acts of civil or military authority and governmental action. The Fund shall use commercially reasonable efforts to commence performance of its obligations during any of the foregoing circumstances.

  • Force Majeure Events means acts of war, domestic and/or international terrorism, civil riots or rebellions, quarantines, embargoes and other similar unusual governmental actions, extraordinary elements of nature or acts of God.

  • Force Majeure Report means a report to be given by the Affected Party to the other party following the giving of a Force Majeure Notice;

  • Relevant Force Majeure Event means a Force Majeure Event in relation to which an Affected Party is claiming relief under this Clause 17; and

  • Event of Force Majeure means one of the following events:

  • Excused Outage means any disruption to or unavailability of Services caused by or due to (i) Scheduled Maintenance,

  • Unavoidable Delay means an event which delays Closing which is a strike, fire, explosion, flood, act of God, civil insurrection, act of war, act of terrorism or pandemic, plus any period of delay directly caused by the event, which are beyond the reasonable control of the Vendor and are not caused or contributed to by the fault of the Vendor. “Unavoidable Delay Period” means the number of days between the Purchaser’s receipt of written notice of the commencement of the Unavoidable Delay, as required by paragraph 5(b), and the date on which the Unavoidable Delay concludes.

  • Excusable Delay means a delay due to acts of God, governmental restrictions, stays, judgments, orders, decrees, enemy actions, civil commotion, fire, casualty, strikes, work stoppages, shortages of labor or materials or other causes beyond the reasonable control of Borrower, but lack of funds in and of itself shall not be deemed a cause beyond the control of Borrower.

  • Unavoidable Delays means delays due to any of the following, and only the following, (provided that such delay is beyond Construction Manager’s reasonable control): war, insurrection, civil commotion, strikes, slowdowns, lock outs, riots, flood, earthquakes, fires, casualties, acts of God, acts of a public enemy, acts of terrorism, epidemics, quarantine restrictions, freight embargoes, lack of transportation, governmental moratoriums, unusually severe or abnormal weather conditions, failure of utilities, or a court order which causes a delay (unless resulting from a wrongful act of Construction Manager). In no event shall the application to Construction Manager of any applicable law, regulation, rule or other governmental requirement constitute an Unavoidable Delay. Contractor shall use reasonable good faith efforts to notify Owner not later than five (5) days after Construction Manager knows of the occurrence of an Unavoidable Delay. An extension of time for an Unavoidable Delay shall only be for the period of the Unavoidable Delay, which period shall commence to run from the time of the commencement of the cause of the Unavoidable Delay.

  • Excusable Delays mean delays arising without the fault or negligence of Lessor and Lessor's subcontractors and suppliers at any tier, and shall include, without limitation: (1) acts of God or of the public enemy, (2) acts of the United States of America in either its sovereign or contractual capacity, (3) acts of another contractor in the performance of a contract with the Government, (4) fires, (5) floods, (6) epidemics, (7) quarantine restrictions, (8) strikes, (9) freight embargoes, (10) unusually severe weather, or (11) delays of subcontractors or suppliers at any tier arising from unforeseeable causes beyond the control and without the fault or negligence of both the Lessor and any such subcontractor or supplier.

  • Interruption Period shall have the meaning set forth in Section 5 hereof.

  • Tenant Delay means an actual delay in the occurrence of the Substantial Completion Date or the Final Completion Date with respect to Landlord’s Work as the result of: (1) any unreasonable delay by Tenant in approving the Plans; (2) any request by Tenant that Landlord delay the commencement or completion of Landlord’s Work for any reason; (3) any request by Tenant to change the Plans after initial approval thereof by Tenant, or the making of any changes to Landlord’s Work requested by Tenant and agreed to by Landlord after initial approval of the Plans by Tenant; (4) any failure by Tenant to respond in writing within seven (7) business days after any written request by Landlord for clarification or interpretation of the Plans or for approval of changes in the Plans deemed necessary by Landlord; or (5) any other act or omission of Tenant or its officers, agents, employees or contractors; Notwithstanding the foregoing, no event shall be deemed to be a Tenant Delay until and unless Landlord has given Tenant written notice (the “Tenant Delay Notice”) advising Tenant (i) that a Tenant Delay is occurring, (ii) of the basis on which Landlord has determined that a Tenant Delay is occurring, and (iii) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay, and Tenant has failed to correct the Tenant Delay specified in the Tenant Delay Notice within forty-eight (48) hours following receipt thereof. No period of time prior to expiration of such 48-hour period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice if Tenant corrects the Tenant Delay specified in the Tenant Delay Notice within such 48-hour period.

  • Tenant Delays means (A) Tenant’s request for changes to Landlord’s Work, regardless of whether any such changes are performed, (B) construction of any such changes, (C) Tenant’s request for materials, finishes, or installations requiring unusually long lead times that were not originally included as a part of Landlord’s Work, (D) Tenant’s delay (which shall mean more than 5 business days) in reviewing, revising, or approving any plans and specifications relating to Landlord’s Work, (E) Tenant’s delay in providing information critical to the normal progression of the Project (Tenant shall provide such information as soon as reasonably possible, but in no event longer than 5 business days after receipt of any request for such information from Landlord), and (F) any other act or omission by Tenant or any Tenant Party (as defined herein), or persons employed by any of such persons, (iv) “Substantially Completed” means the substantial completion of Landlord’s Work (A) in a good and workmanlike manner, (B) in accordance with the requirements described in Exhibit C, and (C) in accordance with all applicable Legal Requirements (including, but not limited to, securing the applicable final building inspection for Landlord’s Work), subject only to normal “punch list” items, and (v) “Existing Tenant Delay” means the refusal or failure by the Existing Tenant (as defined below) to surrender the Premises by July 1, 2010 in accordance with the terms and conditions of the Existing Lease (as defined below). Landlord will promptly perform such punch list items. Tenant shall obtain, at its sole cost and expense, any applicable use and occupancy permit for the Premises issued by the applicable Governmental Authority. If Tenant does not elect to void this Lease within 5 business days of the lapse of such 60 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect. If neither Landlord nor Tenant elects to void this Lease within 5 business days of the lapse of such 60 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect. Sequoia Pharmaceuticals, Inc. (“Existing Tenant”), is currently leasing the Premises from Landlord, and the lease agreement (“Existing Lease”) between Landlord and Existing Tenant is scheduled to expire on July 1, 2010 subject to Landlord’s right to advance the expiration date. Tenant understands, acknowledges, and agrees that Landlord makes no guaranty, representation, or assurance that Landlord will be able to recapture the Premises from the Existing Tenant by July 1, 2010 and that Landlord shall have no obligation or duty to seek the vacation or removal of the Existing Tenant from the Premises.

  • Excused Downtime means the number of minutes in the Charging Period that the LSP is unavailable due to:

  • Terminating Party As defined in Section 7.1(f).

  • Unplanned Service Interruption means any Service Interruption where events or circumstances prevent the timely communication of prior warning or notice to the Trader or any affected Customer;

  • Service Interruption means the cessation of electricity supply to an ICP for a period of 1 minute or longer, other than by reason of De-energisation of that ICP:

  • Third Party Terminating Carrier means a Telecommunications Carrier to which traffic is terminated when CLEC originates traffic that is sent through AT&T-TSP’s network, i.e., CLEC is using AT&T-TSP’s Transit Traffic Service.

  • Landlord Delay means a delay in the construction of the Tenant Improvements or Compliance Work resulting directly from the acts or omissions of Landlord, Landlord’s employees, agents, or contractors including, but not limited to (i) failure of Landlord to timely approve or disapprove any plans; (ii) interference by Landlord, its employees, agents or contractors with the completion of the Tenant Improvements or Compliance Work (including the impairment of Tenant’s contractors’ or vendors’ or employees’ access to the Premises for any reason (including due to the presence of Landlord’s contractors, vendors or personnel), failure to provide reasonable access to the Building’s loading docks or other facilities necessary for the construction of the Tenant Improvements or Compliance Work and/or the movement of materials and personnel to the Premises for such purpose) and (iii) delays due to the acts or failures to act of Landlord, its agents or contractors with respect to payment of the Tenant Improvement Allowance. If Tenant contends that a Force Majeure Construction Delay or a Landlord Delay has occurred, Tenant acknowledges and agrees that it has inspected the Building and the Site and in no event shall the physical character or condition of the Building and/or Site existing as of the Effective Date constitute a basis for a Landlord Delay (this agreement does not apply to the failure of any Building component to properly operate). Further, in no event shall any delay of Landlord constitute a Landlord Delay unless such delay results in a full day of delay in the construction of the Tenant Improvements or Compliance Work. Tenant shall notify Landlord in writing (the “Delay Notice”) of the event which constitutes such Force Majeure Construction Delay or Landlord Delay; such notice may be via electronic mail to Landlord’s construction representative described above. Tenant will additionally use reasonable efforts to mitigate the effects of any Force Majeure Construction Delay or Landlord Delay through the re-sequencing or re-scheduling of work, if feasible, but this sentence will not be deemed to require Tenant to incur overtime or after-hours costs unless Landlord agrees in writing to bear such costs. If the actions or inactions or circumstances described in the Delay Notice constitute a Landlord Delay, and are not cured by Landlord within one (1) business day after Landlord’s receipt of the Delay Notice, then a Landlord Delay shall be deemed to have occurred commencing as of the expiration of such one (l)-business day period. The Lease Commencement Date and the Lease Expiration Date will each be delayed on a day for day basis for each day of Force Majeure Construction Delay or Landlord Delay.

  • Affected Party has the meaning specified in Section 5(b).