ADMINISTRATION OF THE CONTRACT DOCUMENTS Sample Clauses

ADMINISTRATION OF THE CONTRACT DOCUMENTS. Unless otherwise specified in the Contract Documents, any changes to Contract Documents will be made in the form of a written Amendment authorized by the parties in the same manner as this Agreement. Any Contractor-initiated requests for Amendments will be provided to Owner in writing and must be accompanied by a narrative description of the proposed change and the reasons for the request. Any such requests shall be directed to: Senior Manager, Business Services Administrative Office of the Courts Business Services, Floor 7 000 Xxxxxx Xxxx Xxxxxx Xxx Xxxxxxxxx, XX 00000 No Service Work Order shall act to modify the Contract Documents, and any SWO that purports to do so shall be null and void, and without effect. Service Work Orders shall be initiated, authorized, and modified in accordance with the procedures established in Article 2.11.
Sample 1Sample 2
AutoNDA by SimpleDocs
ADMINISTRATION OF THE CONTRACT DOCUMENTS. 2.2.1 Unless otherwise specified in the Contract Documents, any changes to Contract Documents will be made in the form of a written amendment authorized by the parties in the same manner as this Agreement. 2.2.2 Any Contractor-initiated requests for amendments will be provided to Owner in writing and must be accompanied by a narrative description of the proposed change and the reasons for the request. Any such requests shall be directed to:
Sample 1
ADMINISTRATION OF THE CONTRACT DOCUMENTS. 5.1.1 The Architect will be responsible to coordinate, manage and administer all Design Services of the Architect and the Subconsultants. The Architect is further responsible, as designated by the Authority, to coordinate, manage and administer the services to be provided by any Consultant contracted directly by the Authority or Team. 5.1.2 The Architect will make regular on-site observations to check the quality or quantity of the Work, shall carefully review the quantity and quality of the Work as part of Architect’s Design Services, and shall issue written reports of such reviews, shall notify Authority immediately if any Work is found not to be in accordance with the Contract Documents. On the basis of on-site observations and inspections as an Architect, the Architect will keep the Authority informed of progress of the Work, and will guard the Authority against defects and deficiencies in the Work. 5.1.3 Based on the Architect’s observations and evaluations of the Construction Manager’s Application for Payment, the Authority shall review the amounts due the Construction Manager and shall issue a Certificate of Payment as deemed appropriate by the Authority in such amounts. The Architect will be responsible to review and approve the Applications for Payment submitted by the Construction Manager and to provide the Authority with certification that the Work included in the Construction Manager’s Application for Payment has been completed. 5.1.4 The Architect shall recommend the rejection of Work that the Architect discovers does not conform to the Contract Documents. 5.1.5 As and when directed, the Architect will prepare Construction Change Directives, subject to the approval of the Authority, and may authorize minor changes in the Work as provided in Paragraph 6.2. 5.1.6 The Architect shall conduct inspections to determine the date or dates of Substantial Completion and the date of Final Completion. The Architect will receive and review any and all records and written warranties and related documents required by the Construction Services Agreement or the Contract Documents and assembled by the Construction Manager or a Trade Contractor. The Architect will forward all such documentation to the Authority upon the Architect’s review and acceptance. The Architect shall issue a final Certificate for Payment upon compliance with the requirements of the Contract Documents. 5.1.7 Upon request of the Authority, Claims, disputes and other matters in question rela...
Sample 1
ADMINISTRATION OF THE CONTRACT DOCUMENTS. Unless otherwise specified in the Contract Documents, any changes to Contract Documents will be made in the form of a written Amendment authorized by the parties in the same manner as this Agreement. Any Contractor initiated requests for Amendments will be provided to Owner in writing and must be accompanied by a narrative description of the proposed change and the reasons for the request. Any such requests shall be directed to: Senior Manager, Business Services Administrative Office of the Courts Business Services, Floor 7 000 Xxxxxx Xxxx Xxxxxx San Francisco, CA 94102 No Service Work Order shall act to modify the Contract Documents, and any SWO that purports to do so shall be null and void, and without effect. Service Work Orders shall be initiated, authorized, and modified in accordance with the procedures established in Article 2.11.
Sample 1

Related to ADMINISTRATION OF THE CONTRACT DOCUMENTS

  • ADMINISTRATION OF THE CONTRACT 2.2.1 The Architect will provide administration of the Contract as hereinafter described. 2.2.2 The Architect will be the State's representative during construction and until final payment is due. The Architect will advise and consult with the State. The State's instructions to the Contractor shall be forwarded through the Architect. The Architect will have authority to act on behalf of the State only to the extent provided in the Contract Documents, unless otherwise modified by written instrument in accordance with Subparagraph 2.2.10. 2.2.3 The Architect will visit the site at intervals appropriate to the stage of construction to familiarize himself or herself generally with the progress and quality of the Work and to determine in general if the Work is proceeding in accordance with the Contract Documents. However, the Architect will not be required to make exhaustive or continuous on-site inspections to check the quality or quantity of the Work. On the basis of his or her on-site observations as an architect, he or she will keep the State informed of the progress of the Work, and will endeavor to guard the State against defects and deficiencies in the Work of the Contractor. 2.2.4 The Architect will not be responsible for and will not have control or charge of construction means, methods, techniques, sequences or procedures, or for safety precautions and programs in connection with the Work, and he or she will not be responsible for the Contractor's failure to carry out the Work in accordance with the Contract Documents. The Architect will not be responsible for or have control or charge over the acts or omissions of the Contractor, 2.2.5 The Architect shall at all times have access to the Work wherever it is in preparation and progress. The Contractor shall provide facilities for such access so the Architect may perform his or her functions under the Contract Documents.

  • THE CONTRACT DOCUMENTS The Contract Documents consist of the State-Contractor Agreement, the Conditions of the Contract (General, Supplementary and other Conditions), the Drawings, the Specifications, and all Addenda issued prior to bid opening and any Change Orders after execution of the Contract.

  • Duration of the contract framework agreement or dynamic purchasing system II.2.10) Information about variants II.2.11) Information about options

  • Responsibilities of the Contractor The Contractor shall provide all technical and professional expertise, knowledge, management, and other resources required for accomplishing all aspects of the tasks and associated activities identified in the Scope of Work. In the event that the need arises for the Contractor to perform services beyond those stated in the Scope of Work, the Contractor and the City shall negotiate mutually agreeable terms and compensation for completing the additional services.

  • Termination of the Contract 1. The Contractor may terminate the contract if the Partner has inadequately discharged or failed to discharge any of the contractual obligations, insofar as this is not due to force majeure, after notification of the Partner by registered letter has remained without effect for one month. 2. The Partner shall immediately notify the Contractor, supplying all relevant information, of any event likely to prejudice the performance of this contract.

  • Control of the Contract F1 Transfer and Sub-Contracting F1.1 Except where F1.4 and F1.5 applies, the Contractor shall not assign, sub-contract or in any other way dispose of the Contract or any part of it without prior Approval. Sub-contracting any part of the Contract shall not relieve the Contractor of any of its obligations or duties under the Contract. F1.2 The Contractor shall be responsible for the acts and omissions of its Sub-contractors as though they are its own. F1.3 Where the Authority has consented to the placing of sub-contracts, copies of each sub-contract shall, at the request of the Authority, be sent by the Contractor to the Authority as soon as reasonably practicable. F1.4 Notwithstanding clause F1.1, the Contractor may assign to a third party (“the Assignee”) the right to receive payment of the Contract Price or any part thereof due to the Contractor under this Contract (including any interest which the Authority incurs under clause C2.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!