Completion Date Completion date" shall be the date on which the improvements erected and to be erected upon the leased premises shall have been completed in accordance with the plans and specifications described in article 6.00. The completion date shall constitute the commencement of the term of this Lease for all purposes, whether or not Lessee has actually taken possession. Lessor shall use its best efforts to establish the completion date as the date set forth in section 1.03. In the event that the improvements have not in fact been completed as of that date, Lessee shall notify Lessor in writing of its objections. Lessor shall have a reasonable time after delivery of the notice in which to take such corrective action as may be necessary and shall notify Lessee in writing as soon as it deems such corrective action has been completed and the improvements are ready for occupancy. Upon completion of construction, Lessee shall deliver to Lessor a letter accepting the leased premises as suitable for the purposes for which they are let and the date of such letter shall constitute the commencement of the term of this Lease. Whether or not Lessee has executed such letter of acceptance, taking possession of the leased premises by Lessee shall be deemed to establish conclusively that the improvements have been completed in accordance with the plans and specifications, are suitable for the purposes for which the leased premises are let, and that the leased premises are in good and satisfactory condition as of the date possession was so taken by Lessee, except for latent defects, if any.
Access Control Landlord shall be the sole determinant of the type and amount of any access control or courtesy guard services to be provided to the Project, if any. IN ALL EVENTS, LANDLORD SHALL NOT BE LIABLE TO TENANT, AND TENANT HEREBY WAIVES ANY CLAIM AGAINST LANDLORD, FOR (I) ANY UNAUTHORIZED OR CRIMINAL ENTRY OF THIRD PARTIES INTO THE PREMISES, THE BUILDING OR THE PROJECT, (II) ANY DAMAGE TO PERSONS, OR (III) ANY LOSS OF PROPERTY IN AND ABOUT THE PREMISES, THE BUILDING OR THE PROJECT, BY OR FROM ANY UNAUTHORIZED OR CRIMINAL ACTS OF THIRD PARTIES, REGARDLESS OF ANY ACTION, INACTION, FAILURE, BREAKDOWN, MALFUNCTION AND/OR INSUFFICIENCY OF THE ACCESS CONTROL OR COURTESY GUARD SERVICES PROVIDED BY LANDLORD, IF ANY. Tenant shall provide such supplemental security services and shall install within the Premises such supplemental security equipment, systems and procedures as may reasonably be required for the protection of its employees and invitees, provided that Tenant shall coordinate such services and equipment with any security provided by Landlord. The determination of the extent to which such supplemental security equipment, systems and procedures are reasonably required shall be made in the sole judgment, and shall be the sole responsibility, of Tenant. Tenant acknowledges that it has neither received nor relied upon any representation or warranty made by or on behalf of Landlord with respect to the safety or security of the Premises or the Project or any part thereof or the extent or effectiveness of any security measures or procedures now or hereafter provided by Landlord, and further acknowledges that Tenant has made its own independent determinations with respect to all such matters.
LESSOR'S ACCESS; SHOWING PREMISES; REPAIRS Lessor and Lessor's agents shall have the right to enter the Premises at any time, in the case of an emergency, and otherwise at reasonable times for the purpose of showing the same to prospective purchasers, lenders, or lessees, and making such alterations, repairs, improvements or additions to the Premises or to the Building, as Lessor may reasonably deem necessary. Lessor may at any time place on or about the Premises or Building any ordinary "For Sale" signs and Lessor may at any time during the last one hundred eighty (180) days of the term hereof place on or about the Premises any ordinary "For Lease" signs. All such activities of Lessor shall be without abatement of rent or liability to Lessee.
Study Period (a) The Acquiror shall have the right, until 5:00 p.m. on the last day of the Study Period, and thereafter if the Acquiror notifies the Contributor that the Acquiror has elected to proceed to Closing in the manner described below, to enter upon the Real Property and to perform, at the Acquiror's expense, such economic, surveying, engineering, environmental, topographic and marketing tests, studies and investigations as the Acquiror may deem appropriate. If such tests, studies and investigations warrant, in the Acquiror's sole, absolute and unreviewable discretion, the acquisition of the Property for the purposes contemplated by the Acquiror, then the Acquiror may elect to proceed to Closing and shall so notify the Contributor prior to the expiration of the Study Period. If for any reason the Acquiror does not so notify the Contributor of its determination to proceed to Closing prior to the expiration of the Study Period, or if the Acquiror notifies the Contributor, in writing, prior to the expiration of the Study Period that it has determined not to proceed to Closing, this Agreement automatically shall terminate, the Acquiror shall be released from any further liability or obligation under this Agreement.
Commencement Date Landlord shall deliver possession of the Premises to Tenant on the date (the “Delivery Date”) that Landlord’s Market Ready Improvements described on EXHIBIT C attached hereto and the Tenant Improvements to be completed by Landlord pursuant to the Work Letter Agreement attached hereto as EXHIBIT D are substantially completed. For purposes of this Lease, Landlord’s Market Ready Improvements and the Tenant Improvements shall be deemed to be “substantially completed” when Landlord’s Market Ready Improvements and the Tenant Improvements have been completed in accordance with any plans and specifications therefor, subject only to the completion of any minor punch-list items, and the City of Sunnyvale has completed a final inspection of such work and issued a temporary certificate of occupancy or other written approvals permitting legal occupancy of the Premises. The term of this Lease (“Term”) shall be seventy-six (76) months commencing on the date (the “Commencement Date”) which is thirty (30) days from the Delivery Date. If the Delivery Date does not occur on or before May 1, 2018, for any reason other than (i) ArcTec’s failure to complete the Final Plans and Specifications (as such term is defined in the Work Letter attached as EXHIBIT D) and submit such Final Plans and Specifications (and any other documentation required by the City of Sunnyvale for the issuance of a building permit for the Tenant Improvements) to Landlord’s general contractor by January 8, 2018, (ii) the City requiring Landlord to stop construction due to its commencement of the Tenant Improvements before the permits therefor were issued or (iii) delays caused by the acts or omission of Tenant, as defined in Paragraph 3(c) below, then the date Tenant is otherwise obliged to commence payment of Rent shall be delayed by one (1) additional day for each day the Delivery Date is delayed beyond such date.
Network Access Control The VISION Web Site and the Distribution Support Services Web Site (the “DST Web Sites”) are protected through multiple levels of network controls. The first defense is a border router which exists at the boundary between the DST Web Sites and the Internet Service Provider. The border router provides basic protections including anti-spoofing controls. Next is a highly available pair of stateful firewalls that allow only HTTPS traffic destined to the DST Web Sites. The third network control is a highly available pair of load balancers that terminate the HTTPS connections and then forward the traffic on to one of several available web servers. In addition, a second highly available pair of stateful firewalls enforce network controls between the web servers and any back-end application servers. No Internet traffic is allowed directly to the back-end application servers. The DST Web Sites equipment is located and administered at DST’s Winchester data center. Changes to the systems residing on this computer are submitted through the DST change control process. All services and functions within the DST Web Sites are deactivated with the exception of services and functions which support the transfer of files. All ports on the DST Web Sites are disabled, except those ports required to transfer files. All “listeners,” other than listeners required for inbound connections from the load balancers, are deactivated. Directory structures are “hidden” from the user. Services which provide directory information are also deactivated.
Construction Period The term “Construction Period” shall mean the period from the date of this Lease to the date that Landlord completes construction of the Landlord’s Work (including any “Additional Base Building Items”, as defined in Section 3(f) of the Tenant Work Letter), and Common Areas, regardless of the occurrence of any Tenant Delay and without regard to the effect of any provision of this Lease pursuant to which the Premises are deemed to be Ready for Occupancy in advance of its actual occurrence. Notwithstanding any provision of this Lease to the contrary (including Exhibit B), during the Construction Period only, the following provisions shall be applicable:
Early Access Sublandlord agrees to cooperate with Subtenant to allow Subtenant access to the Initial Premises from the day following the Consent Date to the Delivery Date and deliver exclusive possession of the Initial Premises, including the Data Room (but excluding the Lab Space), on the Delivery Date, for design and construction purposes and for the purposes of the installation of furniture, fixtures and equipment and preparing the Initial Premises for occupancy (the “Early Access Activities”), provided that Subtenant has first given Sublandlord at least one (1) business day’s prior notice of any such access (for access prior to the Delivery Date only) and has first delivered to Sublandlord a certificate of insurance evidencing compliance with the insurance obligations herein. Such access (a) shall be solely for the Early Access Activities and not for the purposes of occupancy or possession of the Initial Premises, or of conducting business therein, and (b) shall be subject to and upon all the terms and conditions of this Sublease (including without limitation Section 11 hereof), except that Subtenant shall have no obligation to pay Base Rent or Additional Rent for the period prior to the Initial Premises Commencement Date; provided, however, that if Subtenant’s pursuit of the Early Access Activities causes an increase of more than ten percent (10%) in the cost of utilities (including without limitation water, electricity, heat or air conditioning) allocable to the Initial Premises on a square-foot basis (as compared to the average cost for such utilities over the prior three (3) months), Subtenant shall reimburse Sublandlord for such increase in the cost of utilities within thirty (30) days following Sublandlord’s presentation of an invoice therefor (including reasonable supporting documentation), which invoice shall be presented to Subtenant within fifteen (15) days following each month of such Early Access Activities. The Early Access Activities shall be performed between the hours of 6:00 a.m. and 5:00 p.m. on business days, and shall be coordinated with Sublandlord. Subtenant’s early access shall not affect or alter the Initial Premises Commencement Date, the Expansion Premises Commencement Date, the Expiration Date, or the Term.
LANDLORD'S ACCESS TO PREMISES Landlord reserves and shall at any time upon reasonable notice and in compliance with Tenant’s reasonable security measures have the right to enter the Premises to inspect the same, to supply any service to be provided by Landlord to Tenant hereunder to service and repair HVAC units, water pipes and sprinkler mains, and electrical and telephone risers servicing other parts of the Building, to show said Premises to prospective purchasers or tenants, to alter or repair the Premises or any portion of the Building, and to place “for sale” or “for rent” signs on the Building, all without being deemed guilty of an eviction of Tenant and without abatement of Rent, provided that the business of Tenant shall be interfered with as little as is reasonably practicable. Tenant hereby waives any claim for damages or any inconvenience to or interference with Tenant’s business, any loss of quiet enjoyment of the Premises and any other loss occasioned thereby. For each of the aforesaid purposes, Landlord shall at all times have and retain a key with which to unlock the main door to the Premises but not Tenant’s vaults and safes, and Landlord shall have the right to use any and all means which Landlord may deem proper to open said door in an emergency in order to obtain entry to the Premises, and any entry to the Premises obtained by Landlord by any of said means shall not under any circumstances be construed or deemed to be a forcible or unlawful entry into, or a detainer of the Premises, or any eviction of Tenant from the Premises or any portion thereof. No provision of this Lease shall be construed as obligating Landlord to perform any repairs, alterations or decoration except as otherwise expressly agreed to be performed by Landlord.
Commencement Date Delay Except as otherwise provided in the Lease, Delivery of the Premises shall occur when Landlord’s Work has been Substantially Completed, except to the extent that completion of Landlord’s Work shall have been actually delayed by any one or more of the following causes (“Tenant Delay”):