CONTINGENT ADDITIONAL SERVICES Sample Clauses
CONTINGENT ADDITIONAL SERVICES. 3.3.1 Making material revisions in Drawings, Specifications or other documents when such revisions are:
1. inconsistent with approvals or instructions previously given by the Owner, including revisions made necessary by adjustments in the Owner's program or Project budget;
2. required by the enactment or revision of codes, laws or regulations subsequent to the preparation of such documents, or
3. due to changes required as a result of the Owner's failure to render decision in a timely manner.
3.3.2 Providing services required because of significant changes in the Project including, but not limited to, size, quality, complexity, or the Owner's schedule, except for services required under Subsection 2.5.2.
3.3.3 Preparing Drawings, Specifications and other documentation and supporting data, and providing other services in connection with Change Orders and Construction Change Directives.
3.3.4 Providing consultation concerning replacement of work damaged by fire or other cause during construction, and furnishing services required in connection with the replacement of such work.
3.3.5 Providing services made necessary by the default of the Contractor, by major defects or deficiencies in the work of the Contractor, or by failure of performance of either the Owner or Contractor under the Contract for Construction.
3.3.6 Providing services in evaluating an extensive number of claims submitted by the Contractor or others in connection with the work.
3.3.7 Providing services in connection with a public hearing, arbitration proceeding or legal proceeding except where the Design Professional is party thereto.
3.3.8 Providing services in addition to those required by Article 2 for preparing documents for alternate, separate or sequential bids or providing services in connection with bidding or construction prior to the completion of the Construction Documents Phase.
3.3.9 Notwithstanding anything contained in the Agreement, Proposal or these General Conditions to the contrary, all services described in this Article 3 that are caused or necessitated in whole or in part due to the negligent act or omission of the Design Professional shall be performed by the Design Professional as a part of the Basic Services under the Agreement with no additional compensation above and beyond the compensation due the Design Professional for the Basic Services. The intervening or concurrent negligence of the Owner shall not limit the Design Professional’s obligations under this Subsecti...
CONTINGENT ADDITIONAL SERVICES. 3.3.1 (Revise Documents) Add to the end: “To the extent of any conflict, Subparagraph 2.3.6 controls Subparagraph 3.3.1.”
CONTINGENT ADDITIONAL SERVICES. The specifically recognized Additional Services for this Project and the amount of compensation to the Design Professional for these specific Additional Services shall be in accordance with, and shall not exceed the amounts included in, attached Exhibit “B”.
CONTINGENT ADDITIONAL SERVICES. 3.3.1 Making material and substantial revisions in Drawings, Specifications or other documents when such revisions are:
.1 inconsistent with approvals or instructions previously given by the Owner, including revisions made necessary by adjustments in the Owner’s program or Project budget; .2 required by the enactment or revision of codes, laws or regulations subsequent to the preparation of such documents; or
CONTINGENT ADDITIONAL SERVICES. 3.2.1 A material substitution and/or substantial revisions in drawings, specifications or other documents, is defined as:
A. Inconsistent with approvals or instructions previously given by the Owner including revisions made necessary by completing adjustments in Owner’s program or Project budget;
B. Required by the enactment or revision of codes, laws, or regulations subsequent to the preparation of such documents; or
C. Due to changes required as a result of the Owner’s failure to render decisions in a timely manner.
3.2.2 Providing services required because of significant changes in the Project including, but not limited to, size, quality, complexity, the Owner’s schedule, or method of bidding or negotiating and contracting for construction, except for services required under Paragraph 5.2.5; provided, however, that where said services are made necessary because of the significant increase in the size, quality, or complexity of the Project, which results in a significant increase of construction costs; therefore, the Architect’s fee for Basic Services, which fee is commensurate with the services required of the Architect, this provision shall not apply.
3.2.3 Providing modifications to the design and documents as directed by the Owner including, but not limited to, possible educational specifications modifications, and other programming modifications.
3.2.4 Providing services and connection with an arbitration proceeding or legal proceeding except where the Owner or Architect is a party thereto.
CONTINGENT ADDITIONAL SERVICES. The services described below, if approved in writing by the Owner, shall be contingent additional services.
CONTINGENT ADDITIONAL SERVICES. 3.3.1 Making revisions in drawings, specifications or other documents when such revisions are:
3.3.2 inconsistent with approvals or instructions previously given by the Owner, including revisions made necessary by adjustments in the Owner’s program or Project budget;
3.3.3 required by the enactment or revision of codes, laws or regulations subsequent to the preparation of Design Development documents; or
3.3.4 due to changes required as a result of the Owner’s failure to render decisions in a timely manner.
3.3.5 Providing services required because of significant changes in the Project including, but not limited to, size, quality, complexity, the Owner’s schedule, or the method of bidding and contracting for construction, except for services required under Subparagraph 5.2.5
3.3.6 Preparing Drawings, Specifications and other documentation and supporting data, evaluating Contractor’s proposals, and providing other services in connection with Change Orders and Construction Change Directives due to unforeseen conditions or Owner requested changes.
3.3.7 Providing services in connection with evaluating substitutions proposed by the Contractor and making subsequent revisions to Drawings, Specifications and other documentation resulting therefrom.
3.3.8 Providing consultation concerning replacement of Work damaged by fire or other cause during construction, and furnishing services required in connection with the replacement of such Work.
3.3.9 Providing services made necessary by the default of the Contractor, by major defects or deficiencies in the Work of the Contractor, or by failure of performance of either the Owner or Contractor under the Contract for Construction, when the original contract Substantial Completion date is exceeded by more than sixty (60) days.
3.3.10 Providing services in evaluating an extensive number of claims submitted by the Contractor or others in connection with the Work.
3.3.11 Providing services in connection with a public hearing, a dispute resolution proceeding or a legal proceeding except where the Owner’s Representative is a party thereto.
CONTINGENT ADDITIONAL SERVICES. 4.3.1. Making revisions to Drawings, Specifications or other documents when such revisions are:
a) Inconsistent with written approvals or instructions previously given by the Owner, including revisions made necessary by adjustments in the Owner’s program or Project budget;
b) Requested by the Owner because of an unexpected change in the Owners Budget.
c) Required by the enactment or revision of codes, laws or regulations subsequent to the preparation of such documents; or
d) Required due to a difference in the interpretation of a code, law or regulation by the authority having jurisdiction or a requirement imposed by that authority that may not otherwise be required by the code, either prior or subsequent to previous review and approval; or e) Due to changes required as a result of the Owner’s failure to render decisions in a timely manner and thereby cause unreasonable delay in the orderly progress of the Architect’s services.
4.3.2. Providing services required because of changes in the Project including, but not limited to, changes in size, quality, complexity, the Owner’s schedule, or the method of bidding or negotiating and contracting for construction.
4.3.3. Reviewing a Contractor’s submittal out of sequence from the submittal schedule agreed to by the Architect; or providing services in evaluating more than 2 (unless otherwise mutually agreed upon) submissions by the Contractor due to the contractor’s failure to provide the required data or products.
CONTINGENT ADDITIONAL SERVICES. Making revisions in drawings, specifications or other documents when such revisions are:
CONTINGENT ADDITIONAL SERVICES. Contingent Additional Services consist of: