Basic Engineering Designs Sample Clauses

Basic Engineering Designs. (A) The Concessionaire shall prepare the Basic Engineering Designs in accordance with the Technical Specifications, Applicable Laws and Applicable Permits. If the Concessionaire proposes to set up the Power Plant, the Concessionaire shall also submit the Basic Engineering Designs for the Power Plant. The Basic Engineering Designs shall be drawn to scale, with accurate dimensions, to minimize construction delays, disputes and cost overruns and to ensure smooth construction of the Facilities. The Facilities should be designed in a manner such that the Concessionaire can obtain a consent to operate from the Uttar Pradesh Environment Protection and Pollution Control Board for the operation of the Facilities. The Existing Facilities should be renovated so that the Existing Facilities can be operated in accordance with the Applicable Laws and Applicable Permits obtained for the Existing Facilities. The Basic Engineering Designs should also specify the Proposed Technology for the Farrukhabad STP and the Fatehgarh STP.
Sample 1
AutoNDA by SimpleDocs
Basic Engineering Designs. (A) The Concessionaire shall prepare the Basic Engineering Designs in accordance with the Technical Specifications, Applicable Laws and Applicable Permits. If the Concessionaire proposes to set up the Power Plant, the Concessionaire shall also submit the Basic Engineering Designs for the Power Plant. The Basic Engineering Designs shall be drawn to scale, with accurate dimensions, to minimize construction delays, disputes and cost overruns and to ensure smooth construction of the STP Facilities. The STP Facilities should be designed in a manner such that the Concessionaire can obtain a consent to operate from the Bihar State Pollution Control Board for the operation of the STP Facilities. The Basic Engineering Designs should also specify the Proposed Technology for the Digha STP and the Kankarbagh STP.
Sample 1
Basic Engineering Designs. A. The Concessionaire shall prepare the Basic Engineering Designs in accordance with the Technical Specifications, Applicable Laws and Applicable Permits. If the Concessionaire proposes to set up the Power Plant, the Concessionaire shall also submit the Basic Engineering Designs for the Power Plant. The Basic Engineering Designs shall be drawn to scale, with accurate dimensions, to minimize construction/renovation delays, disputes and cost overruns and to ensure smooth construction/renovation of the relevant Facilities. The Facilities should be designed in a manner such that the Concessionaire can obtain a consent to operate from the West Bengal Pollution Control Board for the operation of the Facilities. The Existing Facilities, wherever applicable, should be constructed and renovated such that the Existing Facilities can be operated in accordance with Design Standards, Applicable Laws and the Applicable Permits obtained for the Existing Facilities. The Basic Engineering Designs should also specify the Proposed Technology/Engineering for Tolly‟s Nallah STP 1, Tolly‟s Nallah STP 2 and Tolly‟s Xxxxxx XXX 0.
Sample 1
Basic Engineering Designs. The Concessionaire shall prepare the Basic Engineering Designs in accordance with the Technical Specifications, Applicable Laws and Applicable Permits. If the Concessionaire proposes to set up the Power Plant, the Concessionaire shall also submit the Basic Engineering Designs for the Power Plant. The Basic Engineering Designs shall be drawn to scale, with accurate dimensions, to minimize construction/renovation delays, disputes and cost overruns and to ensure smooth construction/renovation of the relevant Facilities. The Facilities should be designed in a manner such that the Concessionaire can obtain a consent to operate from the West Bengal Pollution Control Board for the operation of the Facilities. The Existing Facilities, wherever applicable, should be constructed and renovated such that the Existing Facilities can be operated in accordance with Design Standards, Applicable Laws and the Applicable Permits obtained for the Existing Facilities. The Basic Engineering Designs should also specify the Proposed Technology/Engineering for Tolly‟s Nallah STP 1, Tolly‟s Nallah STP 2 and Tolly‟s Xxxxxx XXX 0. Within 30 days from the Appointed Date, the Concessionaire shall submit 4 hard copies and 1 soft copy on a compact disc of the draft Basic Engineering Designs to the KMC for its review and approval. The KMC shall forward the Basic Engineering Designs to the Project Engineer and the Indian Institute of Technology (IIT) or other such reputed institutions for their review and comments. The KMC shall provide comments if any, on the draft Basic Engineering Designs (including any comments from IIT/other reputed institute and the Project Engineer) to the Concessionaire or notify the Concessionaire of its approval of the draft Basic Engineering Designs within 20 days from the date of receipt of the draft Basic Engineering Designs. The KMC may require the Concessionaire to amend or modify the draft Basic Engineering Designs if the KMC, IIT/other reputed institute or the Project Engineer identifies any deficiencies, inaccuracies or shortcomings in the draft Basic Engineering Designs. If the Concessionaire receives any comments, suggestions or instructions to modify the draft Basic Engineering Designs from the KMC, then the Concessionaire shall modify the draft Basic Engineering Designs to correct any such shortcomings, inaccuracies or deficiencies and/or address, in writing, the KMC's/IIT's/ other reputed institute‟s/the Project Engineer's comments on the draft Basic...
Sample 1

Related to Basic Engineering Designs

  • Schematic Design Phase Services § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services.

  • Reverse Engineering The Customer must not reverse assemble or reverse compile or directly or indirectly allow or cause a third party to reverse assemble or reverse compile the whole or any part of the software or any products supplied as a part of the Licensed System.

  • Research Design The data generated by excavations at the prehistoric site(s) will be used to examine at least three topics: (1) chronology; (2) technology; and (3) subsistence practices. Insights into changing patterns of community organization may also be granted, as may insights into changes in social organization. The data recovered will then be compared to data from other regional sites.

  • Engineering Forest Service completed survey and design for Specified Roads prior to timber sale advertisement, unless otherwise shown in A8 or Purchaser survey and design are specified in A7. On those roads for which Forest Service completes the design during the contract, the design quantities shall be used as the basis for revising estimated costs stated in the Schedule of Items and adjusting Timber Sale Account. Forest Service engineering shall be completed according to the schedule in A8. Should Forest Service be unable to perform the designated survey and design by the completion date or other agreed to time, upon written agreement, Purchaser shall assume responsibility for such work. In such event, Contracting Officer shall revise:

  • CONSTRUCTION AND RELATED ENGINEERING SERVICES A. General construction work for buildings (CPC 512) 1) Unbound* 2) None 3) None 1) Unbound* 2) None 3) None

  • Geotechnical Engineer « »« » « » « » « » « »

  • Design Development Phase Services 3.3.1 Based on the Owner’s approval of the Schematic Design Documents, and on the Owner’s authorization of any adjustments in the Project requirements and the budget for the Cost of the Work, the Architect shall prepare Design Development Documents for the Owner’s approval. The Design Development Documents shall illustrate and describe the development of the approved Schematic Design Documents and shall consist of drawings and other documents including plans, sections, elevations, typical construction details, and diagrammatic layouts of building systems to fix and describe the size and character of the Project as to architectural, structural, mechanical and electrical systems, and other appropriate elements. The Design Development Documents shall also include outline specifications that identify major materials and systems and establish, in general, their quality levels.

  • Design Professional to Design Work The Design Professional Contract requires the Design Professional to design and to prepare the Contract Documents, a copy of which shall be furnished to the Contractor upon request. The Design Professional Contract requires the Design Professional to designate a readily accessible representative (either on Site or by computer, phone or fax or otherwise) who shall have authority promptly to render decisions and to furnish information required of the Design Professional.

  • SCOPE OF ARCHITECT’S BASIC SERVICES 3.1 The Architect’s Basic Services consist of those described in this Article 3 and include usual and customary structural, mechanical, and electrical engineering services. Services not set forth in this Article 3 are Supplemental or Additional Services.

  • Project Design Applicants must design a project that provides access to health services to enable eligible women and men experiencing health needs to secure and maintain safe and accessible quality screening and diagnostic services, comprehensive family planning, and/ or other women’s health services.

Time is Money Join Law Insider Premium to draft better contracts faster.