CONSEQUENCES OF CONTRACTOR'S FAILURE TO PERFORM REQUIRED SERVICES Sample Clauses

CONSEQUENCES OF CONTRACTOR'S FAILURE TO PERFORM REQUIRED SERVICES. CONTRACTOR shall perform the Scope of Work requirements as described herein. COUNTY will apply one or more of the surveillance methods mentioned below and will deduct an amount from the CONTRACTOR’S invoice or otherwise withhold payment for unsatisfactory or non- performed work. COUNTY reserves the right to change surveillance methods at any time during the CONTRACT without notice to the CONTRACTOR.
Sample 1
AutoNDA by SimpleDocs
CONSEQUENCES OF CONTRACTOR'S FAILURE TO PERFORM REQUIRED SERVICES. The Contractor shall perform all of the contract requirements. The Government will inspect and assess Contractor performance in accordance with FAR 52.246-4, INSPECTION OF SERVICES – FIXED PRICE and the Section E provision entitled GOVERNMENT PERFORMANCE ASSESSMENT. The Government will require reperformance, withhold payment, or seek other suitable consideration for unsatisfactory or non-performed work. When defects can’t be corrected by re-performance, the Government may reduce the price to reflect the reduced value of services performed.
Sample 1Sample 2
CONSEQUENCES OF CONTRACTOR'S FAILURE TO PERFORM REQUIRED SERVICES. The Contractor shall perform the Scope of Work requirements as described herein. Xxxx Xxxxx Airport will deduct an amount from the Contractors invoice or otherwise withhold payment for unsatisfactory or non-performed work. ATTACHMENT B CONTRACTOR’S PRICING
Sample 1Sample 2
CONSEQUENCES OF CONTRACTOR'S FAILURE TO PERFORM REQUIRED SERVICES. In addition to the provisions outlined in Clause 8 of the Standard Contract Provisions for Use with District of Columbia Government Supplies and Services Contracts, July 2010, Attachment J.1 to this Agreement, if DBH determines that Provider has failed to comply with any applicable federal or District law or regulation, including but not limited to the False Claims Act and the D.C. Human Rights Act, The agency may request the Contracting Officer to take any or all of the following actions with substantiating evidence of noncompliance with the terms and conditions of the Human Care Agreement resulting from a RFQ process :
Sample 1
CONSEQUENCES OF CONTRACTOR'S FAILURE TO PERFORM REQUIRED SERVICES a. The Contractor shall perform all of the contract requirements. The Government reserves the right to surveillance at any time during the contract without notice to the Contractor. In the case of unsatisfactory or non- performed work, the Government: (1) May give the Contractor written notice of observed deficiencies prior to deducting for unsatisfactory or non-performed work and/or assessing liquidated damages. Such written notice shall not be a prerequisite for withholding payment for non-performed work. The Government may specify, as provided for below, that liquidated damages can be assessed against the Contractor. Such liquidated damages are to compensate the Government for administrative costs and other expenses resulting from the unsatisfactory or non-performed work. (2) May, at its option, allow the Contractor an opportunity to re-perform the unsatisfactory or non-performed work, at no additional cost to the Government. In the case of daily work, corrective action must be completed within six (6) hours of notice to the Contractor. In the case of other work, corrective action must be completed within twenty-four (24) hours of notice. In addition, the Government can assess liquidated damages, as referenced above, in the amount of ten (10) percent of the value of all observed defects. The original inspection results of the Contractor’s work will not be modified upon re-inspection. However, the Contractor will be paid for satisfactorily re-performed work. (3) Shall deduct from Contractor's invoice all amounts associated with the unsatisfactory or non-performed work at the prices set out in the Schedule or provided by other provisions of this contract, unless the Contractor is required to re-perform and satisfactorily completes the work. In addition, the Government can assess liquidated damages, as referenced above, in the amount of ten (10) percent of the value of all observed defects. (4) May, at its option, perform the work by Government personnel or by other means. The Government will reduce the amount of payment to the Contractor, by the amount paid to any Government personnel (based on wages, retirement and fringe benefits) plus material, or by the actual costs incurred to accomplish the work by other means. If the actual costs cannot be readily determined, the prices set out in the Schedule will be used as the basis for the deduction. In addition, the Government can assess liquidated damages, as referenced above, in the amount of twenty (20) per...
Sample 1
CONSEQUENCES OF CONTRACTOR'S FAILURE TO PERFORM REQUIRED SERVICES. The Contractor shall perform all of the contract requirements. Xxxx Xxxxx Airport will apply one or more of the surveillance methods mentioned below and will deduct an amount from the Contractors invoice or otherwise withhold payment for unsatisfactory or non-performed work. Xxxx Xxxxx Airport reserves the right to change surveillance methods at any time during the contract without notice to the Contractor.
Sample 1
CONSEQUENCES OF CONTRACTOR'S FAILURE TO PERFORM REQUIRED SERVICES a. The Contractor shall perform all of the contract requirements. The Government reserves the right to surveillance at any time during the contract without notice to the Contractor. In the case of unsatisfactory or non-performed work, the Government: (1) May give the Contractor written notice of observed deficiencies prior to deducting for unsatisfactory or non- performed work and/or assessing liquidated damages. Such written notice shall not be a prerequisite for withholding payment for non-performed work. The Government may specify, as provided for below, that liquidated damages can be assessed against the Contractor. Such liquidated damages are to compensate the Government for administrative costs and other expenses resulting from the unsatisfactory or non-performed work. (2) May, at its option, allow the Contractor an opportunity to re-perform the unsatisfactory or non-performed work, at no additional cost to the Government. In the case of daily work, corrective action must be completed within six
Sample 1
AutoNDA by SimpleDocs
CONSEQUENCES OF CONTRACTOR'S FAILURE TO PERFORM REQUIRED SERVICES. 19. 1 The Contractor shall be held to the full performance of the BPA. The CFSA will deduct from the Contractor's invoice or otherwise withhold payment for any non-conforming service as specified below. 19.2 A service task may be composed of several sub-items. A service task may be determined to be partially complete if the Contractor satisfactorily completes some, but not all, of the sub-items. In those cases, partial deductions may be taken from the Contractor's invoice/timesheet. 19.3 The CFSA shall give the Contractor written notice of deductions by providing copies of reports, which summarize the deficiencies for which the determination was made to assess the deduction in payment for unsatisfactory work. 19.4 Therefore in the case of non-performed work, the CFSA: 19.5 Will deduct from the Contractor's invoice/timesheet all amounts associated with such non-performed work at the rate set out in Section 6 or provided by other provisions of the BPA. 19.6 May, at its option, afford the Contractor an opportunity to perform the non-performed work within a reasonable period subject to the discretion of the Contracting Officer and at no additional cost to the CFSA. 19.7 May, at its option, perform the services by the CFSA personnel or other means.
Sample 1

Related to CONSEQUENCES OF CONTRACTOR'S FAILURE TO PERFORM REQUIRED SERVICES

  • Lenders’ Failure to Perform All Advances (other than Swing Loans and Agent Advances) shall be made by the Lenders contemporaneously and in accordance with their Pro Rata Shares. It is understood that (i) no Lender shall be responsible for any failure by any other Lender to perform its obligation to make any Advance (or other extension of credit) hereunder, nor shall any Commitment of any Lender be increased or decreased as a result of any failure by any other Lender to perform its obligations hereunder, and (ii) no failure by any Lender to perform its obligations hereunder shall excuse any other Lender from its obligations hereunder.

  • Failure to Perform Obligations In the event Business Associate fails to perform its obligations under this Agreement, Covered Entity may immediately discontinue providing PHI to Business Associate. Covered Entity may also, at its option, require Business Associate to submit to a plan of compliance, including monitoring by Covered Entity and reporting by Business Associate, as Covered Entity in its sole discretion determines to be necessary to maintain compliance with this Agreement and applicable law.

  • WARRANTY OF CONTRACTOR’S ABILITY TO PERFORM The Contractor warrants that, to the best of its knowledge, there is no pending or threatened action, proceeding, or investigation, or any other legal or financial condition, that would in any way prohibit, restrain, or diminish the Contractor’s ability to satisfy its Contract obligations. The Contractor warrants that neither it nor any affiliate is currently on the Suspended Vendor List, Convicted Vendor List, or the Discriminatory Vendor List, or on any similar list maintained by any other state or the federal government. The Contractor shall immediately notify the Department in writing if its ability to perform is compromised in any manner during the term of the Contract. Contractor’s candidates shall complete this Resume Self-Certification Form. Completed Resume Self-Certification Forms shall be submitted within the Contractor’s response to Customer’s requests for quote. “I the undersigned do hereby certify, under the penalty of perjury, that information in my resume submitted for consideration of the State of Florida contract position is true, correct, complete, and made in good faith to the best of my knowledge and belief. If an omission, falsification, misstatement, or misrepresentation has been made regarding my education, work ability, experience, employment history, and/or fitness for employment as a contractor, I may be disqualified as a contractor, and the matter will be reported to appropriate agency or law enforcement personnel. I understand that there may be civil and/or criminal penalties for misrepresenting pertinent information in connection with contract positions, including, but not limited to, penalties available under sections 287.133 or 817.566, Florida Statutes. I further understand that if I am not a United States citizen, violation cases may be reported to the US Department of Homeland Security for potential deportation.” “In addition, I the undersigned do hereby consent to the release of my information by employers, educational institutions, law enforcement agencies, and other individuals and organizations to investigators and other authorized agents of Florida for verification and investigation purposes. I understand that any documents submitted to procure a contract(s) with the State of Florida, including resumes, are public records.” Print Full Legal Name of Candidate Candidate’s Signature Date Candidate’s Form of Identification Presented Identification number Contractor’s Witness Signature One Date Contractor’s Witness Signature Two Date Print Name Contractor’s Witness One Print Name Contractor’s Witness Two Customers shall complete this Contractor Selection Justification Form for each candidate selected and attach all completed forms to the purchase order. Date: Contractor’s Name: Contractor’s Contact Information: Candidate’s Name: Address: _ Phone: _ Email: Date Candidate will be available: _ Hourly rate of candidate: $ Position candidate recommended for: _ Justification for selection of candidate: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Agency: Division/Section/Unit: _ Printed Name: _ Title: _ Signature _ Date: Contractor's Name: Quarter: Purchase Order (PO) Number: PO Total $ Amount: PO Starting Date Ending Date Please review the attached Rating Definitions and provide your opinion by rating the following: 1. Effectiveness performing tasks 2. Quality & completeness of work 3 ❒ 3 ❒ 2 ❒ 2 ❒ 1 ❒ 1 ❒

  • Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.

  • Failure to Perform In the event of a failure of performance due under this Agreement and if it becomes necessary for either party to undertake legal action against the other on account thereof, then the prevailing party shall be entitled to reasonable attorney’s fees in addition to costs and necessary disbursements.

  • Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.

  • Force Majeure, Notice of Delay, and No Damages for Delay The Contractor will not be responsible for delay resulting from its failure to perform if neither the fault nor the negligence of the Contractor or its employees or agents contributed to the delay and the delay is due directly to acts of God, wars, acts of public enemies, strikes, fires, floods, or other similar cause wholly beyond the Contractor’s control, or for any of the foregoing that affect subcontractors or suppliers if no alternate source of supply is available to the Contractor. In case of any delay the Contractor believes is excusable, the Contractor will notify the Department or Customer in writing of the delay or potential delay and describe the cause of the delay either (1) within 10 days after the cause that creates or will create the delay first arose, if the Contractor could reasonably foresee that a delay could occur as a result, or (2) if delay is not reasonably foreseeable, within five days after the date the Contractor first had reason to believe that a delay could result. The foregoing will constitute the Contractor’s sole remedy or excuse with respect to delay. Providing notice in strict accordance with this paragraph is a condition precedent to such remedy. No claim for damages will be asserted by the Contractor. The Contractor will not be entitled to an increase in the Contract price or payment of any kind from the Department or Customer for direct, indirect, consequential, impact or other costs, expenses or damages, including but not limited to costs of acceleration or inefficiency, arising because of delay, disruption, interference, or hindrance from any cause whatsoever. If performance is suspended or delayed, in whole or in part, due to any of the causes described in this paragraph, after the causes have ceased to exist the Contractor will perform at no increased cost, unless the Department or Customer determines, in its sole discretion, that the delay will significantly impair the value of the Contract to the State of Florida or to Customers, in which case the Department or Customer may (1) accept allocated performance or deliveries from the Contractor, provided that the Contractor grants preferential treatment to Customers with respect to commodities or contractual services subjected to allocation, or (2) purchase from other sources (without recourse to and by the Contractor for the related costs and expenses) to replace all or part of the commodity or contractual services that are the subject of the delay, which purchases may be deducted from the Contract quantity, or (3) terminate the Contract in whole or in part.

  • Termination for Failure to Pay If Company fails to make any payment due hereunder, Hospital shall have the right to terminate this Agreement upon ten (10) business days written notice, unless Company makes such payments plus any interest due, as set forth in Section 4.7, within said ten (10) day notice period. If payments are not made, Hospital may immediately terminate this Agreement at the end of said ten (10) day period. Company shall be entitled to only one such cure period in a calendar year; for a second failure to make payment on time, Hospital shall have the right to terminate this Agreement immediately upon written notice.

  • Default by Contractor To the maximum extent permitted by applicable law, failure to comply with any of the terms and/or conditions of this Contract, including these General Conditions, shall constitute default by Contractor and grounds for termination of this Contract. Contractor shall be liable for any and all damages suffered by District due to the failure by Contractor or Contractor’s subcontractor(s) to comply with this Contract.

  • Continue to Perform No resignation or removal of the Administrator will be effective, and the Administrator will continue to perform its obligations under this Agreement, until a successor Administrator has accepted its engagement according to Section 3.5(b).

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!