Construction and Use of Poles Sample Clauses

Construction and Use of Poles. Whenever feasible, Grantee shall use existing poles when the installation of facilities above- ground is permitted. In the event Grantee cannot obtain the necessary poles and related facilities pursuant to a pole attachment agreement, and only in such event, then it shall be lawful for Grantee to make all needed excavations in the Streets for the purpose of placing, erecting, laying, maintaining, repairing and removing poles, conduits, supports for wires and conductors, and any other facility needed for the maintenance or extension of Grantee's System. All poles of Grantee shall be erected between the curb and the sidewalk unless otherwise designated by the proper authorities of Grantor, and each pole shall be set whenever practicable at an extension lot line. Grantor shall have the right to require Grantee to change the location of any pole, conduit, structure or other facility within Rights-of-Way when, in the opinion of Grantor, the public convenience requires such change, and the expense thereof shall be paid by Xxxxxxx.
Sample 1Sample 2See All (4)
AutoNDA by SimpleDocs
Construction and Use of Poles. Grantee shall negotiate and enter into pole attachment agreements with utilities maintaining poles in the Grantee's Franchise Area on terms acceptable to Grantee and the affected utilities and in compliance with SMC 15.32; provided, any obligations to provide fiber or capacity that might be imposed on Grantee under SMC 15.32 and any amendments thereto, shall be deemed fully satisfied for the term of this Franchise and any extensions by Grantee's agreement to install, at the time of Grantee's own construction, fiber for the City in accordance with the following provisions: (A) In the course of Grantee's own construction of its optical fiber system Grantee shall include at the City's request additional fiber for the City's exclusive use for governmental purposes. Such purposes shall not include any lease, license, or other transfer to any third party of the right to use such fiber and shall not include any commercial use. However, such purposes may include the following uses, for which the City may receive payment to defray its costs of installation and maintenance: (1) The City may share use of the fiber with other governments for governmental purposes where signals are mixed with City signals in the same transmission system; and (2) The City may make fibers available to Schools as distinctly leased fibers or as part of a shared transmission system as described above. (B) The City shall bear the incremental cost of adding the additional fiber during Grantee's construction and the incremental cost, if any, of maintenance.
Sample 1Sample 2See All (4)
Construction and Use of Poles. (A) Whenever feasible, the construction, maintenance, and use of Grantee’s Cable System shall comply with the standards of materials in engineering and all other provisions of a pole user agreement for use of poles, entered into by and between the pole owners and the Grantee, or separate agreements between each of said companies and the Grantee. The City may request a copy of any pole attachment agreement affecting poles place in the Streets, and Grantee shall not unreasonably refuse such request. In the event Grantee cannot obtain the necessary poles and allied facilities pursuant to the provisions of such an agreement, and only in such event, then it shall be lawful for the Grantee to make all needed excavations in the Streets for the purpose of placing, erecting, laying, maintaining, repairing, and removing poles, conduits, supports for wires and conductors, and any other Facility needed for the maintenance or extension of Grantee’s Cable System. All poles of the Grantee shall be erected between the curb and the sidewalk unless otherwise designated by the proper City authorities, and each pole shall be set whenever practicable at an extension of a lot line. The City shall have the right to require the Grantee to change the location of any pole, conduit, structure or other Facility within the Streets when in the opinion of the City the public convenience requires such change, and the expense thereof shall be paid by the Grantee. (B) The terms of Section 15.15 shall not exempt the Grantee from compliance with all Charter and ordinance provisions relating to such excavations or construction or from any provision requiring payment of permit or license fees pertaining thereto.
Sample 1
Construction and Use of Poles. Grantee shall negotiate and enter into pole attachment agreements with utilities maintaining poles in the Grantee's franchise area on terms acceptable to Grantee and the affected utilities and in compliance with SMC Ch. 15.32; provided, any obligations to provide fiber or capacity that might be imposed on Grantee under SMC Ch. 15.32 and any amendments thereto, shall be deemed fully satisfied for the term of this franchise and any extensions by Grantee's agreement to install, at the time of Grantee's own construction, fiber for the City in accordance with the following provisions: (A) In the course of Grantee's own construction of its optical fiber system Grantee shall include at the City's request additional fiber for the City's exclusive use for governmental purposes. Such purposes shall not include any lease, license, or other transfer to any third party of the right to use such fiber and shall not include any commercial use. However, such purposes may include the following uses, for which the City may receive payment to defray its costs of installation and maintenance: (1) The City may share use of the fiber with other governments for governmental purposes where signals are mixed with City signals in the same transmission system; and (2) The City may make fibers available to Schools as distinctly leased fibers or as part of a shared transmission system as described above. (B) The City shall bear the incremental cost of adding the additional fiber during Grantee's construction and the incremental cost, if any, of maintenance. (C) The total amount of fiber installed for the City under this provision shall not exceed thirty (30) miles in distance, nor two hundred (200) fiber miles (number of fibers in a sheath times distance) without the express consent of Grantee. (D) Grantee's agreement to provide fiber under this section shall not be construed as acquiescence in or admission of the City's authority to impose such obligations unilaterally as set forth in Ordinance No. 116633. The City's agreement to these provisions does not constitute acknowledgement of any lack of the City's authority to impose obligations unilaterally as set forth in Ordinance No. 116633.
Sample 1
Construction and Use of Poles. Whenever feasible, Grantee shall use existing poles when the installation of facilities aboveground is permitted. In the event Grantee cannot obtain the necessary poles and related facilities pursuant to a pole attachment agreement, and only in such event, then it shall be lawful for Grantee to make all needed excavations in the Streets for the purpose of placing, erecting, laying, maintaining, repairing and removing poles, conduits, supports for wires and conductors and any other facility needed for the maintenance or extension of Grantee’s Cable System. The City shall have the right to require Grantee to change the location of any of Grantee’s poles within Rights-of-Way when, in the opinion of the City, the public convenience requires such change, and the expense thereof shall be paid by Grantee. Notwithstanding the foregoing, the erection of new poles is only to be a last resort and in any event new poles may not be erected in any new subdivision.
Sample 1
Construction and Use of Poles. (A) In the event Grantee cannot obtain the necessary poles and allied facilities agreements, and only in such event, then it shall be lawful for the Grantee to make all needed excavations in the Streets for the purpose of placing, erecting, laying, maintaining, repairing, and removing poles, conduits, supports for wires and conductors, and any other Facility needed for the maintenance or extension of Grantee's Cable System. All poles of the Grantee shall be erected between the curb and the sidewalk unless otherwise designated by the proper Jurisdictional authorities, and each pole shall be set whenever practicable at an extension of a lot line. A Jurisdiction shall have the right to require the Grantee to change the location of any pole, conduit, structure or other Facility within the Streets when in the opinion of the Jurisdiction the public convenience requires such change, and the expense thereof shall be paid by the Grantee. (B) The terms of Section 15.14(A) shall not exempt the Grantee from compliance with all Charters, resolutions and ordinance provisions relating to such excavations or construction or from any provision requiring payment of permit or license fees pertaining thereto.
Sample 1
Construction and Use of Poles. Grantee shall complete a new pole attachment agreement with Seattle City Light to cover all attachment within the Franchise Area that are necessary for the implementation of the Franchise Agreement.
Sample 1
AutoNDA by SimpleDocs
Construction and Use of Poles. (A) In the event Grantee cannot obtain the necessary poles and allied facilities agreements, and only in such event, then it shall be lawful for the Grantee to make all needed excavations in the Streets for the purpose of placing, erecting, laying, maintaining, repairing, and removing poles, conduits, supports for wires and conductors, and any other Facility needed for the maintenance or extension of Grantee's Cable System. All poles of the Grantee shall be erected between the curb and the sidewalk unless otherwise designated by the proper County authorities, and each pole shall be set whenever practicable at an extension of a lot line. A County shall have the right to require the Grantee to change the location of any pole, conduit, structure or other Facility within the Streets when, in the opinion of the County, the public convenience requires such change, and the expense thereof shall be paid by the Grantee. (B) The terms of Section 14.14(A) shall not exempt the Grantee from compliance with all Charter and ordinance provisions relating to such excavations or construction or from any provision requiring payment of permit or license fees pertaining thereto.
Sample 1

Related to Construction and Use of Poles

  • Maintenance and Use of Property Borrower shall cause the Property to be maintained in a good and safe condition and repair. The Improvements and the Personal Property shall not be removed, demolished or materially altered (except for normal replacement of the Personal Property or as permitted in the PETsMART Lease) without the consent of Lender. Except as provided in Section 3.8(f) hereof, Borrower shall promptly repair, replace or rebuild or cause to be repaired, replaced or rebuilt, any part of the Property which may be destroyed by any casualty, or become damaged, worn or dilapidated or which may be affected by any proceeding of the character referred to in Section 3.6 hereof and shall complete and pay for any structure at any time in the process of construction or repair on the Land. Borrower shall not initiate, join in, acquiesce in, or consent to any change in any private restrictive covenant, zoning law or other public or private restriction, limiting or defining the uses which may be made of the Property or any part thereof, provided, that Borrower shall be permitted to enter into easement agreements or grant rights of way so long as such agreements or grants do not reduce the value of the Property or impair its use, and so long as Borrower has delivered to Lender a title endorsement satisfactory to Lender with respect to such agreements and/or rights of way. If under applicable zoning provisions the use of all or any portion of the Property is or shall become a nonconforming use, Borrower will not cause or permit the nonconforming use to be discontinued or the nonconforming Improvement to be abandoned without the express written consent of Lender.

  • Construction of Agreement The parties mutually acknowledge that they and their attorneys have participated in the preparation and negotiation of this Agreement. In cases of uncertainty this Agreement shall be construed without regard to which of the parties caused the uncertainty to exist.

  • Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians. (ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked. (iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority. (iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.

  • Installation and Use You may install and use the Software only for the number of licenses acquired by you. In order to exercise your rights to the Software under this Agreement, you must activate your copy of the Software in the manner described during the launch sequence.

  • Installation and Use Rights You may install and use any number of copies of the software on your devices.

  • CONSTRUCTION AND RENOVATION Construction and renovation projects for a state, local, territorial, or Tribal government’s principal Emergency Operations Center (EOC) as defined by the State Administrative Agency are allowable under the EMPG Program. Written approval must be provided by FEMA prior to the use of any EMPG Program funds for construction or renovation. Requests for EMPG Program funds for construction of an EOC must be accompanied by an EOC Investment Justification (located in the Related Documents tab of the EMPG xxxxxx.xxx posting) to their Regional EMPG Manager for review. Additionally, recipients are required to submit a SF-424C Form and Budget detail citing the project costs. When applying for funds to construct communication towers Sub-Recipients must submit evidence that the Federal Communication Commission’s (FCC) Section 106 review process has been completed and submit all documentation resulting from that review to Grants Program Directorate (GPD) prior to submitting materials for EHP review. Sub-Recipients are also encouraged to have completed as many steps as possible for a successful EHP review in support of their proposal for funding (e.g., coordination with their State Historic Preservation Office to identify potential historic preservation issues and to discuss the potential for project effects, compliance with all state and EHP laws and requirements). Projects for which the Sub-Recipient believes an Environmental Assessment (EA) may be needed, as defined in as defined in DHS Instruction Manual 023-01-001-01, Revision 01, FEMA Directive 108-1 and FEMA Instruction 108-1-1, must also be identified to the FEMA EMPG Regional Program Manager within six months of the award, and completed EHP review materials must be submitted no later than 12 months before the end of the period of performance. EHP review packets should be sent to xxxxxxxxxx@xxxx.xxx. EMPG Program Sub-Recipients using funds for construction projects must comply with the Xxxxx-Xxxxx Act (40 U.S.C. §§ 3141 et seq.). Grant Sub-Recipients must ensure that their contractors or subcontractors for construction projects pay workers no less than the prevailing wages for laborers and mechanics employed on projects of a character similar to the contract work in the civil subdivision of the state in which the work is to be performed. Additional information regarding compliance with the Xxxxx- Xxxxx Act, including Department of Labor (DOL) wage determinations, is available from the following website: xxxxx://xxx.xxx.xxx/whd/govcontracts/dbra.htm In general, Sub-Recipients should consult with their Grant Manager prior to making any investment that does not clearly meet the allowable expense criteria established in this Guidance.

  • Operation and Use So long as the Aircraft, Airframe or any Engine is subject to the Lien of this Trust Indenture, the Owner shall not operate, use or locate the Aircraft, Airframe or any Engine, or allow the Aircraft, Airframe or any Engine to be operated, used or located, (i) in any area excluded from coverage by any insurance required by the terms of Section 4.06, except in the case of a requisition by the U.S. Government where the Owner obtains indemnity in lieu of such insurance from the U.S. Government, or insurance from the U.S. Government, against substantially the same risks and for at least the amounts of the insurance required by Section 4.06 covering such area, or (ii) in any recognized area of hostilities unless covered in accordance with Section 4.06 by war risk insurance, or in either case unless the Aircraft, the Airframe or any Engine is only temporarily operated, used or located in such area as a result of an emergency, equipment malfunction, navigational error, hijacking, weather condition or other similar unforeseen circumstance, so long as Owner diligently and in good faith proceeds to remove the Aircraft from such area. So long as the Aircraft, the Airframe or any Engine is subject to the Lien of this Trust Indenture, the Owner shall not permit such Aircraft, Airframe or any Engine, as the case may be, to be used, operated, maintained, serviced, repaired or overhauled (x) in violation of any Law binding on or applicable to such Aircraft, Airframe or Engine or (y) in violation of any airworthiness certificate, license or registration of any Government Entity relating to the Aircraft, the Airframe or any Engine, except (i) immaterial or non-recurring violations with respect to which corrective measures are taken promptly by Owner or Permitted Lessee, as the case may be, upon discovery thereof, or (ii) to the extent the validity or application of any such Law or requirement relating to any such certificate, license or registration is being contested in good faith by Owner or Permitted Lessee in any reasonable manner which does not involve any material risk of the sale, forfeiture or loss of the Aircraft, Airframe or any Engine, any material risk of criminal liability or material civil penalty against Mortgagee or impair the Mortgagee's security interest in the Aircraft, Airframe or any Engine.

  • Construction and Maintenance There are on-going maintenance, renovation and construction projects taking place in and around the residences. The work typically takes place during regular business hours, but may begin earlier or extend into evenings or weekends. On-going construction or renovation projects will continue through midterm and final exam periods. The University will take measures to ensure that prudent construction practices are followed, but there may be noise, dust and temporary interruption of some services. Residents may be required to temporarily or permanently relocate to facilitate construction or renovation to their residence area. There will be no compensation or reduction to your residence fees due to disruption and/or relocation.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • LOCATION AND DESCRIPTION OF THE PROPERTY The subject property is a single-storey terraced house bearing the postal address of Xx. 00, Xxxxxx 00/XX0, Xxxxxx Xxxxx Xxxxxxx, 00000 Xxxxxxx Xxxxx, Xxxxxx. The subject property will be sold on an “as is where is basis” and subject to a reserve price of RM310,000.00 (RINGGIT MALAYSIA THREE HUNDRED TEN THOUSAND ONLY) and subject to the Conditions of Sale and by way of an Assignment from the above Assignee/Bank subject to the consent being obtained by the Purchaser from the Developer and other relevant authorities if any, including all terms, conditions, stipulations and covenants which were and may be imposed by the Developer and the relevant authorities. Any arrears of quit rent, assessments and service or maintenance charges which may be lawfully due to any relevant authority or the Developer up to the date of auction sale of the property shall be paid out of the purchase money upon receipt of full purchase price. All other fees, costs and charges relating to the transfer and assignment of the property shall be borne by the successful Purchaser. Online bidders are further subject to the Terms & Conditions on xxx.xxxxxxxxxxxxxxxx.xxx. All intending bidders are required to deposit 10% of the fixed reserve price for the said property by Bank Draft or Cashier’s Order in favour of UOBM for KRISHNAMAL A/P MURLIGIAH & XXXXXXXXXXX A/L XXXXXXX or remit the same through online banking transfer, one (1) working day before auction date. The balance of the purchase money shall be paid by the Purchaser within one hundred and twenty (120) days from the date of auction sale to UNITED OVERSEAS BANK (MALAYSIA) BHD via Real Time Electronics Transfer of Funds and Securities (XXXXXX). For online bidders please refer to the Terms & Conditions on xxx.xxxxxxxxxxxxxxxx.xxx on the manner of payment of the deposit. FOR FURTHER PARTICULARS, please contact M/S HOE & MOIRA, of Xxxxx 000X (Xxxxx), 0xx Xxxxx, Xxxxx Xxxxxx Xxxxxx, Xxxxxxxxxx Xxxx, 00000 Xxxxxx, Xxxxxxxx. (Ref:H&M/MT/Z4P/CB23/16) Tel.: 00-000 0000, Fax: 00-000 0000) the Assignee herein or the undermentioned Auctioneer. Suite C-20-3A, Level 20, Block C, Megan Avenue II, / XXXXX XXXXX BIN XXXXXX 00, Xxxxx Xxx Xxxx Xxxx, 50450 Kuala Lumpur (Licensed Auctioneers) Tel No.: 00-0000 0000 Fax No.: 00-0000 0000 Our Ref: LIAN/UOB1035HM Website: xxx.xxxxxxxxxxxxxxxx.xxx E-mail: xxxx@xxxxxxxxxxxxxxxx.xxx [berkuatkuasa dari 1.11.2022, perniagaan perbankan pengguna (consumer banking business) CITIBANK BERHAD (No. Syarikat: 199401011410 (297089-M) telah dipindahmilik kepada xxx diletakhakkan kepada UOB di bawah Perintah Letakhak bertarikh 12.10.2022 melalui Mahkamah Tinggi Kuala Lumpur Saman Pemula No. WA-24NCC-903-09/2022] Dalam menjalankan xxx xxx kuasa xxxx telah diberikan kepada Pihak Pemegang Serahhak/Bank dibawah Perjanjian Kemudahan, Penyerahanhak xxx Surat Kuasa Wakil kesemuanya Bertarikh 09hb Julai, 2001 diantara Pihak Penyerahhak, Pihak Pelanggan xxx Pihak Pemegang Serahhak/Bank yang diperbuat dalam perkara diatas, adalah dengan ini diisytiharkan bahawa Pihak Pemegang Serahhak/Bank tersebut dengan bantuan Pelelong yang tersebut dibawah.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!