Continuance of Work During Dispute Sample Clauses

Continuance of Work During Dispute. At all times during the term of this Contract, including during the course of and notwithstanding the existence of any Claim: (a) Contractor shall perform as directed by Owner, in a diligent manner and without delay, shall abide by Owner’s decisions or orders, and shall comply with all applicable provisions of the Contract Documents; and (b) Owner shall perform its obligations under this Contract in a diligent manner and without delay. Records of the Work shall be kept in sufficient detail to enable payment in accordance with applicable provisions in the Contract Documents.
Sample 1Sample 2Sample 3See All (8)
AutoNDA by SimpleDocs
Continuance of Work During Dispute. During the course of the Maintenance Disputes Review Board process, the Contractor will continue with the work as directed by the Engineer in a diligent manner and without delay or otherwise conform to the Engineer’s decision or order, and will be governed by all applicable provisions of the Contract. Throughout any protested work, the Contractor will keep complete records of extra costs and time incurred. The Contractor will permit the Engineer and Board access to these and any other records needed for evaluating the dispute.
Sample 1
Continuance of Work During Dispute. At all times during the course of the dispute resolution process, the Contractor shall continue to prosecute the work as directed by the contract in a diligent manner and without delay, or shall conform to the Department’s written direction or order. Records of the work shall be kept in sufficient detail by both parties to substantiate and quantify payment in accordance with the applicable sections of the Specifications and the contract provisions. Nothing in this Special Provision shall limit or modify the procedures contained in Section 105.19, as amended by the Special Provisions of this Contract. Failure to properly submit a Dispute to the DRB under the terms of the Special Provision for Partnering and the Issue Resolution Ladder contained therein shall be a conclusive waiver of the Contractor’s right for a DRB review of the Dispute and to such claim for damages by the Contractor.
Sample 1
Continuance of Work During Dispute. At all times during the course of any disagreement, dispute, legal proceeding, mediation or arbitration process, Contractor shall continue with the Work as directed by Authority, in a diligent manner and without delay or conform to Authority’s decision or order, and shall be governed by the applicable provisions of this Contract. Contractor agrees that it has adequate remedies at law and in no case, other than set out herein, shall Contractor have the right to stop the Work or abandon the Project. Records of the Work performed during such time shall be kept in sufficient detail to enable payment in accordance with the applicable provisions in this Contract, if necessary. In the event of a disagreement of work performed, Contractor shall xxxx monthly. XII.‌
Sample 1
Continuance of Work During Dispute. During the course of any Dispute Resolution Procedures, Developer shall continue performing the Work, including any Work that is the subject of the Dispute, as directed by the Department and in accordance with the Contract Documents.
Sample 1
Continuance of Work During Dispute. During the course of the dispute resolution process, Developer will continue with the Work (including any Work that is the subject of the Dispute) in a diligent manner and without delay or otherwise conform to the Authority’s decision or order, and will be governed by all applicable provisions of the Agreement, and the Authority shall continue to make payments of any amounts not in dispute pursuant to the terms of the Agreement. Throughout any disputed Work, Developer will keep complete records of extra costs and time incurred. Developer will provide the Authority and any Disputes Review Board members access to these and any other records needed for evaluating the Dispute.
Sample 1

Related to Continuance of Work During Dispute

  • Conduct During Dispute Resolution Process Unless otherwise agreed in writing, the Parties shall, and shall cause the respective members of their Groups to, continue to honor all commitments under this Agreement and each Ancillary Agreement to the extent required by such agreements during the course of dispute resolution pursuant to the provisions of this Article VII, unless such commitments are the specific subject of the Dispute at issue.

  • Compensation During Dispute If a purported termination occurs following a Change in Control and during the Term and the Date of Termination is extended in accordance with Section 7.3 hereof, the Company shall continue to pay the Executive the full compensation in effect when the notice giving rise to the dispute was given (including, but not limited to, salary) and continue the Executive as a participant in all compensation, benefit and insurance plans in which the Executive was participating when the notice giving rise to the dispute was given, until the Date of Termination, as determined in accordance with Section 7.3 hereof. Amounts paid under this Section 7.4 are in addition to all other amounts due under this Agreement (other than those due under Section 5.2 hereof) and shall not be offset against or reduce any other amounts due under this Agreement.

  • Termination Procedures and Compensation During Dispute 7.1. After a Change in Control and during the term of this Agreement, any purported termination of the Executive's employment (other than by reason of death) shall be communicated by written Notice of Termination from one party hereto to the other party hereto in accordance with Section 10 hereof. For purposes of this Agreement, a "

  • Applicable Law and Dispute Resolution 11.1 The execution, validity, performance and interpretation of this Agreement shall be governed by and construed in accordance with the laws of the PRC.

  • Arbitration Process Any arbitration will be conducted pursuant to the applicable rules (the “Arbitration Rules”) of the American Arbitration Association, as modified herein, to the extent such modifications are not prohibited by the Arbitration Rules. The arbitration will be conducted in Indianapolis, Indiana. The parties will select a single arbitrator, but in the event that the parties are unable to agree, the arbitrator will be appointed pursuant to the Arbitration Rules. The arbitrator will be a practicing attorney with significant expertise in litigating and/or presiding over cases involving the substantive legal areas involved in the dispute. The parties to the arbitration will not request, and the arbitrator will not order, that any discovery be taken or provided, including depositions, interrogatories or document requests, except to the extent the amount in controversy exceeds $50,000. The arbitration will be concluded within three months of the date the arbitrator is appointed. The arbitrator’s findings, reasoning, decision, and award will be stated in writing and based upon applicable law. Judgment on the arbitration award may be entered in any court having jurisdiction. In the event that the arbitration results in an award which imposes an injunction or contains a monetary award in excess of $100,000, the award will be reviewable on appeal initiated by filing notice of appeal with the AAA office within 30 days of the award, governed by the AAA Optional Appellate Arbitration Rules and conducted by a panel of three new arbitrators, ruling by majority, under the procedure for appointment from the national roster of arbitrators. Unless the applicable Arbitration Rules require otherwise, arbitration fees and costs will be shared equally by the claimant(s) and respondent(s), respectively, in any arbitration proceeding. Should the AAA be unavailable, unable or unwilling to accept and administer the arbitration of any claim under these arbitration provisions as written, the parties will agree on a substitute arbitration organization, such as JAMS, that will enforce the arbitration provisions as written. Because this Agreement memorializes a transaction in interstate commerce, the Federal Arbitration Act governs the interpretation and enforcement of these arbitration provisions. More information about arbitration, including the Arbitration Rules, is available at xxx.xxx.xxx or by calling 0-000-000-0000.

  • Applicable Laws and Dispute Resolution a. The formation, validity, interpretation and performance of and settlement of disputes under this Agreement shall be governed by the laws of the PRC.

  • Applicable Law; Dispute Resolution i. This Agreement, and all claims, disputes or disagreements arising out of or connected with this Agreement, its validity or any breach thereof, shall be governed by the laws in effect in the State of Texas (excluding conflicts of laws provisions), and to the extent applicable to maritime issues, the maritime laws of the United States (excluding conflict of laws provisions).

  • Dispute Resolution Process Any claim, dispute or other matter in question not resolved by the process identified in Paragraph

  • Termination Procedure Regardless of basis, in the event of suspension or termination (in full or in part), the parties shall cooperate to ensure an orderly and efficient suspension or termination. Accordingly, Contractor shall deliver to Purchasers all goods and/or services that are complete (or with approval from Enterprise Services, substantially complete) and Purchasers shall inspect, accept, and pay for the same in accordance with this Master Contract and the applicable Purchase Order. Unless directed by Enterprise Services to the contrary, Contractor shall not process any orders after notice of suspension or termination inconsistent therewith.

  • Arbitration, Remedies Each party hereto agrees that any dispute relating to the subject matter of this Agreement shall be settled and determined by arbitration in the City of New York pursuant to the rules of the NFA or, if the NFA should refuse to accept the matter, the American Arbitration Association.

Time is Money Join Law Insider Premium to draft better contracts faster.