Customer Obligations 41.1. The Customer undertakes to use the Services strictly in accordance with the Contract and such other conditions as may be notified in writing to the Customer by Comtact from time to time and in accordance with the relevant provisions of the Communications Xxx 0000 with any other applicable laws and regulations, any directions given by the Director General of the office of Telecommunications or other competent authority.
41.2. The Customer will ensure that neither the Customer nor anyone under their control may use the Services:- o as a means of communication for a purpose other than that for which the Services are provided or in a manner in which constitutes a violation or infringement of the rights of any other party; o to make offensive, indecent, menacing, nuisance or hoax calls or calls of a defamatory character or fraudulently or in connection with a criminal offence.
41.3. The Customer hereby indemnifies and shall keep indemnified Comtact against all liabilities, claims, damages, losses and expenses arising from any breach of the Customer’s obligations in clause 41.2 and against any claim which is made against Comtact and/or the TSP because the Services are misused in any way by the Customer. Comtact or TSP reserve the right to take further action as specified in clause 46.
41.4. In respect of LCR Services the Customer is responsible for checking that the Customer is not currently in a contract with any other supplier(s) before changing over the line rental or LCR services to Comtact. Comtact will not be liable for any cancellation charges or other fees charged by the Customer’s previous supplier.
41.5. The Customer will comply with current regulations for NGNs which includes but is not limited to the following: o the Customer will provide the caller pricing information for each number wherever the number is printed or published. o the Customer will notify callers of undue delays between a call being connected and the caller accessing the service o where required the Customer will obtain prior permission for premium rate numbers 41.6. Comtact cannot be held responsible for any costs, consequential or otherwise, incurred by the Customer in preparation for the commencement of services until such time that Comtact confirms the activation of NGN number(s). The Customer should not undertake any marketing activities or publication of numbers until an order confirmation has been received from Comtact.
Obligations of Customer Axway’s indemnification obligation is contingent upon the Customer: (a) giving immediate written notice to Axway of any such Infringement Claim; (b) giving Axway control of the defense and related settlement negotiations, provided , however that Axway will obtain the Customer’s prior written consent, which shall not be unreasonably withheld or delayed, if any settlement of such an Infringement Claim requires Customer to admit liability, take or refrain from taking any particular action other than cessation of use of the infringing Services, Product, or Deliverable , and (c) assisting in the defense at Axway’s reasonable request, provided Axway agrees to pay Customer’s reasonable expenses in connection therewith. The Customer may participate in such defense and in any settlement discussions directly or through counsel of the Cus tomer’s choice, at the Customer’s expense, provided such participation does not materially prejudice Axway’s sole control of the defense or cause Axway to incur material additional costs in the conduct of such defense .
Supplier Obligations 7.1 The Supplier shall:
7.1.1 at all times allocate sufficient resources to supply the Services in accordance with the Contract;
7.1.2 provide and fulfil any ancillary or incidental service, function or responsibility not specified in the Service Specification where such service, function or responsibility is necessary for the proper performance of the relevant Services;
7.1.3 obtain, and maintain throughout the duration of the Contract, all the consents, approvals, licences and permissions (statutory, regulatory, contractual or otherwise) it may require and which are necessary for the provision of the Services or performance of any other obligation under this Contract;
7.1.4 ensure the Supplier Assets used in the performance of the Services will be free of all encumbrances (except as agreed in writing with the Authority);
7.1.5 ensure that in the performance of its obligations under the Contract it does not disrupt the operations of each Commissioning Body and their respective Personnel;
7.1.6 ensure that any documentation, information and training provided to each Commissioning Body under this Contract (including in relation to the use of the Website) is comprehensive, accurate and prepared in accordance with Good Industry Practice;
7.1.7 co-operate with the Other Supplier(s) and provide reasonable information (including any documentation), advice and assistance in connection with the Services to the Other Supplier(s) including to enable such Other Supplier(s) to provide services to the respective Commissioning Bodies and, on the expiry or termination of this Contract for any reason, to enable the timely transition of the Services (or any of them) to the respective Commissioning Bodies and/or to any Replacement Supplier;
7.1.8 to the extent it is legally able to do so, hold on trust for the sole benefit of the Authority, all warranties and indemnities provided by third parties or any Sub- contractor in respect of any Deliverables and/or the Services and, where any such warranties are held on trust, at its cost enforce such warranties in accordance with any reasonable directions that the Authority may notify from time to time to the Supplier;
7.1.9 unless it is unable to do so, assign to the Authority on the Authority’s written request and at the cost of the Supplier any such warranties and/or indemnities as are referred to in Clause 7.1.8;
7.1.10 provide each Commissioning Body with such advice and assistance as that Commissioning Body may reasonably require during the Contract Period in respect of the supply of the Services;
7.1.11 gather, collate and provide such information and co-operation as the Authority may reasonably request for the purposes of ascertaining the Supplier’s compliance with its obligations under the Contract;
7.1.12 notify the Authority of any circumstances suggesting that a change of Control of the Supplier is planned, in contemplation or has taken place;
7.1.13 notify the Authority in writing of any material detrimental change in the financial standing and/or any change in the credit rating of the Supplier;
7.1.14 subject to Clause 33.6, notify the Authority in writing within ten (10) Working Days of their occurrence, of any actions, suits or proceedings or regulatory investigations before any court or administrative body or arbitration tribunal pending or, to its knowledge, threatened against it that might affect its ability to perform its obligations under the Contract; and
7.1.15 ensure that neither it, nor any of its Affiliates or Personnel, bring any Commissioning Body into disrepute by engaging in any act or omission which is reasonably likely to diminish the trust that the public places in that Commissioning Body, regardless of whether or not such act or omission is related to the Supplier’s obligations under this Contract.
Obligations of the Customer 3.1 The Customer agrees to:
(a) The Customer shall give the Company not less than 14 days prior written notice of any proposed change of ownership of the Customer and or any change in the Customer’s details (including but not limited to, changes in the customer’s name, address, contact phone/fax numbers or business practice). The Customer shall be liable for any loss incurred by the Company as a result of the Customers failure to comply with this clause.
(b) Pay the Company the Price for carrying out the Works in accordance with this agreement;
(c) Provide the Company with all necessary plans, specifications, services and amenities, so as to allow the Company to carry out the Works, provide access to the Location and ensure to the Company’s reasonable satisfaction that the Location remains in a state and condition that is safe for the Company and its employees and agents;
(d) Ensure the Location complies with all necessary bylaws and restrictions is structurally sound (in accordance with all legislation governing safety in the workplace);
(e) Not to cause any disruption or obstruction to the carrying out of any Works and to follow any reasonable instructions provided by the Company about the Works;
(f) Where the Works requires co-ordination with other trades then the Customer will supply the Company with a schedule detailing all relevant information so as to allow the Company sufficient time to co-ordinate with the Customer’s other tradespersons;
(g) Permit the Company to attach such reasonable signage as the Company may wish to any Works so as to identify that the Company is carrying out the Works;
(h) In circumstances where it wishes to make a claim against the Company pursuant to the guarantee given in clause 13.2, exclusively permit the Company or its authorised representative to remedy or make good any defects in its Workmanship and not permit any other third party to do so.
3.2 Without prejudice to any other right or remedy of the Company, if the Customer fails to carry out or perform any of its obligations pursuant to this clause 3 (excepting clause 3.1(g)) then, in addition to any Additional Expenses Charge that may apply, the Company may charge the Customer a Services Delay Charge for each day (or part thereof) that the Company is, in its reasonable opinion, unable and/or not required to carry out or perform the Works as a result of such breach by the Customer.
3.3 Where the Customer requests any Related Work to be carried out, the Company will use its best endeavours to source suppliers and/or contractors to carry out the Related Work, but the Customer is responsible for the commissioning, controlling, and payment for such work.
3.4 The Customer acknowledges that unless otherwise agreed in writing between the Customer and the Company, the Customer shall be responsible for obtaining, paying for and maintaining in force all permits, approvals, authorisations, authorities, licences and consents of all regulatory authorities whatsoever which are or may be necessary or advisable in connection with the Works.
Interconnection Customer Obligations The Interconnection Customer shall maintain the Large Generating Facility and the Interconnection Customer’s Interconnection Facilities in a safe and reliable manner and in accordance with this LGIA.
Developer Obligations In accordance with applicable NYISO requirements, Developer shall maintain satisfactory operating communications with Connecting Transmission Owner and NYISO. Developer shall provide standard voice line, dedicated voice line and facsimile communications at its Large Generating Facility control room or central dispatch facility through use of either the public telephone system, or a voice communications system that does not rely on the public telephone system. Developer shall also provide the dedicated data circuit(s) necessary to provide Developer data to Connecting Transmission Owner and NYISO as set forth in Appendix D hereto. The data circuit(s) shall extend from the Large Generating Facility to the location(s) specified by Connecting Transmission Owner and NYISO. Any required maintenance of such communications equipment shall be performed by Developer. Operational communications shall be activated and maintained under, but not be limited to, the following events: system paralleling or separation, scheduled and unscheduled shutdowns, equipment clearances, and hourly and daily load data.
Service Provider Obligations Service Provider shall make the Software and the Services required for provisioning the Software (Software and Services hereinafter together and individually may also be referred to as “Service” or “Services”) available to Customer as described in the Services Description and in the Services Specific Terms (together hereinafter referred to as “Services Description”) referenced in the Order Forms and according to the terms and conditions of this Agreement. Service Provider may amend the Services from time to time, provided that such amendments shall not materially diminish the overall Service. Service Provider aims to provide the Software access to Customer within two (2) working days upon the Effective Date, unless otherwise set forth in the Services Description. The Software may consist of a web application provided to Customer in form of a software as a service solution and a mobile application to be installed by Customer on its mobile device. The agreed scope and quality of the Services is exclusively set forth in the Services Description. Public statements concerning the Service made by Service Provider or its agents will only take form when expressively confirmed by Service Provider in writing. Notwithstanding section 7.1, information and specifications contained within the Services Description shall not qualify as warranty or guarantee with regards to the Service’s quality or as any other kind of guarantee, unless they have been confirmed as such by Service Provider in writing. Service Provider may update and improve the Services from time to time; any such Updates, meaning software that remedies "Defects" (as defined in section 7.4) in the Services and/or may include minor improvements of the Services, are included in the Agreement. In addition to Updates, Service Provider may offer Upgrades and/or Add-On Services to the Services, where “Upgrades” mean new capabilities or functionalities of the Services and “Add-On Services” either mean (i) new and/or additional functionality packages in form of separate modules to the Services, or (ii) integrations or connection applications with other Hilti or third party software applications. Upgrades and Add-On Services are only subject to the Agreement, if ordered separately and paid for by Customer, where additional terms and conditions may apply.
Provider Obligations A. PROVIDER will perform the Services in accordance with the standards of care, skill, and diligence expected of a qualified, competent and experienced professional in the provision of the type of services required under this Agreement.
B. PROVIDER will obtain, maintain in effect, and pay the cost for all licenses, permits, or certifications that may be necessary for PROVIDER’s performance of this Agreement.
C. PROVIDER represents and warrants that there are no obligations, commitments, third party rights, or impediments of any kind that will limit or prevent PROVIDER’s performance of the Services.
Obligations of the Client 4.1. The client undertakes to inform the company in advance (meaning no later than 2 calendar days) about the dispatch of the goods, by entering the shipment into the Xxxxx.xxx software.
4.1.1. In case of non-compliance with subparagraph 3.2.1 of this agreement, the company has the right to refuse the client in accepting and placing his goods at the warehouse.
4.2. To send goods from the warehouse or to carry out other operations, the client is obliged to provide his client number (client ID) and data of the goods.
Obligations of the Contractor (i) Subject to and on the terms and conditions of this Agreement, the Contractor shall undertake the survey, investigation, design, engineering, procurement, construction, and maintenance of the Project Highway and observe, fulfil, comply with and perform all its obligations set out in this Agreement or arising hereunder.
(ii) The Contractor shall comply with all Applicable Laws and Applicable Permits (including renewals as required) in the performance of its obligations under this Agreement.
(iii) Subject to the provisions of Clauses 4.1 (i) and 4.1 (ii), the Contractor shall discharge its obligations in accordance with Good Industry Practice and as a reasonable and prudent person.
(iv) The Contractor shall remedy any and all loss, defects, or damage to the Project Highway from the Appointed Date until the end of the Construction Period at the Contractor’s cost, save and except to the extent that any such loss, defect, or damage shall have arisen from any wilful default or neglect of the Authority.
(v) The Contractor shall remedy any and all loss, defect or damage to the Project Highway during the Defects Liability Period at the Contractor’s cost to the extent that such loss, defect or damage shall have arisen out of the reasons specified in Clause 17.3.
(vi) The Contractor shall remedy any and all loss or damage to the Project Highway during the Maintenance Period at the Contractor’s cost, including those stated in Clause 14.1 (ii), save and except to the extent that any such loss or damage shall have arisen on account of any wilful default or neglect of the Authority or on account of a Force Majeure Event.
(vii) The Contractor shall, at its own cost and expense, in addition to and not in derogation of its obligations elsewhere set out in this Agreement:
(a) make, or cause to be made, necessary applications to the relevant Government Instrumentalities with such particulars and details as may be required for obtaining Applicable Permits set forth in Schedule-F and obtain and keep in force and effect such Applicable Permits in conformity with the Applicable Laws;
(b) procure, as required, the appropriate proprietary rights, licences, agreements and permissions for Materials, methods, processes and systems used or incorporated into the Project Highway;
(c) make reasonable efforts to maintain harmony and good industrial relations among the personnel employed byit or its Sub-contractors in connection with the performance of its obligations under this Agreement;
(d) ensure and procure that its Sub-contractors comply with all Applicable Permits and Applicable Laws in the performance by them of any of the Contractor’s obligations under this Agreement;
(e) not do or omit to do any act, deed or thing which may in any manner violate any provisions of this Agreement;
(f) support, cooperate with and facilitate the Authority in the implementation and operation of the Project in accordance with the provisions of this Agreement;
(g) ensure that the Contractor and its Sub-contractors comply with the safety and welfare measures for labour in accordance with the Applicable Laws and Good Industry Practice;
(h) keep, on Site, a copy of this Agreement, publications named in this Agreement, the Drawings, Documents relating to the Project, and Change of Scope orders and other communications given under this Agreement. The Authority’s Engineer and its authorised personnel shall have the right of access to all these documents at all reasonable times;
(i) cooperate with other contractors employed by the Authority and personnel of any public authority; and
(j) not interfere unnecessarily or improperly with the convenience of the public, or the access to and use and occupation of all roads and footpaths, irrespective of whether they are public or in the possession of the Authority or of others.
(viii) The Contractor shall undertake all necessary superintendence to plan, arrange, direct, manage, inspect and test the Works. The Contractor shall provide all necessary superintendence of the Works for the proper fulfilling of the Contractor's obligations under the Agreement. Such superintendence shall be given by competent person having adequate knowledge of the operations to be carried out (including the methods and techniques required, the hazards likely to be encountered and methods of preventing accidents) for the satisfactory and safe execution of the Works.
(ix) The Contractor shall obtain and maintain a project related bank account operational at site where all transactions related to the payment of work will be done. The Contractor shall submit a monthly account statement and a detailed report on utilization of funds transferred to this project related bank account to Authority’s Engineer. Notwithstanding anything contrary to this agreement, the authority, in the interest and to ensure timely completion of the work, reserves the right to audit such bank accounts to ensure that there is no diversion of funds from this project specific account to any other project being implemented by the Contractor.
(x) The Contractor shall provide the documents of the Contractor specified in the Agreement, and all Contractors' personnel; Goods, consumables and other things and services, whether of a temporary or permanent nature, required in and for the execution, completion of Works and remedying defects.
(xi) The Contractor shall perform the Works in conformity with the Project requirements and other requirements and standards prescribed under or pursuant to the Agreement.
(xii) The Contractor shall carry out such work incidental and contingent to the original Scope of the Project to comply with Good Industry Practices.
(xiii) The Contractor shall maintain required staff and necessary Contractor’s equipment and materials within the reach of the Site during the Defects Liability Period so that any defects arising are promptly attended.
