DELAYS AND SUSPENSIONS Sample Clauses

DELAYS AND SUSPENSIONS. 32.1. The County may direct the Contractor, in writing, to suspend, delay, or interrupt all or any part of the work of this contract for the period of time deemed appropriate for the convenience of the County. The County will extend the Contractor's time of completion by a period of time that in the discretion of the Purchasing Agent is reasonably suited for completion of work. The County may further amend the contract by mutual agreement for any increase in the cost of performance of the contract (excluding profit) resulting solely from the delay or suspension of the contract. No adjustment shall be made under this clause for any delay or interruption resulting from any other cause, including the fault or negligence of the Contractor.
Sample 1Sample 2Sample 3See All (17)
AutoNDA by SimpleDocs
DELAYS AND SUSPENSIONS. Company may delay or suspend all or any part of this Agreement by providing written notice to Provider. Provider's obligations to Company under this Agreement will remain in full force and effect despite the delay or suspension of this Agreement under this Section. If Company suspends this Agreement, Provider shall be entitled to compensation in accordance with the terms of this Agreement up to the date of suspension; provided, however, Company’s liability to Provider shall in no case exceed the compensation payable to Provider pursuant to this Agreement, as appropriately adjusted and without duplication of payment.
Sample 1Sample 2See All (4)
DELAYS AND SUSPENSIONS. The Company may suspend or delay the effectiveness of the Registration Statement for one or more reasonable periods of time (but not exceeding thirty (30) days in the aggregate during any twelve (12) month period), if (a) the Company determines, in its reasonable judgment, that such registration or offering would interfere with any financing, acquisition, corporate reorganization or other material transaction involving the Company or any of its Affiliates or would require premature disclosure thereof and (b) gives Stockholder at least two (2) Business Days prior written notice of such delay or suspension. Nothing contained in this Section 8, however, affects the Company's obligations under Section 3.5, except as provided herein.
Sample 1Sample 2
DELAYS AND SUSPENSIONS. 21.1 AlexRenew may direct the Contractor, in writing, to suspend, delay, or interrupt all or any part of the work of this Contract for the period of time deemed appropriate for the convenience of AlexRenew. AlexRenew will extend the Contractor's time of completion by a period of time that in the discretion of the Purchasing Agent is reasonably suited for completion of work. AlexRenew may further amend the Contract by mutual agreement for any increase in the cost of performance of the Contract (excluding profit) resulting solely from the delay or suspension of the Contract. No adjustment shall be made under this clause for any delay or interruption resulting from any other cause, including the fault or negligence of the Contractor.
Sample 1
DELAYS AND SUSPENSIONS. 19.1. The County may direct the Solar Power Provider, in writing, to suspend, delay, or interrupt all or any part of the work of this contract for the period of time deemed appropriate for the convenience of the County. The County will extend the Solar Power Provider's time of completion by a period of time that in the discretion of the Purchasing Agent is reasonably suited for completion of work. The County may further amend the contract by mutual agreement for any increase in the cost of performance of the contract (excluding profit) resulting solely from the delay or suspension of the contract. No adjustment shall be made under this clause for any delay or interruption resulting from any other cause, including the fault or negligence of the Solar Power Provider.
Sample 1
DELAYS AND SUSPENSIONS. 33.1. The County may direct the contractor, in writing, to suspend, delay, or interrupt all or any part of the work of this contract for the period of time deemed appropriate for the convenience of the County. The County will extend the contractor's time of completion by a period of time that in the discretion of the Purchasing Agent is reasonably suited for completion of work, and is at least as long as the delay imposed by the County. The County may further amend the contract by mutual agreement for any increase in the cost of performance of the contract (excluding profit) resulting solely from the delay or suspension of the contract. No adjustment shall be made under this clause for any delay or interruption resulting from any other cause, including the fault or negligence of the contractor.
Sample 1
DELAYS AND SUSPENSIONS. Notwithstanding the foregoing, the Company may delay filing a registration statement, and may withhold efforts to cause the registration statement to become effective, if the Board of Directors of the Company determines in good faith that such registration might (i) interfere with or affect the negotiation or completion of any transaction that is being contemplated by the Company (whether or not a final decision has been made to undertake such transaction) at the time the right to delay is exercised, or (ii) involve initial or continuing disclosure obligations that might not be in the best interest of the Company's stockholders. If, after a registration statement becomes effective, the Company advises the Holder that the Company considers it appropriate for the registration statement to be amended, the Holder shall suspend any further sales of its registered Shares until the Company advises them that the registration statement has been so amended.
Sample 1
AutoNDA by SimpleDocs
DELAYS AND SUSPENSIONS. The provisions in this Section 5.3 are intended to apply to situations involving the ongoing, uninterrupted Manufacture of Sarepta Drug Products once the Lead DMD Product Launch has occurred. [**]
Sample 1
DELAYS AND SUSPENSIONS. The provisions in this Section 3.5 are intended to apply to situations involving the ongoing, uninterrupted Manufacture of BridgeBio Products, including orders for [***] In the event of delays in approval or commercial launch or suspension of production after initial launch (for reasons other than the negligence (or more culpable conduct) of Catalent or a breach of this Agreement by Catalent) and if (for reasons other than the negligence (or more culpable conduct) of Catalent or a breach of this Agreement by Catalent) BridgeBio is unable to increase orders for the Manufacture of other BridgeBio Products in the Dedicated Clean Room Suite, BridgeBio shall pay to Catalent the Minimum Annual Threshold (as the same may be offset by work conducted in such suites pursuant to a Scope of Work or Purchase Orders) for as long as the Manufacture of the BridgeBio Product is delayed or suspended, and there shall be no additional payments or costs arising from BridgeBio’s provision of the Rolling Forecast (including the binding portion thereof) or actual Purchase Orders placed other than for the Manufacture of Batches which have commenced and for the non-cancelable orders of Raw Materials.
Sample 1

Related to DELAYS AND SUSPENSIONS

  • Termination and Suspension Customer is entitled to suspend the performance of its obligations in whole or in part or terminate the Agreement with immediate effect, without prejudice to its right to claim damages and without any compensation to or indemnification of Supplier (i) in case Supplier has been declared bankrupt, is in a state of liquidation, has ceased or suspended whole or a substantial part of its business, is subject of a court order or preventative legal scheme of settlement, (ii) in case of non- compliance with the Compliance Requirements or the provisions of safety, health, environment and security or (iii) in case of not approved changes pursuant to article 10. After such termination Customer may return received Goods and/or Services in whole or partly against repayment and retransfer of ownership therein to Supplier.

  • No Suspension Trading in the Common Stock shall not have been suspended on the Exchange and the Common Stock shall not have been delisted from the Exchange.

  • Amendments, Suspension and Termination To the extent permitted by the Plan, this Agreement may be wholly or partially amended or otherwise modified, suspended or terminated at any time or from time to time by the Board or the Committee. Except as provided in the preceding sentence, this Agreement cannot be modified, altered or amended, except by an agreement, in writing, signed by both the Partnership and the Participant.

  • General Disclosure Package As of the Applicable Time, neither (i) the General Use Issuer Free Writing Prospectus issued at or prior to the Applicable Time and, the preliminary prospectus supplement, dated May 27, 2009, including the base prospectus, dated November 6, 2007, (which is the most recent Statutory Prospectus distributed to investors generally),and the other information, if any, stated in Schedule B to this Agreement to be included in the General Disclosure Package, all considered together (collectively, the “General Disclosure Package”), nor (ii) any individual Limited Use Issuer Free Writing Prospectus, when considered together with the General Disclosure Package, included any untrue statement of a material fact or omitted to state any material fact necessary in order to make the statements therein, in the light of the circumstances under which they were made, not misleading. The preceding sentence does not apply to statements in or omissions from any Statutory Prospectus or any Issuer Free Writing Prospectus in reliance upon and in conformity with written information furnished to the Company by any Underwriter through the Representatives specifically for use therein, it being understood and agreed that the only such information furnished by any Underwriter consists of the information described as such in Section 8(b) hereof.

  • Effect of Force Majeure If either Party is rendered wholly or partially unable to perform its obligations under this Agreement because of a Force Majeure Act, that Party shall be excused from whatever performance is affected by the Force Majeure Act to the extent so affected, provided that:

Time is Money Join Law Insider Premium to draft better contracts faster.