Delivery of Request for Change Order Sample Clauses

Delivery of Request for Change Order. DB Contractor shall deliver a Request for Change Order under this Section 10.3.2.5 to TxDOT within 30 Days after delivery of the PCO Notice, or such longer period of time as may be allowed in writing by TxDOT. TxDOT may require design and construction costs to be covered by separate Requests for Change Order.
AutoNDA by SimpleDocs
Delivery of Request for Change Order. Maintenance Contractor shall deliver a Request for Change Order under this Section 10.3.2.5 to TxDOT within 30 days after delivery of the PCO Notice, or such longer period of time as may be allowed in writing by TxDOT. TxDOT may require design and construction costs to be covered by separate Requests for Change Order.
Delivery of Request for Change Order. DB Contractor shall deliver a Request for Change Order under this Section 4.5.6.1 to TxDOT within 30 days after delivery of the PCO Notice or within 10 Business Days after receipt of TxDOT’s determination to require a Request for Change Order in accordance with Section 4.5.4.1.3, whichever is applicable. TxDOT may require design and construction costs to be covered by separate Requests for Change Order. If DB Contractor fails to deliver a complete Request for Change Order meeting all of the requirements of Section 4.5.6.2 within the appropriate time period, DB Contractor shall be required to provide a new PCO Notice before it may submit a Request for Change Order.
Delivery of Request for Change Order. DB Contractor shall deliver a Request for Change Order under this Section 13.3.2.4 to TxDOT within 30 days after delivery of the PCO Notice, or such longer period of time as may be allowed in writing by TxDOT. TxDOT may require design and construction costs to be covered by separate Requests for Change Order. If DB Contractor requests a time extension, then TxDOT, in its sole discretion, may require DB Contractor to provide two alternative Requests for Change Order, one of which shall provide for a time extension and any additional costs permitted hereunder, and the other of which shall show all Acceleration Costs associated with meeting the non-extended Completion Deadlines, as well as any additional costs permitted hereunder. If it is not feasible to recover to the non-extended Completion Deadline or if DB Contractor believes that the costs associated with such a recovery are prohibitive, then DB Contractor shall recommend a date to be shown in the alternative Change Order form. If DB Contractor fails to deliver a complete Request for Change Order or incomplete Request for Change Order meeting all of the requirements of this Section 13.3.2.4 within the appropriate time period, DB Contractor shall be required to provide a new PCO Notice before it may submit a Request for Change Order.
Delivery of Request for Change Order. Contractor shall deliver a Request for Change Order to VPRA within sixty (60) Days after Contractor’s delivery of the Change Notice. If Contractor fails to submit a complete Request for Change Order within sixty (60) Days after Contractor’s delivery of the Change Notice, Contractor shall be deemed to have irrevocably and forever waived and released any right to any relief whatsoever for any effect attributable or related to the Relief Event and the acts or omissions comprising such Relief Event; provided, however, that if Contractor submits a Request for Change Order within sixty (60) Days of the date of Contractor’s delivery of the Change Notice and VPRA responds as provided in Section 14.5.1 of these General Terms and Conditions that Contractor’s Request for Change Order is incomplete, Contractor shall have until the later of (a) fifteen (15) Days after receipt of VPRA’s notice pursuant to Section 14.5.1 of these General Terms and Conditions or (b) sixty (60) Days after Contractor’s delivery of the Change Notice, to comply in full with Section 14.4.1 of these General Terms and Conditions before the waiver herein becomes effective.
Delivery of Request for Change Order. Integrator shall deliver all Requests for Change Order under this Section 13.3 to TxDOT within 30 days after delivery of the PCO Notice, or such longer period of time as may be allowed in writing by TxDOT. TxDOT may require design and construction costs to be covered by separate Requests for Change Order. If Integrator requests a time extension, then TxDOT, in its sole discretion, may require Integrator to provide two alternative Requests for Change Order, one of which shall provide for a time extension and any additional costs permitted hereunder, and the other of which shall show all Acceleration Costs associated with meeting the original Completion Deadlines, as well as any additional costs permitted hereunder. If it is not feasible to recover to the original Completion Deadline or if Integrator believes that the costs associated with such a recovery are prohibitive, then Integrator shall recommend a date to be shown in the alternative Change Order form. If Integrator fails to deliver a complete Request for Change Order or incomplete Request for Change Order meeting all of the requirements of Section 13.3.2.6 within the appropriate time period, Integrator shall be required to provide a new PCO Notice before it may submit a Request for Change Order.

Related to Delivery of Request for Change Order

  • Change Order (5) The Change Order is then submitted to the Project Manager who immediately processes the CO with OPC as required by Bulletin 3.5 and BGS’ Contracting Plan.

  • Execution of requests 1. In order to comply with a request for assistance, the requested authority shall proceed, within the limits of its competence and available resources, as though it were acting on its own account or at the request of other authorities of that same Party, by supplying information already possessed, by carrying out appropriate enquiries or by arranging for them to be carried out. This provision shall also apply to any other authority to which the request has been addressed by the requested authority when the latter cannot act on its own.

  • REQUEST FOR REVIEW Within sixty (60) days after receiving notice from the Plan Administrator that a claim has been denied (in part or all of the claim), then claimant (or their duly authorized representative) may file with the Plan Administrator, a written request for a review of the denial of the claim. The claimant (or his duly authorized representative) shall then have the opportunity to submit written comments, documents, records and other information relating to the claim. The Plan Administrator shall also provide the claimant, upon request and free of charge, reasonable access to, and copies of, all documents, records and other information relevant (as defined in applicable ERISA regulations) to the claimant’s claim for benefits.

  • Amendment Process Requests to amend the Demonstration must be submitted to CMS for approval no later than 120 days prior to the planned date of implementation of the change and may not be implemented until approved. Amendment requests must include, but are not limited to, the following:

  • Project Delivery Order Procedures The TIPS Member having approved and signed an interlocal agreement, or other TIPS Membership document, may make a request of the awarded vendor under this Agreement when the TIPS Member has services that need to be undertaken. Notification may occur via phone, the web, email, fax, or in person. Upon notification of a pending request, the awarded vendor shall make contact with the TIPS Member as soon as possible, but must make contact with the TIPS Member within two working days. Scheduling of Projects Scheduling of projects (if applicable) may be accomplished when the TIPS Member issues a Purchase Order and/or an Agreement or Contract that will serve as “the notice to proceed” as agreed by the Vendor and the TIPS Member. The period for the delivery order will include the mobilization, materials purchase, installation and delivery, design, weather, and site cleanup and inspection. No additional claims may be made for delays as a result of these items. When the tasks have been completed the awarded vendor shall notify the client and have the TIPS Member or a designated representative of the TIPS Member inspect the work for acceptance under the scope and terms in the Purchase Order and/or Agreement or Contract. The TIPS Member will issue in writing any corrective actions that are required. Upon completion of these items, the TIPS Member will issue a completion notice and final payment will be issued per the contractual requirements of the project with the TIPS Member. Any Construction contract prepared by the TIPS Member’s Legal Counsel may alter the terms of this subsection, “Scheduling of Projects”.

  • Project Delivery Order Procedures The TIPS Member having approved and signed an interlocal agreement, or other TIPS Membership document, may make a request of the awarded Vendor under this Agreement when the TIPS Member desires goods or services awarded to the Vendor. Notification may occur via phone, the web, courier, email, fax, or in person. Upon notification of a pending request, the awarded Vendor shall acknowledge the TIPS Member’s request as soon as possible, but must make contact with the TIPS Member within two working days. Status of TIPS Members as Related to This Agreement TIPS Members stand in the place of TIPS as related to this agreement and have the same access to the proposal information and all related documents. TIPS Members have all the same rights under the awarded Agreement as TIPS.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!