Directives for Performance of the Services. 1. The Architect shall provide, with the assistance of the Consultants, the professional Services more particularly described in Section VII below for this Project. 2. The Architect shall provide a schedule for the performance of the Services upon execution of this Agreement. Time is of the essence in the performance of this Agreement. 3. The estimated Direct Construction Cost of the Project is $ to $ . [OR] The construction budget for the Project is currently estimated at $ . 4. The Architect shall fully cooperate with Owner to meet all Project budgets. Owner understands that Architect, in providing opinions of probable construction cost, has no control over the cost or availability of labor, equipment, or materials, or over market conditions or Contractor's method of pricing, and that Architect's opinions of probable construction costs are made on the basis of Architect's professional judgment and experience. Architect makes no warranty, express or implied, that the bids or the negotiated cost of the Work will not vary from Architect's opinion of probable construction cost. In the event the Architect's opinion of probable construction cost exceeds the budget for the Project listed in Sub-section 3 above by any amount during the design or construction phases, or in the event the bids or negotiated cost of the Work exceed the budget for the Project listed earlier in this Section by more that 10 percent, Architect, upon notice from Owner and prior to the award of the construction contract, agrees to modify, at Architect's sole expense, Architect's Schematic Design documents, Design Development documents or Construction Documents (or with owners approval those portions of those documents where opinions of probable construction costs or bids exceeded the budget or stipulated percentage). This redesign effort shall constitute Architect's sole responsibility with respect to its opinions of probable construction cost, and Architect agrees to cooperate with Owner in revising the Project scope and quality in order to reduce the opinion of probable Construction Cost, or the bids or negotiated price, so that they do not exceed the Project budget. 5. The Architect shall provide all Services for the Project in accordance with the terms and conditions of this Agreement. The Architect's performance of Services shall be as a professional Architect to the Owner to perform the professional services necessary for the Project, and to provide the technical documents and super...

Directives for Performance of the Services. 1. The Consultant shall provide all Services for the Project in accordance with the terms and conditions of this Agreement. The Consultant's performance of Services shall be as a professional Consultant to the Owner to carry out the activities of Project and to provide the technical documents and supervision to achieve the Owner's Project objectives. 2. In administering this Agreement, the Owner may employ the services of an independent project manager, and potentially, other consultants as needed to fulfill the Owner’s objectives. 3. The Consultant shall provide a list of all sub-consultants which the Consultant intends to utilize on the Project. The list shall include such information on the qualifications of the sub-consultants as may be requested by the Owner. The Owner reserves the right to review the sub-consultants proposed, and the Consultant shall not retain a sub-consultant to which the Owner has a reasonable objection. 4. The Consultant shall provide to the Owner a list of the proposed key Project personnel of the Consultant and its sub-consultants to be assigned to the Project. This list shall include such information on the professional background of each of the assigned personnel as may be requested by the Owner. In the event that key personnel or sub-consultants become unavailable to Consultant at anytime, Consultant shall replace the key personnel and sub-consultants with personnel or sub-consultants having substantially equivalent or better qualifications than the key personnel or sub-consultant being replaced, as approved by Owner. Likewise, the Consultant shall remove any individual or sub-consultant from the Project if so directed by Owner in writing following discussion with the Consultant, provided that Consultant shall have a reasonable time period within which to find a suitable replacement. 5. Consultant shall make no news release, press release or statement to a member of the news media regarding this Project without prior written authorization from Owner.

See All (5)

Directives for Performance of the Services. 1. The Commissioning Agent shall provide all Services for the Project in accordance with the terms and conditions of this Agreement. The Commissioning Agent's performance of Services shall be as a professional Commissioning Agent for the Owner to carry out the activities of equipment and system commissioning, and to provide the technical documents and testing to achieve the Owner's Project objectives. 2. In administering this Agreement, the Owner may employ the services of an independent project manager, and potentially, other consultants as needed to fulfill the Owner’s objectives. Commissioning Agent shall cooperate with, and coordinate its Services with, such other consultants as the Owner and/or its Project Commissioning Agent may retain, as well as the Contractor and its subcontractors, in order to complete the commissioning Services and Project in a timely, cost-effective, and efficient manner. 3. Upon execution of the Agreement, Commissioning Agent shall provide Owner with a list of all Consultants Commissioning Agent intends to utilize on the Project. The list shall include such information on the qualifications of the Consultants as may be requested by the Owner. The Owner reserves the right to review the Consultants proposed, and the Commissioning Agent shall not retain a Consultant to which the Owner has a reasonable objection. 4. The Commissioning Agent shall provide to the Owner a list of its proposed key personnel and its Consultants to be engaged in performance of Services. This list shall include such information on the professional background of each of the assigned personnel as may be requested by the Owner. The Commissioning Agent acknowledges that award of this Agreement was made on the basis of the unique background and abilities of the proposed key personnel and Consultants identified in Commissioning Agent’s proposal for Services. Therefore, Commissioning Agent shall make available key personnel and Consultants as identified in its proposal. Any attempted substitution without written consent of Owner shall constitute a material breach of this Agreement. In the event that key personnel or Consultants become unavailable to Commissioning Agent at any time, Commissioning Agent shall replace the key personnel and Consultants with personnel or Consultants having substantially equivalent or better qualifications than the key personnel or Consultant being replaced, as approved by Owner. Likewise, the Commissioning Agent shall remove any pers...

See All (5)

Directives for Performance of the Services. 1. The Design Professional shall provide, with the assistance of the Consultants, the professional Services more particularly described in Section VII below for this Project. 2. The Design Professional shall provide a schedule for the performance of the Services upon execution of this Agreement. Time is of the essence in the performance of this Agreement.

Directives for Performance of the Services. 1. The Contractor shall provide all Services under this Agreement in accordance with the terms and conditions of this Agreement. The Contractor's performance of Services shall be as a professional Contractor to the Owner to carry out the Work under this Agreement and to provide the technical documents and supervision to achieve the Owner's objectives. 2. The Contractor shall provide a schedule for the performance of the Services upon execution of this Agreement. Time is of the essence in the performance of this Agreement. 3. In administering this Agreement, the Owner may employ the services of an independent project manager, and potentially, other contractors as needed to fulfill the Owner’s objectives.

Directives for Performance of the Services. 1. The Architect shall provide, with the assistance of the Consultants, the professional Services more particularly described in Section VII below for this Project. 2. The Architect shall provide a schedule for the performance of the Services upon execution of this Agreement. Time is of the essence in the performance of this Agreement. 3. The estimated Direct Construction Cost of the Project is $ to $ . [OR] The construction budget for the Project is currently estimated at $ . SAMPL exceed the budget for the Project listed earlier in this Section by more that 10 percent, Architect, upon notice from Owner and prior to the award of the construction contract, agrees to modify, at Architect's sole expense, Architect's Schematic Design documents, Design Development documents or Construction Documents (or with owners approval those portions of those documents where opinions of probable construction costs or bids exceeded the budget or stipulated percentage). This redesign effort shall constitute Architect's sole responsibility with respect to its opinions of probable construction cost, and Architect agrees to cooperate with Owner in revising the Project scope and quality in order to reduce the opinion of probable Construction Cost, or the bids or negotiated price, so that they do not exceed the Project budget. 5. The Architect shall provide all Services for the Project in accordance with the terms and conditions of this Agreement. The Architect's performance of Services shall be as a professional Architect to the Owner to perform the professional services necessary for the Project, and to provide the technical documents and supervision required to achieve the Owner's Project objectives. 6. In administering this Agreement, the Owner may employ the services of an independent project manager and other consultants as needed to fulfill the Owner’s objectives. 7. The Architect shall utilize the key personnel and Consultants identified on the attached Exhibit 1 in the performance of the Services for the Project. In addition to the full names, titles/positions and a summary of the duties and Services to be performed by the key personnel and Consultants that are included in the attached Exhibit 1, the Architect agrees to promptly provide such additional information on the professional background of each of the assigned personnel and Consultants as may be requested by the Owner. The Architect acknowledges that the Owner’s award of this Agreement to the Architect was made ...

Directives for Performance of the Services i. The Architect/Engineer/Engineer shall provide, with the assistance of the Consultants, the professional Services more particularly described in Section VII below for this Project.

Directives for Performance of the Services. 1. The Consultant shall provide all Services for the Project in accordance with the terms and conditions of this Agreement. The Consultant's performance of Services shall be as a professional Consultant to the Owner to carry out the activities of Project and to provide the technical documents and supervision to achieve the Owner's Project objectives. 2. In administering this Agreement, the Owner may employ the services of an independent project manager, and potentially, other consultants as needed to fulfill the Owner’s objectives. 3. The Consultant shall provide a list of all Consultants which the Consultant intends to utilize on the Project. The list shall include such information on the qualifications of the Consultants as may be requested by the Owner. The Owner reserves the right to review the Consultants proposed, and the Consultant shall not retain a Consultant to which the Owner has a reasonable objection. 4. The Consultant shall provide to the Owner a list of the proposed key Project personnel of the Consultant and its Consultants to be assigned to the Project. This list shall include such information on the professional background of each of the assigned personnel as may be requested by the Owner. In the event that key personnel or Consultants become unavailable to Consultant at anytime, Consultant shall replace the key personnel and Consultants with personnel or Consultants having substantially equivalent or better qualifications than the key personnel or Consultant being replaced, as approved by Owner. Likewise, the Consultant shall remove any individual or Consultant from the Project if so directed by Owner in writing following discussion with the Consultant, provided that Consultant shall have a reasonable time period within which to find a suitable replacement. 5. Consultant shall make no news release, press release or statement to a member of the news media regarding this Project without prior written authorization from Owner.

Directives for Performance of the Services Sample Clauses

Filter & Search

Related Clauses

Parent Clauses

Sub-Clauses