Expeditious Determination of All Claims and Disagreements Sample Clauses

Expeditious Determination of All Claims and Disagreements. Any disagreement or dispute between the Buyer and Seller or Buyer and TNB pursuant to the Wellington Neighborhood Contract to Buy Real Estate or this Limited Warranty or affecting the Residence or any claim in any way related to the Wellington Neighborhood Contract to Buy Real Estate, the Limited Warranty or occupancy of the Property that cannot be resolved, shall be expeditiously and inexpensively determined by the following method: One, or more, of the parties may declare that a dispute or claim exists, in which event the matter shall be referred within seven (7) days to the Judicial Arbitrator Group (“JAG”), Denver, Colorado or if JAG is unavailable, to such other impartial arbitrator group as may be selected by the Seller. A single, fair and just arbitrator from such group shall be selected by the Seller. The arbitration shall be conducted by the arbitrator and by the parties at the JAG offices in Denver, Colorado pursuant to the following method and without participation of attorneys or other legal advisors: Ten days before the arbitration is to begin, each party shall submit to the arbitrator a summary statement of no more than five double-spaced and typewritten pages that shall set forth the following sections: (i) a succinct statement of the nature and extent to the dispute, (ii) a summary of the position of the submitting party, (iii) a summary of the evidence in support of the position of the submitting party, including a list of witnesses and what they would state on the subject, and a list of documents and what pertinence they have to the dispute, and (iv) a request for specific relief sought. No other written submission to the arbitrator shall be permitted before, during or after the arbitration other than as related to procedural matters. For purposes of this section, if the Buyer or an officer of the Seller or TNB is an attorney, he shall be deemed a “party” and allowed to participate. The arbitration shall consume no more than eight hours, seven hours of which shall be devoted to testimony (to the extent necessary) and the arbitrator shall control the course thereof according to whatever order or pattern he deems fair, but allowing sufficient time for cross-examination of any and all witnesses. No cross examination shall exceed in length the direct examination of the same witness. Within the eight-hour limitation, each party shall be permitted a 15-minute opening statement and 15-minute closing statement. No formal rules of procedure or evi...
Sample 1
AutoNDA by SimpleDocs

Related to Expeditious Determination of All Claims and Disagreements

  • Claims and Disputes A. Claims by CONTRACTOR shall be made in writing to the COUNTY within two (2) business days after the commencement of the event giving rise to such claim or CONTRACTOR shall be deemed to have waived the claim. All claims shall be priced in accordance with the section in this document entitled “Changes in Work”.

  • Resolution of Claims and Disputes 4.4.1 The Architect will review Claims and take one or more of the following preliminary actions within ten days of receipt of a Claim: (1) request additional supporting data from the claimant, (2) submit a schedule to the parties indicating when the Architect expects to take action, (3) reject the Claim in whole or in part, stating reasons for rejection, (4) recommend approval of the Claim by the other party or (5) suggest a compromise. The Architect may also, but is not obligated to, notify the surety, if any, of the nature and amount of the Claim.

  • Complaints and Disputes 28.1. If the Client wishes to report a complaint, he must send an email to the Company with the completed “Complaints Form” found on the Website. The Company will try to resolve it without undue delay and according to the Company’s Complaints Procedure for Clients.

  • DETERMINATION OF DISPUTES Any dispute arising under this Section 2.6 shall be resolved pursuant to the dispute resolution procedures of Article 7.

  • Complaints and Dispute Resolution 16.1 Where a dispute arises in connection with any aspect of this Agreement, the parties acting with good faith, will use all reasonable endeavours to bring any such issue to the attention of the other party in a timely fashion and in any event within 60 days of any such dispute coming to their attention.

  • Amicable Settlement and Dispute Resolution i. Either Party is entitled to raise any claim, dispute or difference of whatever nature arising under, out of or in connection with this Agreement ( “Dispute”) by giving a written notice (Dispute Notice) to the other Party, which shall contain:

  • Consultations and Dispute Settlement 1. The provisions of Articles XXII and XXIII of GATT 1994 as elaborated and applied by the Dispute Settlement Understanding shall apply to consultations and the settlement of disputes under this Agreement, except as otherwise specifically provided herein.

  • Resolution of Disagreements Disputes arising under this Agreement will be resolved informally by discussions between Agency Points of Contact, or other officials designated by each agency.

  • APPLICABLE LAW AND DISPUTE SETTLEMENT 1. The execution and performance of this Contract shall be governed by the laws of People’s Republic of China;

  • Disagreement If the Parties reasonably and in good faith disagree as to whether there has been a material breach, the Party that seeks to dispute that there has been a material breach may contest the allegation in accordance with Section 13.1. The cure period for any allegation made in good faith as to a material breach under this Agreement will, subject to Sections 12.3.1 and 13.2, run from the date that written notice was first provided to the Breaching Party by the Non-Breaching Party.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!