Extension of Time and Compensation Rights Sample Clauses

Extension of Time and Compensation Rights. In the case of any suspension under this Section 20.7 or any suspension by Contractor under Section 19.5, other than a Suspension for Cause: (a) the Project Guaranteed Dates shall be extended by a period equal to the suspension period, subject to Section 20.7.1, plus a reasonable period for demobilization and remobilization as approved by Owner; (b) Owner shall pay Contractor within the periods provided in Article 6 after receipt of Contractor’s invoices (which invoices shall be submitted monthly during the applicable suspension period) for those costs (including a reasonable fee) incurred during the suspension period that are documented by Contractor to the reasonable satisfaction of Owner, to the extent attributable to the suspension, and that are: (i) for the purpose of safeguarding or storing the Work and the Equipment and Materials at the point of fabrication, in transit, or at the Project Site; (ii) for personnel, Subcontractors, or rented Equipment and Materials, the payments for which, with Owner’s prior written concurrence, are continued during the suspension period; (iii) for reasonable costs of demobilization and remobilization; or (iv) for rescheduling the Work (including penalties or additional payments to Subcontractors for the same); or (v) any other actual costs that can be reasonably demonstrated by Contractor and reasonably acceptable to Owner with respect to the Project; and (c) the Project Schedule, the Critical Path Items on the Milestone Summary Schedule and the Payment Schedule shall be adjusted to account for same.
Sample 1
AutoNDA by SimpleDocs
Extension of Time and Compensation Rights. In the case of any suspension under this Article 22 or any suspension by Contractor under Section 20.5, other than a Suspension for Cause (as defined below): (a) the Substantial Completion Guaranteed Date and every other Contractor milestone shall be extended by the period of time that Contractor is delayed in the performance of activities or milestones as a result of such suspension, plus a reasonable period for demobilization and remobilization as approved by Owner; (b) Owner shall pay Contractor within thirty (30) days after receipt of Contractor’s invoice (which invoices shall be submitted monthly during the applicable suspension period) for those costs incurred during the suspension period that are documented by Contractor to the reasonable satisfaction of Owner, to the extent attributable to the suspension, and that are: (i) for the purpose of safeguarding and/or storing the Work and the Equipment and Materials at the point of fabrication, in transit, or at the Site; (ii) for personnel, Subcontractors, Vendors, or rented Equipment and Materials, the payments for which, with Owner’s prior written concurrence, are continued during the suspension period; (iii) for reasonable costs of demobilization and remobilization; or (iv) for rescheduling the Work (including penalties or additional payments to Subcontractors or Vendors for the same); and (c) the Key Date Items on the Key Date Schedule and the Payment Schedule shall be adjusted to account for same. Notwithstanding the foregoing, neither the Contract Price nor the Substantial Completion Guaranteed Date shall be adjusted for a Suspension for Cause. A suspension shall be a Suspension for Cause if both of the following conditions are satisfied (a “Suspension for Cause”):
Sample 1

Related to Extension of Time and Compensation Rights

  • Extra Compensation The Board shall pay no fees, other than described above, to the PA/E unless authorized by the Board as follows: A. If the scope of the Project or site is changed, the Board and the PA/E shall negotiate a reasonable fee based upon the probable estimated construction cost in changing the scope of the work and the approximate percentage of the estimated construction cost which was used to negotiate this Agreement if, and, as such may be applicable. B. If the DOE or Board requires the PA/E to make major or costly changes to the Schematic, Preliminary or Construction Document Phase submittals, which changes are not caused by architectural or engineering error or oversight, the PA/E shall be paid to redesign for additional expenses in an amount agreed to by the parties. Under no circumstances will the principals of the PA/E and the principals of his consultants be paid a fee in excess of $125.00 per hour.

  • Employment and Compensation The following terms and conditions will govern the Executive’s employment with the Company throughout the Term.

  • Overtime and Compensatory Time Overtime work shall be compensated as follows: A. Hours in an active pay status in excess of forty (40) hours in any calendar week shall be compensated at the rate of one and one-half (1 1/2) times the total rate of pay, as defined by Section 43.01, for each hour of such time. Total rate of pay includes the base rate plus longevity, all applicable supplements, and shift differential where applicable. B. An employee may elect to take compensatory time off in lieu of cash overtime payment for hours in an active pay status more than forty (40) hours in any calendar week. Such compensatory time shall be granted on a time and one-half (1 1/2) basis. C. The maximum accrual of compensatory time shall be two hundred forty (240) hours and compensatory time must be taken within one (1) year of its being earned. D. When the maximum hours of compensatory time accrual is rendered, payment for overtime work shall be made in cash. Compensatory time not taken within one (1) year shall be paid in cash to a maximum of eighty (80) hours in any pay period. E. Compensatory time is not available for use until it appears on the employee’s earnings statement and on the date the funds are made available. F. Upon termination of employment, an employee shall be paid for unused compensatory time at a rate which is the higher of: 1. The final total rate received by the employee, or 2. The average total rate received by the employee during the last three (3) years of employment. For the purposes of this Article, active pay status is defined as the conditions under which an employee is eligible to receive pay, and includes, but is not limited to, vacation leave and personal leave. Sick leave and any leave used in lieu of sick leave shall not be considered as active pay status for purposes of this Article. Compensatory time requests must be submitted in writing twenty-four (24) hours in advance of the anticipated time off, unless the need for time off is of an emergency nature.

  • Compensation for Overtime Assigned overtime is designated as those hours over the regular hours of work which are requested of the employee by management. Assigned overtime worked shall be paid at the rate of time and one-half (1 1/2).

  • Termination Compensation Termination Compensation equal to two (2) times the Executive's Base Period Income shall be paid to the Executive in a single sum payment in cash on the thirtieth (30th) business day after the later of (a) the Control Change Date and (b) the date of the Executive's employment termination; provided that if at the time of the Executive's termination of employment the Executive is a Specified Employee, then payment of the Termination Compensation to the Executive shall be made on the first day of the seventh (7th) month following the Executive's employment termination.

  • Exclusivity of Salary and Benefits The Executive shall not be entitled to any payments or benefits other than those provided under this Agreement.

  • Additional Compensation Notwithstanding anything in this Memorandum of Understanding to the contrary when in the judgment of the Board, it becomes necessary or desirable to utilize the services of County employees in capacities other than those for which they are regularly employed, the Board may authorize and, if appropriate, fix an additional rate of compensation for such employees.

  • Employees and Compensation (A) Shown on Schedule 6.15(A) is a list of the name of each employee, sales agent or other Person, separately identified as to part-time or full-time, who is currently employed in the Business by Seller, together with each Person’s job classification, date of hire, and current rate of compensation (or method for computing same). All employees of Seller are “at will” employees whose employment may be terminated by Seller at any time, with or without notice or cause. (B) Schedule 6.15(B) hereto lists all compensation and benefit plans, contracts and arrangements maintained, sponsored or participated in by Seller or any of its Affiliates in connection with the Business and in effect as of the date hereof including, without limitation, all pension (including all such employee pension benefit plans as defined in Section 3(2) of ERISA), profit-sharing, savings and thrift, fringe benefit, bonus, incentive or deferred compensation, severance pay and medical and life insurance plans and employee welfare plans as defined in Section 3(1) of ERISA that are sponsored by Seller or any of its Affiliates and in which any employees of Seller participate (collectively, “Employee Benefit Plans”). (C) As to Employee Benefit Plans sponsored by Seller or its Affiliates that are “employee pension benefit plans” as defined in Section 3(2) of ERISA, such plans sponsored by Seller or its Affiliates are tax qualified under Section 401(a) of the Code, are not currently under examination by, nor are any matters pending before, the Internal Revenue Service, the Employee Benefits Security Administration or any quasi-government agency, are not subject to any claim, suit or arbitration (other than routine claims for benefits), are not subject to the minimum funding standards of Code Section 412, are in compliance with and have been administered in accordance with their terms and in compliance with all applicable requirements of law, including, but not limited to, the Code and ERISA, and there have been no prohibited transactions as defined in Code Section 4975 or ERISA Section 406 with respect to such plans that could subject Seller or its Affiliates to a tax or penalty under Code Section 4975 or ERISA Section 502(i). (D) Neither Seller nor any of its Affiliates has incurred any Liability under Title IV of ERISA that has or could, after the Effective Date, become a Lien upon any of the Purchased Assets pursuant to ERISA Section 4068. (E) Neither Seller nor any of its Affiliates is or has ever been required to contribute to any “multiemployer plan,” as such term is defined in Section 4001(a)(3) of ERISA, in which any employees of Seller in connection with the Business participate. (F) Except as set forth in Schedule 6.15(F), no Employee Benefit Plan provides medical, surgical, hospitalization, death or similar benefits (whether or not insured) for employees for period extending beyond their retirement or other termination of service, other than (i) coverage mandated by applicable law, or (ii) death benefits under any pension plan. (G) For the purposes of this Section 6.15, Seller shall include all trades or business under common control with Seller as provided in the regulations under Code Section 414(c).

  • Special Compensation The Company shall pay to the Executive a lump sum equal to three times the sum of (a) the highest per annum base rate of salary in effect with respect to the Executive during the three-year period immediately prior to the termination of employment plus (b) the Highest Bonus Amount. Such lump sum shall be paid by the Company to the Executive within ten business days after the Executive's termination of employment, unless the provisions of Section 3(e) below apply. The amount of the aggregate lump sum provided by this Section 3(c), whether paid immediately or deferred, shall not be counted as compensation for purposes of any other benefit plan or program applicable to the Executive.

  • REFUND OF UNEARNED COMPENSATION The Party of the Second Part agrees to refund the Party of the First Part any compensation received for which no services were rendered. TERMINATION: This contract may be terminated by either party pursuant to law. OTHER CONDITIONS: Any subsequent contracts shall supersede the provisions of this contract. PARTIES: The Fort Xxxxx School District 100, Party of the First Part, and XXXXX XXXXX XXXXX Party of the Second Part, agree as follows:

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!