Method of Performing the Work Sample Clauses

Method of Performing the Work. When measurements are affected by conditions already established or where items are to be fitted into constructed conditions, it shall be the Contractor's responsibility to verify all such dimensions at the site and the actual job dimensions shall take precedence. The apparent silence of the Contract Documents as to any detail, or the apparent omission from them of a detailed description concerning any Work to be done and materials to be furnished, shall be regarded as meaning that only the best general practice is to prevail and that only material and workmanship of the best quality is to be used, and interpretation of the Contract Documents shall be made upon that basis.
Sample 1
AutoNDA by SimpleDocs
Method of Performing the Work. ‌ The apparent silence of the Contract Documents as to any detail, or the apparent omission from them of a detailed description concerning any Work to be done and materials to be furnished, shall be regarded as meaning that only the best general practice is to prevail and that only material and workmanship of the best quality is to be used, and interpretation of the Contract Documents shall be made upon that basis. When measurements are affected by conditions already established or where items are to be fitted into constructed conditions, it shall be the Contractor's responsibility to verify all such dimensions at the site and the actual job dimensions shall take precedence. If the City’s Project Manager reasonably determines the rate of progress of the Work is not such as to ensure its completion within the designated completion time, or if, in the opinion of the City’s Project Manager, the Contractor is not proceeding with the Work diligently or expeditiously or is not performing all or any part of the Work according to the Project schedule accepted by or determined by the City’s Project Manager, the City’s Project Manager shall have the right to order the Contractor to do either or both of the following: (1) improve its work force; and/or (2) improve its performance in accordance with the schedule to ensure completion of the Project within the specified time. The Contractor shall immediately comply with such orders at no additional cost to the City.
Sample 1
Method of Performing the Work. The Contractor shall familiarize itself with normal Town operations where the Work is to be performed so that it can conduct the Work in the best possible manner to the complete satisfaction of the Project Manager. The Work to be performed shall be done in such a manner so as not to interfere with the normal Town operations. The manner in which the Work is performed shall be subject to the approval of the Project Manager, whom if necessary, shall have the authority to require changes in the manner in which the Work is performed. There shall be no obstruction of Town services without the prior written approval of the Project Manager. The Contractor shall protect public and private property, and utilities from injury or loss arising in connection with the Work, and take all necessary precautions to prevent accidents, injuries, or damage to persons or property on or near the Work. The Contractor shall be responsible for, and shall replace and make good all loss, injury, or damage to any property (including landscaping, irrigation, walks, drives, structures or utilities). Contractor shall be responsible for documentation including photos of the work site before and after the authorized services/work is conducted to verify property’s pre-existing and post-existing condition.
Sample 1
Method of Performing the Work. The apparent silence of the Contract as to any detail, or the apparent omission from them of a detailed description concerning any Work to be done and materials to be furnished, shall be regarded as meaning that only the best general practice is to prevail and that only material and workmanship of the best quality is to be used, and interpretation of the Contract shall be made upon that basis. The Contractor shall comply with the manufacturer’s requirements for the handling, delivery and storage of all equipment and materials. Contractor shall inspect all equipment and materials immediately prior to installation and shall not install any damaged or defective items. Contractor shall comply with the manufacturer’s applicable instructions and recommendations for the performance of the Work, to the extent that these instructions and recommendations are more explicit or more stringent than requirements indicated in the Contract. The Contractor shall familiarize itself with normal Town operations where the Work is to be performed so that it can conduct the Work in the best possible manner to the complete satisfaction of the Project Manager. The Work to be performed shall be done in such a manner so as not to interfere with the normal Town operations. The manner in which the Work is performed shall be subject to the approval of the Project Manager, whom if necessary, shall have the authority to require changes in the manner in which the Work is performed. There shall be no obstruction of Town services without the prior written approval of the Project Manager. All requests for such interruption or obstruction must be given in writing to the Project Manager twenty- four (24) hours in advance of the interruption of Town operations.
Sample 1
Method of Performing the Work. 13 12. Work Staging and Phasing 14 13. Site Investigation and Representation 14 14. Design-Build Firm to Check Plans, Specifications and Data 14 15. Design-Build Firm's Responsibility for Damages and Accidents 14 16. Accidents 15 17. Safety Precautions 15 18. Occupational Health and Safety 16
Sample 1
Method of Performing the Work. When measurements are affected by conditions already established or where items are to be fitted into constructed conditions, it shall be the Design-Build Firm's responsibility to verify all such dimensions at the site and the actual job dimensions shall take precedence. The apparent silence of the Contract documents as to any detail, or the apparent omission from them of a detailed description concerning any Work to be done and materials to be furnished, shall be regarded as meaning that only the best general practice is to prevail and that only material and workmanship of the best quality is to be used, and interpretation of the Contract Documents shall be made upon that basis. Communication and coordination between the Project Manager, Consultant , and the Design-Build Firm is key to successful execution and completion of the Work. If the Project Manager or Consultant reasonably determines the rate of progress of the Work is not such as to ensure its completion within the designated completion time, or if, in the opinion of the Project Manager the Design-Build Firm is not proceeding with the Work diligently or expeditiously or is not performing all or any part of the Work according to the Project schedule accepted by or determined by the Project, the Project Manager shall have the right to order the Design-Build Firm to do either or both of the following: (1) improve its work force; and/or (2) improve its performance in accordance with the schedule to ensure completion of the Project(s) within the specified time. The Design-Build Firm shall comply with such orders at no additional cost to the City, within seven calendar days upon the receipt of a “Notice to Cure”; (3) The City at its sole option may also have Work performed by a third party Design-Build Firm and deduct such cost from any monies due the Design- Build Firm. Where materials are transported in the performance of the Work, vehicles shall not be loaded beyond the capacity recommended by the vehicle manufacturer or permitted by Federal, State or local law(s). When it is necessary to cross curbing or sidewalks, protection against damage shall be provided by the Design-Build Firm and any damaged curbing, grass areas, sidewalks or other areas shall be repaired at the expense of the Design-Build Firm to the satisfaction of the Project Manager and Consultant. The Design-Build Firm shall furnish to the Project Manager a complete listing of 24-hour telephone numbers at which responsible representativ...
Sample 1

Related to Method of Performing the Work

  • Method of Performing Services Contractor will determine the method, details, and means of performing the above-described services including measures to protect the safety of the traveling public and Contractor’s employees. County shall not have the right to, and shall not, control the manner or determine the method of accomplishing Contractor’s services.

  • Standard of Performance Consultant represents and warrants that it has the qualifications, experience and facilities necessary to properly perform the services required under this Agreement in a thorough, competent and professional manner. Consultant shall at all times faithfully, competently and to the best of its ability, experience and talent, perform all services described herein. In meeting its obligations under this Agreement, Consultant shall employ, at a minimum, generally accepted standards and practices utilized by persons engaged in providing services similar to those required of Consultant under this Agreement.

  • Continuing the Work The Contractor shall carry on the Work and adhere to the progress schedule during all disputes, disagreements or alternative resolution processes with the Owner. The Contractor shall not delay or postpone any Work because of the pending resolution of any disputes, disagreements or processes, except as the Owner and the Contractor may agree in writing.

  • Method of Billing Consultant may submit invoices to the City for approval on a progress basis, but no more often than two times a month. Said invoice shall be based on the total of all Consultant’s services which have been completed to City’s sole satisfaction. City shall pay Consultant’s invoice within forty-five (45) days from the date City receives said invoice. Each invoice shall describe in detail, the services performed, the date of performance, and the associated time for completion. Any additional services approved and performed pursuant to this Agreement shall be designated as “Additional Services” and shall identify the number of the authorized change order, where applicable, on all invoices.

  • PERIOD OF PERFORMANCE The period of performance for this contract begins , and ends .

  • Subcontracting for the Provision of Services (a) The parties acknowledge that, subject to the provisions of the Enabling Legislation, the HSP may subcontract the provision of some or all of the Services. For the purposes of this Agreement, actions taken or not taken by the subcontractor, and Services provided by the subcontractor, will be deemed actions taken or not taken by the HSP, and Services provided by the HSP. (b) When entering into a subcontract the HSP agrees that the terms of the subcontract will enable the HSP to meet its obligations under this Agreement. Without limiting the foregoing, the HSP will include a provision that permits the Funder or its authorized representatives, to audit the subcontractor in respect of the subcontract if the Funder or its authorized representatives determines that such an audit would be necessary to confirm that the HSP has complied with the terms of this Agreement. (c) Nothing contained in this Agreement or a subcontract will create a contractual relationship between any subcontractor or its directors, officers, employees, agents, partners, affiliates or volunteers and the Funder. (d) When entering into a subcontract, the HSP agrees that the terms of the subcontract will enable the HSP to meet its obligations under the FLSA.

  • Acceptance of Employment; Standard of Performance The Subadviser accepts its employment as a discretionary series adviser of the Designated Series and agrees to use its best professional judgment to make investment decisions for the Designated Series in accordance with the provisions of this Agreement and as set forth in Schedule D attached hereto and made a part hereof.

  • Testing-the-Waters Materials If at any time following the distribution of any Written Testing-the-Waters Communication there occurred or occurs an event or development as a result of which such Written Testing-the-Waters Communication included or would include an untrue statement of a material fact or omitted or would omit to state a material fact necessary in order to make the statements therein, in the light of the circumstances existing at that subsequent time, not misleading, the Company will promptly notify the Representatives and will promptly amend or supplement, at its own expense, such Written Testing-the-Waters Communication to eliminate or correct such untrue statement or omission.

  • Acceptance of Appointment; Standard of Performance Adviser accepts the appointment as discretionary portfolio manager and agrees to use its best professional judgment to make timely investment decisions for the Fund in accordance with the provisions of this Agreement.

  • Removal of Personnel The CONSULTANT agrees, within thirty (30) calendar days of receipt of a written request from the COUNTY, to promptly remove and replace the CONSULTANT'S Project Director, or any other personnel employed or retained by the CONSULTANT, or personnel of the sub-consultants or subcontractors engaged by the CONSULTANT to provide and/or perform services and/or work pursuant to the requirements of this Agreement, who the COUNTY shall request, in writing, be removed, which request may be made by the COUNTY with or without cause. However, if day thirty

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!