Milestone Deliverables. The Critical Deliverables, Transition Milestones and Transformation Milestones (and related deliverables) are "Milestone Deliverables" for purposes of this Agreement. Other Deliverables may also be classified as Milestone Deliverables by the Parties if so agreed in writing. Each Milestone Deliverable shall be provided by Service Provider and subject to DIR (or, if designated in writing by DIR, DIR Customer's) "Acceptance" as described below in Section 4.6(b)(i) through (v).
Milestone Deliverables. The Critical Deliverables are "Milestone Deliverables" for purposes of this Agreement. Other Deliverables may also be classified as Milestone Deliverables by the Parties if so agreed in writing. Each Milestone Deliverable shall be provided by Service Provider and subject to DIR (or, if designated in writing by DIR, DIR Customer's) "Acceptance" as described below in S ection 4.8(b)(i) through ( v).
Milestone Deliverables. The Recipient shall provide to the Province, to the Province’s satisfaction, the Milestone Deliverables as set out in Annex A-3 of Schedule A. Any Milestone Deliverable with a Milestone Completion Date occurring during a Claim Period must be submitted at the time of the claim. Milestone Deliverables will conform with the requirements and specifications set out in Annex A-3 of Schedule A.
Milestone Deliverables. Licensee shall deliver to Platinum the following Milestone Deliverables for Platinum's written approval (subject to Paragraphs 11(b) and (c)): concept/treatment, design document, technical document, character models, material game builds and revisions, first playable version, Alpha, Beta and Gold Master candidate. Licensee shall also deliver to Platinum a Milestone Schedule in which descriptions for each Milestone Deliverable and the delivery dates for such Deliverables are set out, which Milestone Schedule shall mirror that which Licensee accepts from its Developer(s). With regard to the delivery dates for the final Deliverables of the Title, Licensee shall deliver the final Deliverables to Platinum in accordance with the Milestone Schedule. If Licensee fails to deliver the final Deliverables within three (3) months of the dates set out in the Milestone Schedule approved by Platinum, Platinum shall be entitled to terminate this Agreement in accordance with Paragraph 23. By way of clarification, Licensee shall have the opportunity to cure such non-delivery of the final Deliverable prior to any attempted termination provided that such later delivery of the final Deliverable permits the Title to be commercially released as provided herein.
Milestone Deliverables. ON Semiconductor will use commercially reasonable efforts to complete assigned Milestones according to the following timetable and as may be further detailed in each SOW: Milestone 0 Development Agreement signed & project kick-off [***] T0(1) Milestone 1 [***] [***] T0 + [***] months Milestone 2 [***] [***] T0 + [***] months Milestone 3 [***] [***] T0 + [***] months Milestone 4 [***] [***] T0 + [***] months Milestone 5 [***] [***] T0 + [***] months Milestone 6 [***] [***] T0 + [***] months Total [***]
(1) T0 is the Effective Date.
(2) [***].
(3) [***].
Milestone Deliverables. The Critical Deliverables and Transition Milestones are "Milestone Deliverables" for purposes of this Agreement. Other Deliverables may also be classified as Milestone Deliverables by the Parties if mutually agreed. Each Milestone Deliverable shall be provided by Successful Respondent and subject to DIR (or, if designated in writing by DIR, DIR Customer's) "Acceptance" as described below in Section 4.5(b)Error! Reference source not found. through (v). Specific Acceptance criteria may be contained within Exhibit 3.7, individual Work Orders, or in a Deliverables Expectation Document as described in Exhibit 3.3 Critical Deliverables.
Milestone Deliverables. The Parties will submit the following “Milestone Deliverables,” “Delivery Dates,” and
Milestone Deliverables. The Parties will submit the following “Milestone Deliverables,” “Delivery Dates,” and “Amounts” in the Web form at the “Business Terms” page for the Project on the Site:
4. Final Delivery Date & Amount US$
Milestone Deliverables. YMCA shall during the course of the design phase and the construction phase deliver either by mail or hand delivery to the City PM the Milestone Deliverables.
Milestone Deliverables
