Extraordinary Circumstances If either party is rendered unable, wholly or in part, by reason of strikes, accidents, acts of God, weather conditions or any other acts beyond its control and without its fault or negligence to comply with any obligations or performance required under this Agreement, then such party shall have the option to suspend its obligations or performance hereunder until the extraordinary performance circumstances are resolved. If the extraordinary performance circumstances are not resolved within a reasonable period of time, however, the non-defaulting party shall have the option, upon prior written notice, of terminating the Agreement.
Termination on Change of Control and Insolvency 36.1 The Authority may terminate the Contract with immediate effect by notice in writing where the Contractor is a company and in respect of the Contractor: -
Unusual Circumstances If during a contract term where costs to the City are to remain firm or adjustments are restricted by a percentage or CPI cap, unusual circumstances that could not have been foreseen by either party of the contract occur, and those circumstances significantly affect the Contractor’s cost in providing the required prior items or services, then the Contractor may request adjustments to the costs to the City to reflect the changed circumstances. The circumstances must be beyond the control of the Contractor, and the requested adjustments must be fully documented. The City may, after examination, refuse to accept the adjusted costs if they are not properly documented, increases are considered to be excessive, or decreases are considered to be insufficient. In the event the City does not wish to accept the adjusted costs and the matter cannot be resolved to the satisfaction of the City, the City will reserve the following options:
Prevention of Avoidance The Parties shall implement as necessary requirements to prevent Financial Institutions from adopting practices intended to circumvent the reporting required under this Agreement.
CHANGE OF CIRCUMSTANCES The Company will, at any time during the pendency of a Placement Notice advise the Agent promptly after it shall have received notice or obtained knowledge thereof, of any information or fact that would alter or affect in any material respect any opinion, certificate, letter or other document required to be provided to the Agent pursuant to this Agreement.
Unavoidable Delay When construction is impeded as a result of strikes, lockouts, acts of God or other factors beyond the control, and ability to remedy, of the Developer.
Unavoidable Delays Delays due to acts of God, acts of public agencies, labor disputes, strikes, fires, freight embargoes, inability (despite the exercise of due diligence) to obtain supplies, materials, fuels or permits, or other causes or contingencies (excluding financial inability) beyond the reasonable control of Landlord or Tenant, as applicable. Landlord shall use commercially reasonable efforts to provide Tenant with prompt notice of any Unavoidable Delays.
Uncontrollable Circumstances The University shall not be in default of this Agreement if delays in or failure of performance shall be due to circumstances beyond the reasonable control of the University. Such circumstances shall include, but are not limited to, acts of government or similar authorities, public health emergency, fire, flood, terrorism, earthquakes, weather, riot, civil disturbance, police action or similar events beyond the University’s reasonable control. In the event of an uncontrollable circumstance, the University shall immediately notify the Student and shall resume performance of its obligations immediately upon cessation of the uncontrollable circumstance.
Interference or Impairment If a Party (“Impaired Party”) reasonably determines that the services, network, facilities, or methods of operation, of the other Party (“Interfering Party”) will or are likely to interfere with or impair the Impaired Party’s provision of services or the operation of the Impaired Party’s network or facilities, the Impaired Party may interrupt or suspend any Service provided to the Interfering Party to the extent necessary to prevent such interference or impairment, subject to the following:
Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.