Owner Office Accommodations Sample Clauses

Owner Office Accommodations. All security, furnishings, electrical power and other temporary utilities, lighting, telephones, facsimile, and high speed internet access associated with the office accommodation below shall be provided by Contractor. This shall include the telecommunications line rentals from Notice to Proceed until thirty (30) Days after Substantial Completion of Subproject 2. International long distance calls will be reimbursed to Contractor as Reimbursable Costs. Owner will supply computers to Owner personnel. Contractor shall provide office accommodation for: a. Up to a peak of thirty-three (33) Owner personnel at Contractor’s Houston home office, including six reserved covered parking spaces, commencing with NTP and concluding with Substantial Completion of Subproject 2. b. Up to total forty-two (42) Owner personnel at Liquefaction Facility Site during construction activities, including reserved parking area and six covered parking spaces for Owner personnel until Substantial Completion of Subproject 2.
Sample 1Sample 2Sample 3See All (8)
AutoNDA by SimpleDocs
Owner Office Accommodations. All security, furnishings, electrical power, housekeeping services (including potable water and sewage) and other temporary utilities, lighting, telephones, facsimile, and high speed internet access associated with the office accommodation below shall be provided by Contractor. This shall include the telecommunications services from NTP until thirty (30) Days after Substantial Completion of each Project including business international long distance calls. Contractor will not supply computers, printers and vehicles to Owner personnel. Contractor will provide internet access, and viewing station to review 3D Smart Plant models. Contractor will provide 30 day notice prior to changing document management system. Owner consultants costs, staff and staff costs during engineering, procurement, construction, testing, commissioning, start-up and performance testing periods are excluded. Contractor shall provide office accommodation for: a. Up to a peak of thirty-three (33) Owner personnel at Contractor’s Houston home office, including parking spaces, commencing with NTP and concluding with Substantial Completion of Project 5; and b. Up to total forty-two (42) Owner personnel at Phase 4 Site during construction activities, including parking area for Owner personnel until Substantial Completion of Project 5. This is exclusive of Owner’s operations personnel who it is anticipated will be able to be accommodated in the administration building when ready for occupancy.
Sample 1See All (4)
Owner Office Accommodations. All security, furnishings, electrical power, housekeeping services and other temporary utilities, lighting, telephones, facsimile, and high speed internet access associated with the office accommodation below shall be provided by Contractor commencing at LNTP or NTP (whichever occurs earlier), and concluding upon Substantial Completion of Subproject 3; provided, however, that item 2.3(b) below shall be provided commencing at substantial completion of Subproject 2 until Substantial Completion of Subproject 3, and telecommunications line rentals shall be provided until thirty (30) Days after Substantial Completion of Subproject 3. International long distance calls will be reimbursed to Contractor as Reimbursable Costs. Owner will supply computers to Owner personnel. Contractor shall provide office accommodation for: a. Up to a peak of ten (10) Owner personnel at Contractor’s Houston home office, including two (2) reserved covered parking spaces. b. Up to total forty-five (45) Owner personnel at Stage 2 Site, including a reserved parking area.
Sample 1Sample 2Sample 3
Owner Office Accommodations. All security, furnishings, electrical power and other temporary utilities, lighting, telephones, facsimile, and high speed internet access associated with the office accommodation below shall be provided by Contractor. This shall include the telecommunications line rentals from Notice to Proceed until thirty (30) Days after Substantial Completion of Subproject 4. International long distance calls will be reimbursed to Contractor as Reimbursable Costs. Owner will supply computers to Owner personnel. Contractor shall provide office accommodation for: a. Up to a peak of ten (10) Owner personnel at Contractor’s Houston home office, including two (2) reserved covered parking spaces, commencing with NTP and concluding with Substantial Completion of Subproject 4. b. Up to total twenty (20) Owner personnel at Stage 2 Site during construction activities, including reserved parking area and two (2) covered parking spaces for Owner personnel until Substantial Completion of Subproject 4.
Sample 1Sample 2Sample 3
Owner Office Accommodations. All security, furnishings, electrical power, housekeeping services and other temporary utilities, lighting, telephones, facsimile, and high speed internet access associated with the office accommodation below shall be provided by Contractor. This shall include the telecommunications line rentals from Notice to Proceed until thirty (30) Days after Substantial Completion of Subproject 6. International long distance calls will be reimbursed to Contractor as Reimbursable Costs. Owner will supply computers to Owner personnel. Contractor shall provide office accommodation for: a. Up to a peak of thirty-three (33) Owner personnel at Contractor’s Houston home office, including six (6) reserved covered parking spaces, commencing with LNTP No. 1 or NTP (whichever occurs earlier) and concluding with Substantial Completion of Subproject 6. b. Up to total forty-two (42) Owner personnel at Stage 4 Site during construction activities, including reserved parking area and six (6) covered parking spaces for Owner personnel until Substantial Completion of Subproject 6.
Sample 1

Related to Owner Office Accommodations

  • Proper Accommodation Proper accommodation shall be provided for employees to have their meals and store and change their clothes.

  • Letter of Credit Accommodations (a) Subject to and upon the terms and conditions contained herein, at the request of any Borrower, Lender agrees to provide or arrange for Letter of Credit Accommodations for the account of Borrowers containing terms and conditions acceptable to Lender and the issuer thereof. Any payments made by Lender to any issuer thereof and/or related parties in connection with the Letter of Credit Accommodations shall constitute additional Revolving Loans to Borrowers pursuant to this Section 2. (b) In addition to any charges, fees or expenses charged by any bank or issuer in connection with the Letter of Credit Accommodations, Borrowers shall pay to Lender a letter of credit fee at a rate equal to one and one-half percent (1.5%) per annum on the daily outstanding balance of the Letter of Credit Accommodations for the immediately preceding month (or part thereof), payable in arrears as of the first day of each succeeding month, except that Borrowers shall pay to Lender such letter of credit fee, at Lender's option, without notice, at a rate equal to three and one-half percent (3 1/2%) per annum on such daily outstanding balance for: (i) the period from and after the date of termination hereof until Lender has received full and final payment of all Obligations (notwithstanding entry of a judgment against any Borrower) and (ii) the period from and after the date of the occurrence of an Event of Default for so long as such Event of Default is continuing as determined by Lender. Such letter of credit fee shall be calculated on the basis of a three hundred sixty (360) day year and actual days elapsed and the obligation of Borrowers to pay such fee shall survive the termination or non- renewal of this Agreement. (c) No Letter of Credit Accommodations shall be available unless on the date of the proposed issuance of any Letter of Credit Accommodations, the Revolving Loans available to any Borrowers (subject to the Maximum Credit and any Availability Reserves) are equal to or greater than: (i) if the proposed Letter of Credit Accommodation is for the purpose of purchasing Eligible Inventory, the sum of (A) seventy percent (70%) of the cost of such Eligible Inventory, plus (B) freight, taxes, duty and other amounts which Lender estimates must be paid in connection with such Inventory upon arrival and for delivery to one of such Borrower's locations for Eligible Inventory within the United States of America and (ii) if the proposed Letter of Credit Accommodation is for any other purpose, an amount equal to one hundred (100%) percent of the face amount thereof and all other commitments and obligations made or incurred by Lender with respect thereto. Effective on the issuance of each Letter of Credit Accommodation, an Availability Reserve shall be established in the applicable amount set forth in Section 2.2(c)(i) or Section 2.2(c)(ii). (d) Except in Lender's discretion, the amount of all outstanding Letter of Credit Accommodations and all other commitments and obligations made or incurred by Lender in connection therewith shall not at any time exceed $3,000,000 with respect to all Borrowers; provided, however, that no Letter of Credit Accommodations shall be made with respect to IBI. At any time an Event of Default exists or has occurred and is continuing, upon Lender's request, Borrowers will either furnish cash collateral to secure the reimbursement obligations to the issuer in connection with any Letter of Credit Accommodations or furnish cash collateral to Lender for the Letter of Credit Accommodations, and in either case, the Revolving Loans otherwise available to Borrowers shall not be reduced as provided in Section 2.2(c) to the extent of such cash collateral. (e) Each Borrower shall jointly and severally indemnify and hold Lender harmless from and against any and all losses, claims, damages, liabilities, costs and expenses which Lender may suffer or incur in connection with any Letter of Credit Accommodations and any documents, drafts or acceptances relating thereto, including any losses, claims, damages, liabilities, costs and expenses due to any action taken by any issuer or correspondent with respect to any Letter of Credit Accommodation. Each Borrower assumes all risks with respect to the acts or omissions of the drawer under or beneficiary of any Letter of Credit Accommodation and for such purposes the drawer or beneficiary shall be deemed such Borrower's agent. Each Borrower assumes all risks for, and agrees to pay, all foreign, Federal, State and local taxes, duties and levies relating to any goods subject to any Letter of Credit Accommodations or any documents, drafts or acceptances thereunder. Each Borrower hereby releases and holds Lender harmless from and against any acts, waivers, errors, delays or omissions, whether caused by any Borrower, by any issuer or correspondent or otherwise with respect to or relating to any Letter of Credit Accommodation. The provisions of this Section 2.2(e) shall survive the payment of Obligations and the termination of this Agreement. (f) Nothing contained herein shall be deemed or construed to grant any Borrower any right or authority to pledge the credit of Lender in any manner. Lender shall have no liability of any kind with respect to any Letter of Credit Accommodation provided by an issuer other than Lender unless Lender has duly executed and delivered to such issuer the application or a guarantee or indemnification in writing with respect to such Letter of Credit Accommodation. Each Borrower shall be bound by any reasonable interpretation made in good faith by Lender, or any other issuer or correspondent under or in connection with any Letter of Credit Accommodation or any documents, drafts or acceptances thereunder, notwithstanding that such interpretation may be inconsistent with any instructions of such or any Borrower. Lender shall have the sole and exclusive right and authority to: (i) at any time an Event of Default exists or has occurred and is continuing, (A) approve or resolve any questions of non-compliance of documents, (B) give any instructions as to acceptance or rejection of any documents or goods or (C) execute any and all applications for steamship or airway guaranties, indemnities or delivery orders, and (ii) at all times, (A) grant any extensions of the maturity of, time of payment for, or time of presentation of, any drafts, acceptances, or documents, and (B) agree to any amendments, renewals, extensions, modifications, changes or cancellations of any of the terms or conditions of any of the applications, Letter of Credit Accommodations, or documents, drafts or acceptances thereunder or any letters of credit included in the Collateral. Lender may take such actions either in its own name or in any Borrower's name. (g) Any rights, remedies, duties or obligations granted or undertaken by any Borrower to any issuer or correspondent in any application for any Letter of Credit Accommodation, or any other agreement in favor of any issuer or correspondent relating to any Letter of Credit Accommodation, shall be deemed to have been granted or undertaken by any Borrower to Lender. Any duties or obligations undertaken by Lender to any issuer or correspondent in any application for any Letter of Credit Accommodation, or any other agreement by Lender in favor of any issuer or correspondent relating to any Letter of Credit Accommodation, shall be deemed to have been undertaken by any Borrower to Lender and to apply in all respects to such Borrower.

  • Reasonable Accommodations Landlord agrees to comply with all applicable laws providing equal housing opportunities, including making reasonable accommodations for known physical or mental limitations of qualified individuals with a disability, unless undue hardship on Landlord would result. Tenant is responsible for making Landlord aware of any such required accommodations that are reasonable and will not impose an undue hardship on Landlord. If Tenant discloses a disability and requests an accommodation, Landlord has the right to have a qualified healthcare provider verify the disability if the disability is not readily apparent, and Landlord has the right to use the qualified healthcare provider verifying the disability as a resource for providing the reasonable accommodation.

  • Accommodations Clean accommodations will be provided for employees to have their meals and keep their clothes.

  • Reasonable Accommodation Sections 34.1 through 34.4 of Article 34, Reasonable Accommodation and Disability Separation, apply to represented individuals.

  • DISABILITY ACCOMMODATIONS State does not discriminate on the basis of disability in admission to, access to, or operations of its programs, services, or activities. Individuals who need aids, alternative document formats, or services for effective communications or other disability related accommodations in the programs and services offered are invited to make their needs and preferences known to this office. Interested parties should provide as much advance notice as possible.

  • Request for Credit Extension The Administrative Agent and, if applicable, the L/C Issuer or the Swingline Lender shall have received a Request for Credit Extension in accordance with the requirements hereof. Each Request for Credit Extension (other than a Loan Notice requesting only a conversion of Loans to the other Type or a continuation of Eurodollar Rate Loans) submitted by the Borrower shall be deemed to be a representation and warranty that the conditions specified in Sections 4.02(a) and (b) have been satisfied on and as of the date of the applicable Credit Extension.

  • Borrower’s Loan Application Borrower shall be in default if, during the Loan application process, Borrower or any persons or entities acting at the direction of Borrower or with Borrower’s knowledge or consent gave materially false, misleading, or inaccurate information or statements to Lender (or failed to provide Lender with material information) in connection with the Loan. Material representations include, but are not limited to, representations concerning Xxxxxxxx’s occupancy of the Property as Xxxxxxxx’s principal residence.

  • The Letter of Credit Facility (i) Subject to the terms and conditions hereinafter set forth (A) Issuing Bank agrees, in reliance on the Agreements of the Lenders set forth in this Section (1) to issue Letters of Credit for the account of any Borrower from time to time on any Business Day during the period from the Effective Date hereof until 10 days before the Termination Date in an aggregate Available Amount for all Letters of Credit not to exceed at any time the lesser of (x) the Letter of Credit Facility at such time and (y) the Unused Revolving Credit Commitments of the Lenders at such time (provided that in no event shall the Issuing Bank be required to issue a Letter of Credit if, after giving effect to such issuance, the aggregate amount of the Revolving Credit Exposures of all Lenders shall exceed the Revolving Credit Availability at such time) and to amend or extend Letters of Credit previously issued by it in accordance with the terms of this Section 2.16, and (2) to honor drawings under the Letters of Credit, and (B) the Lenders severally agree to participate in Letters of Credit issued for the account of any Borrower and any drawings thereunder. Each request by a Borrower for the issuance or amendment of a Letter of Credit shall be deemed to be a representation by the Borrowers that the issuance, extension or amendment of the Letter of Credit so requested complies with the conditions set forth in the preceding sentence. Within the foregoing limits, and subject to the terms and conditions hereof, each Borrower’s ability to obtain Letters of Credit shall be fully revolving, and accordingly such Borrower may, during the foregoing period, obtain Letters of Credit to replace Letters of Credit that have expired or that have been drawn upon and reimbursed. (ii) No Letter of Credit shall have an expiration date (including all rights of the applicable Borrower or the beneficiary to require renewal) later than the earlier of (A) 10 days before the Termination Date and (B) one year after the date of issuance thereof (but such Letter of Credit may by its terms be automatically renewable (each, an “Auto-Extension Letter of Credit”); provided that any such Auto-Extension Letter of Credit must permit the Issuing Bank to prevent any such extension at least once in each twelve (12) month period (commencing with the date of issuance of such Letter of Credit) by giving prior notice to the beneficiary thereof not later than a day (the “Non-Extension Notice Date”) in each such twelve (12) month period to be agreed upon at the time such Letter of Credit is issued. Unless otherwise directed by the Issuing Bank, the applicable Borrower shall not be required to make a specific request to the Issuing Bank for any such extension. Once an Auto-Extension Letter of Credit has been issued, the Lenders shall be deemed to have authorized (but may not require) the Issuing Bank to permit the extension of such Letter of Credit at any time to an expiry date not later than the date 10 days before the Termination Date; provided that the Issuing Bank shall not permit any such extension if (A) the Issuing Bank has determined that it would not be permitted, or would have no obligation at such time to issue such Letter of Credit in its revised form (as extended) under the terms hereof (by reason of the provisions of this Section 2.16 or otherwise), or (B) it has received notice (which may be by telephone or in writing) on or before the day that is seven (7) Business Days before the Non-Extension Notice Date (1) from the Agent that the Required Lenders have elected not to permit such extension or (2) from the Agent, any Lender or a Borrower that one or more of the applicable conditions specified in Section 3.02 is not then satisfied, and in each such case directing the Issuing Bank not to permit such extension. (iii) The Issuing Bank shall not be under any obligation to issue any Letter of Credit if: (A) any order, judgment or decree of any Governmental Authority or arbitrator shall by its terms purport to enjoin or restrain the Issuing Bank from issuing the Letter of Credit, or any law applicable to the Issuing Bank or any request or directive (whether or not having the force of law) from any Governmental Authority with jurisdiction over the Issuing Bank shall prohibit, or request that the Issuing Bank refrain from, the issuance of letters of credit generally or the Letter of Credit in particular or shall impose upon the Issuing Bank with respect to the Letter of Credit any restriction, reserve or capital requirement (for which the Issuing Bank is not otherwise compensated hereunder) not in effect on the Effective Date, or shall impose upon the Issuing Bank any unreimbursed loss, cost or expense which was not applicable on the Effective Date and which the Issuing Bank in good xxxxx xxxxx material to it; (B) the issuance of the Letter of Credit would violate one or more policies of the Issuing Bank applicable to letters of credit generally; (C) except as otherwise agreed by the Agent and the Issuing Bank, the Letter of Credit is in an initial stated amount of less than $100,000; (D) the Letter of Credit is to be denominated in a currency other than Dollars; (E) any Lender is at that time a Defaulting Lender, unless the Issuing Bank has entered into arrangements, including the delivery of Cash Collateral, satisfactory to the Issuing Bank (in its sole discretion) with the Borrowers or such Lender to eliminate the Issuing Bank’s actual or potential Fronting Exposure (after giving effect to Section 2.23(a)(iv)) with respect to the Defaulting Lender arising from either the Letter of Credit then proposed to be issued or that Letter of Credit and all other L/C Exposure as to which the Issuing Bank has actual or potential Fronting Exposure, as it may elect in its sole discretion; or (F) the Letter of Credit contains any provisions for automatic reinstatement of the stated amount after any drawing thereunder. (iv) The Issuing Bank shall not amend any Letter of Credit if the Issuing Bank would not be permitted at such time to issue the Letter of Credit in its amended form under the terms hereof. (v) The Issuing Bank shall be under no obligation to amend any Letter of Credit if (A) the Issuing Bank would have no obligation at such time to issue such Letter of Credit in its amended form under the terms hereof, or (B) the beneficiary of such Letter of Credit does not accept the proposed amendment to the Letter of Credit. (vi) The Issuing Bank shall act on behalf of the Lenders with respect to any Letters of Credit issued by it and the documents associated therewith, and the Issuing Bank shall have all of the benefits and immunities (A) provided to the Agent in Article VII with respect to any acts taken or omissions suffered by the Issuing Bank in connection with Letters of Credit issued by it or proposed to be issued by it and L/C Related Documents pertaining to such Letters of Credit as fully as if the term “Agent” as used in Article VII included the Issuing Bank with respect to such acts or omissions, and (B) as additionally provided herein with respect to the Issuing Bank.

  • Issuing Bank’s Duties Regarding Letters of Credit; Unconditional Nature of Reimbursement Obligations In examining documents presented in connection with drawings under Letters of Credit and making payments under such Letters of Credit against such documents, the Issuing Bank shall only be required to use the same standard of care as it uses in connection with examining documents presented in connection with drawings under letters of credit in which it has not sold participations and making payments under such letters of credit. The Borrower assumes all risks of the acts and omissions of, or misuse of the Letters of Credit by, the respective beneficiaries of such Letters of Credit. In furtherance and not in limitation of the foregoing, none of the Issuing Bank, Administrative Agent or any of the Lenders shall be responsible for, and the Borrower’s obligations in respect of Letters of Credit shall not be affected in any manner by, (i) the form, validity, sufficiency, accuracy, genuineness or legal effects of any document submitted by any party in connection with the application for and issuance of or any drawing honored under any Letter of Credit even if such document should in fact prove to be in any or all respects invalid, insufficient, inaccurate, fraudulent or forged; (ii) the validity or sufficiency of any instrument transferring or assigning or purporting to transfer or assign any Letter of Credit, or the rights or benefits thereunder or proceeds thereof, in whole or in part, which may prove to be invalid or ineffective for any reason; (iii) failure of the beneficiary of any Letter of Credit to comply fully with conditions required in order to draw upon such Letter of Credit; (iv) errors, omissions, interruptions or delays in transmission or delivery of any messages, by mail, cable, facsimile, electronic mail, telecopy or otherwise, whether or not they be in cipher; (v) errors in interpretation of technical terms; (vi) any loss or delay in the transmission or otherwise of any document required in order to make a drawing under any Letter of Credit, or of the proceeds thereof; (vii) the misapplication by the beneficiary of any Letter of Credit, or of the proceeds of any drawing under any Letter of Credit; or (viii) any consequences arising from causes beyond the control of the Issuing Bank, Administrative Agent or the Lenders. None of the above shall affect, impair or prevent the vesting of any of the Issuing Bank’s or Administrative Agent’s rights or powers hereunder. Any action taken or omitted to be taken by the Issuing Bank under or in connection with any Letter of Credit, if taken or omitted in the absence of gross negligence or willful misconduct (as determined by a court of competent jurisdiction in a final, non-appealable judgment), shall not create against the Issuing Bank any liability to the Borrower, the Administrative Agent or any Lender. In this connection, the obligation of the Borrower to reimburse the Issuing Bank for any drawing made under any Letter of Credit, and to repay any Revolving Loan made pursuant to the second sentence of the immediately preceding subsection (e), shall be absolute, unconditional and irrevocable and shall be paid strictly in accordance with the terms of this Agreement and any other applicable Letter of Credit Document under all circumstances whatsoever, including without limitation, the following circumstances: (A) any lack of validity or enforceability of any Letter of Credit Document or any term or provisions therein; (B) any amendment or waiver of or any consent to departure from all or any of the Letter of Credit Documents; (C) the existence of any claim, setoff, defense or other right which the Borrower may have at any time against the Issuing Bank, the Administrative Agent or any Lender, any beneficiary of a Letter of Credit or any other Person, whether in connection with this Agreement, the transactions contemplated hereby or in the Letter of Credit Documents or any unrelated transaction; (D) any breach of contract or dispute between the Borrower, the Issuing Bank, the Administrative Agent, any Lender or any other Person; (E) any demand, statement or any other document presented under a Letter of Credit proving to be forged, fraudulent, invalid or insufficient in any respect or any statement therein or made in connection therewith being untrue or inaccurate in any respect whatsoever; (F) any non-application or misapplication by the beneficiary of a Letter of Credit or of the proceeds of any drawing under such Letter of Credit; (G) payment by the Issuing Bank under any Letter of Credit against presentation of a draft or certificate which does not strictly comply with the terms of such Letter of Credit; and (H) any other act, omission to act, delay or circumstance whatsoever that might, but for the provisions of this Section, constitute a legal or equitable defense to or discharge of the Borrower’s Reimbursement Obligations. Notwithstanding anything to the contrary contained in this Section or Section 12.10., but not in limitation of the Borrower’s unconditional obligation to reimburse the Issuing Bank for any drawing made under a Letter of Credit as provided in this Section and to repay any Revolving Loan made pursuant to the second sentence of the immediately preceding subsection (e), the Borrower shall have no obligation to indemnify the Administrative Agent, the Issuing Bank or any Lender in respect of any liability incurred by the Administrative Agent, the Issuing Bank or such Lender arising solely out of the gross negligence or willful misconduct of the Administrative Agent, the Issuing Bank or such Lender in respect of a Letter of Credit as determined by a court of competent jurisdiction in a final, non-appealable judgment. Except as otherwise provided in this Section, nothing in this Section shall affect any rights the Borrower may have with respect to the gross negligence or willful misconduct of the Administrative Agent, the Issuing Bank or any Lender with respect to any Letter of Credit.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!