Performance of Utility Work Sample Clauses

Performance of Utility Work a. The FDOT shall incorporate the Plans Package into its contract for construction of the Project.
Sample 1Sample 2Sample 3See All (7)
AutoNDA by SimpleDocs
Performance of Utility Work a. The FDOT will include the Utility Work in its plans and specifications for the Project and will include the Utility Work as part of the FDOT’s construction of the Project. The preparation of the plans and specifications and the construction of the Project will be performed in such manner as the FDOT, in its discretion, deemed appropriate.
Sample 1Sample 2Sample 3
Performance of Utility Work a. The UAO shall perform the Utility Work in accordance with the utility relocation schedule attached hereto as Exhibit A and by this reference made a part hereof (the Schedule) and the plans and specifications for the Utility Work which have been previously approved by the FDOT (the Plans), said Plans being incorporated herein and made a part hereof by this reference. If the Schedule and the Plans have not been prepared as of the date of the execution of this Agreement, then the Utility Work shall be performed in accordance with the Plans, and the Schedule that are hereafter prepared in compliance with the notice previously sent to the UAO which established the terms and conditions under which those documents are to be prepared. The FDOT’s approval of the Plans shall not be deemed to be an adoption of the Plans by the FDOT nor a substitution for the proper exercise of engineering judgment and the UAO shall at all times remain responsible for any errors or omissions in the Plans. The Utility Work shall include all Facilities located on the Project and neither the failure of the UAO to include all of the Facilities in the Schedule, nor the Plans, nor the failure of the FDOT to identify this omission during its review of the Plans shall relieve the UAO of the obligation to make those Facilities part of the Utility Work. Time shall be of the essence in complying with the total time shown by the Schedule for the Utility Work as well as any and all interim time frames specified therein. The Utility Work shall be performed in a manner and using such methods so as to not cause a delay to the FDOT or its contractors in the prosecution of the Project. The UAO shall be responsible for all costs incurred as a result of any delay to the FDOT or its contractors caused by errors or omissions in the Plans or the Schedule (including location of the Facilities and the proper inclusion of all Facilities as part of the Utility Work as stated above); failure to perform the Utility Work in accordance with the Plans and Schedule; or failure of the UAO to comply with any other obligation under this Agreement or under the law.
Sample 1
Performance of Utility Work a. The UAO shall perform the Utility Work in accordance with the Schedule and the Plans. Time shall be of the essence in complying with the total time shown by the Schedule for the Utility Work as well as any and all interim time frames specified therein. The Utility Work shall be performed in a manner and using such methods so as to not cause a delay to the FDOT or its contractors in the prosecution of the Project. The UAO shall be responsible for all costs incurred as a result of any delay to the FDOT or its contractors caused by errors or omissions in the Plans, Schedule, or Estimate (including inaccurate location of the Facilities); failure to perform the Utility Work in accordance with the Plans and Schedule; or failure of the UAO to comply with any other obligation under this Agreement or under the law.
Sample 1
Performance of Utility Work. When performing utility work in Tract A, each Owner shall use or shall cause anyone performing utility work on behalf of or claiming under such Owner to use, commercially reasonable efforts to minimize any disruption to vehicular ingress and egress across Tract A; provided, however that the Owners acknowledge and accept that vehicular ingress and egress across Tract A may be temporarily limited as a result of utility work in Tract A. After the performance of any utility work in Tract A by or on behalf of an Owner for the purposes set forth in this Section 0, such Owner shall cause the affected portions of Tract A to be properly compacted and shall be responsible, at its sole cost and expense, for the restoration of all improvements and landscaping affected in any way by such work to at least the condition of such improvements and landscaping as it existed prior to such installation (including, without limitation, replacing any damaged trees with trees of similar size and type to the trees damaged), and such Owner shall warranty that all such work shall be free of material defects for a period of one (1) year following the completion of such work. In its use of Tract A and in the performance of the utility work which an Owner is authorized to perform within Tract A, such Owner shall use its reasonable efforts to avoid causing any damage to, or interference with, any improvements on or within Tract A (including, without limitation, any other utility lines installed under, across or within Tract A) or on or within the real property adjacent to Tract A; and each such Owner shall, during the performance of any utility work in Tract A, use commercially reasonable efforts to provide vehicular access to each Owner of Benefited Property.
Sample 1
Performance of Utility Work. When performing utility work in the Roadways, each Owner shall use or shall cause anyone performing utility work on behalf of or claiming under such Owner to use, commercially reasonable efforts to minimize any disruption to vehicular ingress and egress across the Roadways; provided, however that the Owners acknowledge and accept that vehicular ingress and egress across the Roadways may be temporarily limited as a result of utility work in the Roadways. After the performance of any utility work in the Roadways by or on behalf of an Owner for the purposes set forth in this Section 1, such Owner shall cause the affected portions of the Roadways to be properly compacted and shall be responsible, at its sole cost and expense, for the restoration of all improvements and landscaping affected in any way by such work to at least the condition of such improvements and landscaping as it existed prior to such installation (including, without limitation, replacing any damaged trees with trees of similar size and type to the trees damaged), and such Owner shall warranty that all such work shall be free of material defects for a period of one (1) year following the completion of such work. In its use of the Roadways and in the performance of the utility work which an Owner is authorized to perform within the Roadways, such Owner shall use its reasonable efforts to avoid causing any damage to, or interference with, any improvements on or within the Roadways (including, without limitation, any other utility lines installed under, across or within the Roadways) or on or within the real property adjacent to the Roadways; and each such Owner shall, during the performance of any utility work in the Roadways, use commercially reasonable efforts to provide vehicular access to each Owner of Benefited Property.
Sample 1

Related to Performance of Utility Work

  • Performance of Work All work described in this Section 8 shall be performed only by Landlord or by contractors and subcontractors approved in writing by Landlord and only in accordance with plans and specifications approved by Landlord in writing. If Landlord elects, in its sole discretion, to supervise any work described in this Section 8, Tenant shall pay to Landlord a construction management fee equal to 5% of the cost of such work. Tenant shall cause all contractors and subcontractors to procure and maintain insurance coverage naming Landlord, Landlord’s Mortgagee, Landlord’s property management company and Landlord’s asset management company as additional insureds against such risks, in such amounts, and with such companies as Landlord may reasonably require. Tenant shall provide Landlord with the identities, mailing addresses and telephone numbers of all persons performing work or supplying materials prior to beginning such construction and Landlord may post on and about the Premises notices of non-responsibility pursuant to applicable Laws. All such work shall be performed in accordance with all Laws and in a good and workmanlike manner so as not to damage the Building (including the Premises, the Building’s Structure and the Building’s Systems) and shall use materials of a quality that is at least equal to the quality designated by Landlord as the minimum standard for the Building, and in such manner as to cause a minimum of disruption to the other occupants of the Project and interference with other construction in progress and with the transaction of business in the Project and the related complex. Landlord may designate reasonable rules, regulations and procedures for the performance of all such work in the Building (including insurance requirements for contractors) and, to the extent reasonably necessary to avoid disruption to the occupants of the Building, shall have the right to designate the time when such work may be performed. All such work which may affect the Building’s Structure or the Building’s Systems must be approved by the Project’s engineer of record, at Tenant’s expense and, at Landlord’s election, must be performed by Landlord’s usual contractor for such work. All work affecting the roof of the Building must be performed by Landlord’s roofing contractor and no such work will be permitted if it would void or reduce or otherwise adversely affect the warranty on the roof. Upon completion of any work described in this Section 8, except with respect to any Permitted Alterations or any repairs required to be made by Tenant under Section 8.2, Tenant shall furnish Landlord with accurate reproducible “as-built” CADD files of the improvements as constructed.

  • Performance of Services The Contractor is responsible for fully meeting all obligations set forth in the Contract and for providing Product in accordance with the Contract or any Authorized User Agreement.

  • Performance of Agreement Purchaser shall have performed in all material respects all obligations and agreements and complied in all material respects with all covenants and conditions contained in this Agreement to be performed or complied with by it at or prior to the Closing Date.

  • Service Level In the event that League InfoSight discovers or is notified by you of the existence of Non-Scheduled Downtime, we will use commercially reasonable efforts to determine the source of the problem and attempt to resolve it as quickly as possible.

  • Performance of Covenants Each covenant or obligation that the Company is required to comply with or to perform at or prior to the Closing shall have been complied with and performed in all material respects.

  • Service Levels Annex 1 to this Part A of this Call Off Schedule sets out the Service Levels the performance of which the Parties have agreed to measure. The Supplier shall monitor its performance of this Call Off Contract by reference to the relevant performance criteria for achieving the Service Levels shown in Annex 1 to this Part A of this Call Off Schedule (the Service Level Performance Criteria) and shall send the Customer a Performance Monitoring Report detailing the level of service which was achieved in accordance with the provisions of Part B (Performance Monitoring) of this Call Off Schedule. The Supplier shall, at all times, provide the Services in such a manner that the Service Levels Performance Measures are achieved. If the level of performance of the Supplier of any element of the provision by it of the Services during the Call Off Contract Period: is likely to or fails to meet any Service Level Performance Measure or is likely to cause or causes a Critical Service Failure to occur, the Supplier shall immediately notify the Customer in writing and the Customer, in its absolute discretion and without prejudice to any other of its rights howsoever arising including under Clause 12 of this Call Off Contract (Service Levels and Service Credits), may: require the Supplier to immediately take all remedial action that is reasonable to mitigate the impact on the Customer and to rectify or prevent a Service Level Failure or Critical Service Level Failure from taking place or recurring; and if the action taken under paragraph (a) above has not already prevented or remedied the Service Level Failure or Critical Service Level Failure, the Customer shall be entitled to instruct the Supplier to comply with the Rectification Plan Process; or if a Service Level Failure has occurred, deduct from the Call Off Contract Charges the applicable Service Level Credits payable by the Supplier to the Customer in accordance with the calculation formula set out in Annex 1 of this Part A of this Call Off Schedule; or if a Critical Service Level Failure has occurred, exercise its right to Compensation for Critical Service Level Failure in accordance with Clause 13 of this Call Off Contract (Critical Service Level Failure) (including subject, for the avoidance of doubt, the proviso in Clause 13.1.2 of this Call Off Contract in relation to Material Breach). Approval and implementation by the Customer of any Rectification Plan shall not relieve the Supplier of any continuing responsibility to achieve the Service Levels, or remedy any failure to do so, and no estoppels or waiver shall arise from any such Approval and/or implementation by the Customer. SERVICE CREDITS Annex 1 to this Part A of this Call Off Schedule sets out the formula used to calculate a Service Credit payable to the Customer as a result of a Service Level Failure in a given service period which, for the purpose of this Call Off Schedule, shall be a recurrent period of [one Month] during the Call Off Contract Period (the Service Period).

Time is Money Join Law Insider Premium to draft better contracts faster.