Availability Reserves All Revolving Loans otherwise available to Borrower pursuant to the lending formulas and subject to the Maximum Credit and other applicable limits hereunder shall be subject to Lender's continuing right to establish and revise Availability Reserves.
Project Cost Overruns In the event that the Recipient determines that the moneys granted pursuant to Section II hereof, together with the Local Subdivision Contribution, are insufficient to pay in full the costs of the Project, the Recipient may make a request for supplemental assistance to its District Committee. The Recipient must demonstrate that such funding is necessary for the completion of the Project and the cost overrun was the result of circumstances beyond the Recipient's control, that it could not have been avoided with the exercise of due care, and that such circumstances could not have been anticipated at the time of the Recipient's initial application. Should the District Committee approve such request the action shall be recorded in the District Committee's official meeting minutes and provided to the OPWC Director for the execution of an amendment to this Agreement.
Cost Overruns The Borrower shall ensure that all cost-overruns over the estimated construction costs of the Project as certified by a quantity surveyor or the Architect or as ascertained by the Lender as and when they occur shall be funded by the Borrower’s own equity;
Project Costs Simultaneously with the execution of this Agreement, the Company shall disclose to the Department all of the Project Costs which the Company seeks to include for purposes of determining the limitation of the amount of the Credit pursuant to Section 5-30 of the Act and provide to the Department a Schedule of Project Costs in the form as attached hereto as Exhibit C.
Replacement Reserve Fund Borrower shall pay to Lender on the Closing Date and on each Payment Date one twelfth of the amount (the "REPLACEMENT RESERVE MONTHLY DEPOSIT") reasonably estimated by Lender in its sole discretion to be due for replacements and repairs required to be made to the Property during the calendar year (collectively, the "REPLACEMENTS"), which Replacement Reserve Monthly Deposit shall be in an amount equal to no less than $0.15 per year per square foot of gross leasable area. Amounts so deposited shall hereinafter be referred to as Borrower's "REPLACEMENT RESERVE FUND" and the account in which such amounts are held shall hereinafter be referred to as Borrower's "REPLACEMENT RESERVE ACCOUNT". Lender may reassess its estimate of the amount necessary for the Replacement Reserve Fund from time to time, and may increase the monthly amounts required to be deposited into the Replacement Reserve Fund upon thirty (30) days notice to Borrower if Lender determines in its reasonable discretion that an increase is necessary to maintain the proper maintenance and operation of the Property. Any amount held in the Replacement Reserve Account and allocated for the Property shall be retained by Lender in an interest bearing account, or, at the option of Lender, in an Eligible Account at an Eligible Institution; PROVIDED, HOWEVER, that, any interest earned on said account shall accrue in said account for the benefit of Borrower, but shall remain in and constitute part of the Replacement Reserve Fund, and shall be disbursed in accordance with the terms hereof. Notwithstanding anything to the contrary in this Section 7.3, Borrower shall not be required to make Replacement Reserve Monthly Deposits, provided that: (i) no Event of Default shall have occurred; and (ii) Borrower makes all necessary Replacements and otherwise maintains the Property to Lender's satisfaction. Upon notice from Lender following: (a) an Event of Default; or (b) the failure of Borrower to make necessary Replacements or otherwise maintain the Property to Lender's satisfaction, Borrower shall begin to deposit the Replacement Reserve Monthly Deposit into the Replacement Reserve Fund beginning on the Payment Date (as defined herein) immediately following the date of such notice.
Construction Cost Budget The total cost to District of all elements of the Project designed or specified by the Architect, as adjusted at the end of each design phase in accordance with this Agreement. The Construction Cost Budget does not include the compensation of the Architect and the Architect’s Consultants, the cost of land, rights-of-way, financing or other costs which are the responsibility of the District, including construction management.
Construction Contract; Cost Budget Prior to execution of a construction contract, Tenant shall submit a copy of the proposed contract with the Contractor for the construction of the Tenant Improvements, including the general conditions with Contractor (the “Contract”) to Landlord for its approval, which approval shall not be unreasonably withheld, conditioned or delayed. Following execution of the Contract and prior to commencement of construction, Tenant shall provide Landlord with a fully executed copy of the Contract for Landlord’s records. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids and proposals for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, for all of Tenant’s Agents, of the final estimated costs to be incurred or which have been incurred in connection with the design and construction of the Tenant Improvements to be performed by or at the direction of Tenant or the Contractor (the “Construction Budget”), which costs shall include, but not be limited to, the costs of the Architect’s and Engineers’ fees and the Landlord Coordination Fee. The amount, if any, by which the total costs set forth in the Construction Budget exceed the amount of the Tenant Improvement Allowance is referred to herein as the “Over Allowance Amount”. In the event that an Over-Allowance Amount exists, then prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with cash in an amount equal to the Over-Allowance Amount. The Over-Allowance Amount shall be disbursed by Landlord prior to the disbursement of any of the then remaining portion of the Tenant Improvement Allowance, and such disbursement shall be pursuant to the same procedure as the Tenant Improvement Allowance. In the event that, after the total costs set forth in the Construction Budget have been delivered by Tenant to Landlord, the costs relating to the design and construction of the Tenant Improvements shall change, any additional costs for such design and construction in excess of the total costs set forth in the Construction Budget shall be added to the Over-Allowance Amount and the total costs set forth in the Construction Budget, and such additional costs shall be paid by Tenant to Landlord immediately as an addition to the Over-Allowance Amount or at Landlord’s option, Tenant shall make payments for such additional costs out of its own funds, but Tenant shall continue to provide Landlord with the documents described in items (i), (ii), (iii) and (iv) of Section 2.2.2.1 of this Tenant Work Letter, above, for Landlord’s approval, prior to Tenant paying such costs. All Tenant Improvements paid for by the Over-Allowance Amount shall be deemed Landlord’s property under the terms of the Lease.
Additional Reserve Costs (a) If and so long as any Lender is required after the date hereof to make special deposits with the Bank of England, to maintain reserve asset ratios or to pay fees, in each case in respect of such Lender’s Eurocurrency Loans in any Designated Foreign Currency, such Lender may require the relevant Borrower to pay, contemporaneously with each payment of interest on each of such Loans, additional interest on such Loan at a rate per annum equal to the Mandatory Costs Rate calculated in accordance with the formula and in the manner set forth in Exhibit C hereto. (b) If and so long as any Lender is required to comply with reserve assets, liquidity, cash margin or other requirements of any monetary or other authority (including any such requirement imposed by the Board or by European Central Bank or the European System of Central Banks, but excluding requirements reflected in the Mandatory Costs Rate) in respect of any of such Lender’s Eurocurrency Loans, such Lender may require the relevant Borrower to pay, contemporaneously with each payment of interest on each of such Lender’s Eurocurrency Loans subject to such requirements, additional interest on such Loan at a rate per annum specified by such Lender to be the cost to such Lender of complying with such requirements in relation to such Loan. (c) Any additional interest owed pursuant to paragraph (a) or (b) above shall be determined by the relevant Lender, which determination shall be presumed correct in the absence of facts or circumstances indicating that it has been made in error, and notified to the relevant Borrower (with a copy to the Applicable Agent) at least five Business Days before each date on which interest is payable for the relevant Loan, and such additional interest so notified to the relevant Borrower by such Lender shall be payable to the Applicable Agent for the account of such Lender on each date on which interest is payable for such Loan.
Approved Budget (a) On the last Thursday of each month after the Second Amendment Effective Time, on or before 12:00 pm (New York City time) on such Thursday, Administrative Borrower shall prepare and deliver to the Administrative Agent, for review and approval by the Required DDTL Approving Lenders, an updated week-by-week operating budget for the then subsequent month (each a “Budget” and, once approved as set forth below, the “Approved Budget”), which shall reflect Administrative Borrower’s good faith projection, for the Borrowers and their respective Restricted Subsidiaries, of (a) all weekly receipts (including from asset sales) and expenditures (including ordinary course operating expenses and any other fees and expenses related to the Loan Documents) in connection with the operation of their businesses, (b) weekly disbursements, and (c) net cash flow, in each case, for such month. The Budget delivered during the week of March 4, 2024 shall be the Approved Budget for March 2024. Together with delivery of the Budget, Administrative Borrower shall provide the Administrative Agent (for subsequent delivery to the Lenders) a variance report (“Variance Report”) in a form and substance reasonably acceptable to the Required DDTL Approving Lenders, comparing the actual receipts, disbursements, and net cash flow for such month through the immediately preceding week compared to the Approved Budget, both in dollar ($) and percentage (%) figures and an explanation of the variance. Each week promptly after the delivery of the Variance Report, the Borrower’s senior management and financial professionals shall review the Variance Report in detail during a telephonic conference with the Lenders. If the proposed Budget was timely delivered and contains the requisite information, the Lenders shall have until 2:00 p.m. (New York City Time) on the first Business Day of the following week to review any Budget after which time such Budget shall become an Approved Budget for all purposes hereunder; provided, no such Budget shall become an Approved Budget if reasonably objected to in writing (which may include e-mail) during the review period by the Administrative Agent (at the direction of the Required DDTL Approving Lenders) or Required DDTL Approving Lenders. (b) In the event that an event or circumstance occurs in between the monthly dates on which the Budgets are otherwise due pursuant to Section 6.24(a) which would make the then current Budget materially inaccurate, within two (2) Business Days of becoming aware of such event or circumstance, the Administrative Borrower shall provide notice of such event or circumstance to the Administrative Agent and the Lenders and promptly deliver a revised Budget reflecting the impact thereof. Without limiting the foregoing, the Budget shall be updated, modified or supplemented by the Administrative Borrower with the written consent of the Administrative Agent (at the direction of the Required DDTL Approving Lenders), and upon the request of the Administrative Agent (at the direction of the Required DDTL Approving Lenders) from time to time. (c) Each Budget delivered to the Administrative Agent and the Lenders shall be accompanied by such supporting documentation as reasonably requested by the Administrative Agent (at the direction of the Required DDTL Approving Lenders) and shall be prepared in good faith, with due care and based upon assumptions the Borrower believe to be reasonable. (d) Within one (1) Business Day of any Loan Party having knowledge of their occurrence or existence, Administrative Borrower shall provide the Administrative Agent and Lenders with written notice of any event or condition which is reasonably likely to entail expenditures of more than $100,000 which is not included in the Approved Budget (including, but not limited, on account of an accident, environmental event or other unanticipated occurrence) or which would otherwise be reasonably likely to have a negative impact on the value of the Loan Parties’ and their Subsidiaries’ assets or future business prospects or a similar event.
Disbursements from Replacement Reserve Account (a) Lender shall make disbursements from the Replacement Reserve Account to pay Borrower only for the costs of the Replacements. Lender shall not be obligated to make disbursements from the Replacement Reserve Account to reimburse Borrower for the costs of routine maintenance to the Property or for costs which are to be reimbursed from the Required Repair Fund (if any). (b) Lender shall, upon written request from Borrower and satisfaction of the requirements set forth in this Section 7.3.2, disburse to Borrower amounts from the Replacement Reserve Account necessary to pay for the actual approved costs of Replacements or to reimburse Borrower therefor, upon completion of such Replacements (or, upon partial completion in the case of Replacements made pursuant to Section 7.3.2(f)) as determined by Lender. In no event shall Lender be obligated to disburse funds from the Replacement Reserve Account if a Default or an Event of Default exists. (c) Each request for disbursement from the Replacement Reserve Account shall be in a form specified or approved by Lender and shall specify (i) the specific Replacements for which the disbursement is requested, (ii) the quantity and price of each item purchased, if the Replacement includes the purchase or replacement of specific items, (iii) the price of all materials (grouped by type or category) used in any Replacement other than the purchase or replacement of specific items, and (iv) the cost of all contracted labor or other services applicable to each Replacement for which such request for disbursement is made. With each request Borrower shall certify that all Replacements have been made in accordance with all applicable Legal Requirements of any Governmental Authority having jurisdiction over the Property to which the Replacements are being provided and, unless Lender has agreed to issue joint checks as described below, each request shall include evidence of payment of all such amounts. Each request for disbursement shall include copies of invoices for all items or materials purchased and all contracted labor or services provided. Except as provided in Section 7.3.2(e), each request for disbursement from the Replacement Reserve Account shall be made only after completion of the Replacement for which disbursement is requested. Borrower shall provide Lender evidence of completion satisfactory to Lender in its reasonable judgment. (d) Borrower shall pay all invoices in connection with the Replacements with respect to which a disbursement is requested prior to submitting such request for disbursement from the Replacement Reserve Account or, at the request of Borrower, Lender will issue joint checks, payable to Borrower and the contractor, supplier, materialman, mechanic, subcontractor or other party to whom payment is due in connection with a Replacement. In the case of payments made by joint check, Lender may require a waiver of lien from each Person receiving payment prior to Lender's disbursement from the Replacement Reserve Account. In addition, as a condition to any disbursement, Lender may require Borrower to obtain lien waivers from each contractor, supplier, materialman, mechanic or subcontractor who receives payment in an amount equal to or greater than $100,000 for completion of its work or delivery of its materials. Any lien waiver delivered hereunder shall conform to the requirements of applicable law and shall cover all work performed and materials supplied (including equipment and fixtures) for the Property by that contractor, supplier, subcontractor, mechanic or materialman through the date covered by the current reimbursement request (or, in the event that payment to such contractor, supplier, subcontractor, mechanic or materialmen is to be made by a joint check, the release of lien shall be effective through the date covered by the previous release of funds request). (e) If (i) the cost of a Replacement exceeds $100,000, (ii) the contractor performing such Replacement requires periodic payments pursuant to terms of a written contract, and (iii) Lender has approved in writing in advance such periodic payments, a request for reimbursement from the Replacement Reserve Account may be made after completion of a portion of the work under such contract, provided (A) such contract requires payment upon completion of such portion of the work, (B) the materials for which the request is made are on site at the Property and are properly secured or have been installed in the Property, (C) all other conditions in this Agreement for disbursement have been satisfied, (D) funds remaining in the Replacement Reserve Account are, in Lender's judgment, sufficient to complete such Replacement and other Replacements when required, and (E) if required by Lender, each contractor or subcontractor receiving payments under such contract shall provide a waiver of lien with respect to amounts which have been paid to that contractor or subcontractor. (f) Borrower shall not make a request for disbursement from the Replacement Reserve Account more frequently than once in any calendar month and (except in connection with the final disbursement) the total cost of all Replacements in any request shall not be less than $5,000.00.