Seller Work Sample Clauses

Seller Work. Purchaser acknowledges and agrees that Seller has demolished any and all structures and performed all associated abatement, including grading and hydroseeding at the site, so that the Property is cleared and free of debris for Purchaser to proceed with site preparation and construction. Purchaser further acknowledges and agrees that such work has been completed to Xxxxxxxxx’s complete satisfaction.
Sample 1
AutoNDA by SimpleDocs
Seller Work. Seller shall construct and install a sanitary sewer main line to the point where Buyer may construct and install a gravity line on the Property for service of the Property for Buyer’s Intended Use (the “Seller Work”), all upon the following terms and conditions and within the following time periods, subject to Force Majeure, as hereinafter defined, provided, however, the dates listed in this Section 11 are based upon an anticipated Closing on or before September 1, 2020, and in the event the Closing occurs after September 1, 2020, each date in Section 11(a), (b), and (c) shall correspondingly be extended by an equal number of days:
Sample 1
Seller Work. (a) Seller shall use Commercially Reasonable Efforts to obtain an Americans With Disabilities Act Compliance Plan from The United States Department of Justice for the Real Property (the “ADA Plan”) as soon as reasonably practicable after the Effective Date, but in no event later than one hundred eighty (180) days after the Effective Date. Once Seller has obtained the ADA Plan, the Parties shall attach the same hereto as Exhibit G pursuant to an amendment to this Agreement. Seller shall complete, at Seller’s sole cost and expense, the scope of work set forth in the ADA Plan, except for the Ballroom Bathroom Work (the “Seller Work”), in accordance with the time periods required therein. Purchaser acknowledges and agrees that Seller shall not be liable for the completion of any portion of the Ballroom Bathroom Work, and that Purchaser shall be solely responsible for the completion of the Ballroom Bathroom Work at Purchaser’s sole cost and expense after the Closing. Upon completion of each specific item of the Seller Work, Seller shall deliver to Purchaser a written notice that such item of the Seller Work has been completed and copies of the documents listed as “ADA Work Deliverables” on Exhibit G attached hereto with respect to such completed Seller Work (to the extent applicable) (each, a “Seller Work Completion Notice”). Purchaser shall have a period of ten (10) days after receipt of a Seller Work Completion Notice (the “Seller Work Objection Period”) to ensure that, in Purchaser’s reasonable judgment, the subject Seller Work has been satisfactorily completed in accordance with this Agreement and the ADA Plan. If Purchaser, in its reasonable judgment, determines that the subject Seller Work has not been satisfactorily completed in accordance with this Agreement and the ADA Plan, Purchaser must specifically set forth Purchaser’s objections in such notice (a “Seller Work Objection Notice”); provided, however, that Purchaser may not object to the completion of any portion of the Seller Work that has been approved by The United States Department of Justice. If, however, Purchaser, in its reasonable judgment, determines that the subject Seller Work has been satisfactorily completed in accordance with this Agreement, then Purchaser shall memorialize in a writing (an “Acceptance Notice”) to Seller Purchaser’s acceptance of such completed Seller Work (each such date of acceptance with respect to a specific item of Seller Work is referred to herein as the “Acceptan...
Sample 1
Seller Work. As of the Closing Date, Seller shall have paid (or adjusted in accordance with Article VII) all undisputed amounts owed by Seller to any contractor retained by Seller for the applicable portion of any installations, repairs, alterations or other work at the Real Property that has been actually performed as of the Effective Date which, if not so paid, might become the subject of a lien on the Real Property.
Sample 1
Seller Work. Prior to Closing, Seller, at its sole cost and expense, shall complete the installation of a new roof on those certain buildings located on the Real Property and more particularly known as “Building I” and “Building II.” At Closing, Seller shall assign to Buyer the roof warranty, provided that Buyer shall pay any charge or fee associated with the assignment of such warranty.
Sample 1
Seller Work 
Sample 1

Related to Seller Work

  • THE WORK The Work comprises the completed construction required by the Contract Documents and includes all labor necessary to produce such construction, and all materials and equipment incorporated or to be incorporated in such construction.

  • Production Work The Company may use Outside Entities to perform production work outside the plant and its environs provided the Company demonstrates that it is utilizing plant equipment to the maximum extent consistent with equipment capability and customer requirements and the Company is making necessary capital investments to remain competitive in the steel business and is in compliance with Article Eleven, Section B (Investment Commitment).

  • Work The definition of work, for overtime purposes only, includes:

  • Seller’s Deliverables At the Closing, Seller shall deliver to Buyer:

  • Project Completion Part 1 – Material Completion

  • Landlord’s Work (a) For purposes of this lease, "Landlord's Work" means, collectively, the alterations and improvements to the demised premises to be constructed and/or installed by Landlord in accordance with the terms and conditions of this lease, as more particularly described in Exhibit ________ attached to and hereby made a part of this lease. Landlord shall use commercially reasonable efforts to "Substantially Complete" the Landlord's Work not later than ________, 20________ (the "Substantial Completion Target Date"). For purposes of this lease, Landlord's Work shall be deemed to be "Substantially Complete" as of the date on which the general contractor or the architect employed by Landlord with respect to the construction and/or installation of Landlord's Work shall certify in writing to Landlord that: (i) Landlord's Work has been substantially completed in all material respects substantially in accordance with the approved plans and specifications therefor, if any; and (ii) a temporary or permanent certificate of occupancy has been issued by the governmental authority having jurisdiction with respect to Landlord's Work or the governmental authority having jurisdiction with respect to Landlord's Work has otherwise evidenced its approval of Landlord's Work. Landlord shall have no liability whatsoever to Tenant in the event that Landlord shall fail for any reason whatsoever to Substantially Complete Landlord's Work on or before the Substantial Completion Target Date (including, without limitation, for any damages that Tenant may suffer as a result thereof or in connection therewith); provided, however, in such event, Landlord shall use commercially reasonable efforts to Substantially Complete Landlord's Work as soon as possible thereafter. Landlord shall use commercially reasonable efforts to complete any portions or aspects of Landlord's Work which shall be incomplete as of the date of Substantial Completion of Landlord's Work as soon as possible thereafter. Notwithstanding anything to the contrary set forth elsewhere in this lease, Tenant hereby acknowledges and agrees that the construction and/or installation of Landlord's Work by Landlord shall not be deemed in any way to constitute a condition precedent to the occurrence of the Commencement Date (as such date is set forth in Paragraph 1.3 of this lease) or to the effectiveness of any of the agreements or obligations of Tenant set forth in this lease with respect to the demised premises (including, without limitation, the commencement of the obligation to pay Rent by Tenant as of the Commencement Date).

  • Tenant Improvements Subject to the terms and conditions hereof, Landlord agrees, at its cost and expense to complete a “turnkey” interior build-out (“Tenant Improvements”) of the Leased Premises in accordance with the conditions stated in the Work Letter attached hereto as Exhibit C and incorporated hereby pursuant to the Approved Final Plans to be finalized and approved in accordance with the Work Letter and upon approval attached thereto. Any changes or modifications to the Approved Final Plans thereafter must be done in writing and signed by both Tenant and Landlord in accordance with the Work Letter. So long as in accordance with Article 19 of this Lease, Tenant agrees that Landlord shall be entitled to select, in its reasonable discretion and acting in good faith, all architects, engineers, contractors and material suppliers necessary to furnish the labor and materials for the construction of the Tenant Improvements. Landlord shall be the sole contracting party with respect to the employment of contractors which perform the work necessary to construct the Tenant Improvements. Tenant shall not be entitled to access to the Leased Premises prior to the Date of Substantial Completion and Tenant shall not interfere with or impair in any material way the construction of the Tenant Improvements, and any such interference or impairment shall be included within a Tenant Delay as defined in the Work Letter and shall entitle Landlord to all remedies provided herein for breach of this Lease. Prior to the Possession Date, Tenant shall not enter into any contract for construction of any improvements within the Leased Premises with any person other than Landlord without Landlord's prior written consent. Tenant, at Tenant's expense, shall obtain and maintain any and all necessary permits and licenses to enable Tenant to conduct Tenant’s Permitted Use, and the failure of Tenant to obtain or maintain same shall not in any manner affect the Tenant’s obligations hereunder. Landlord shall be solely responsible, at its cost and expense, for obtaining all permits and approvals related to the Tenant Improvements.

  • Creative Work The Executive agrees that all creative work and work product, including but not limited to all technology, business management tools, processes, software, patents, trademarks, and copyrights developed by the Executive during the term of this Agreement, regardless of when or where such work or work product was produced, constitutes work made for hire, all rights of which are owned by the Employer. The Executive hereby assigns to the Employer all rights, title, and interest, whether by way of copyrights, trade secret, trademark, patent, or otherwise, in all such work or work product, regardless of whether the same is subject to protection by patent, trademark, or copyright laws.

  • Punchlist Upon completion of the Performance Tests and prior to Substantial Completion of a Subproject, Owner and Contractor shall inspect the Subproject, and Contractor shall prepare a proposed Punchlist of items identified as needing to be completed or corrected as a result of such inspection. Contractor shall promptly provide the proposed Punchlist to Owner for its review, together with an estimate of the time and cost necessary to complete or correct each Punchlist item. Contractor shall add to the proposed Punchlist any Punchlist items that are identified by Owner within ten (10) Days after Owner’s receipt of the proposed Punchlist from Contractor, and Contractor shall immediately initiate measures to complete or correct, as appropriate, any item on Contractor’s proposed Punchlist (including those items identified by Owner during Owner’s review) that are not of a Punchlist nature. Notwithstanding anything to the contrary in this Agreement, Contractor and Owner are not required as a condition of Substantial Completion of a Subproject to agree upon and identify every Punchlist item and include it on the Punchlist, but Contractor is required to complete as a condition of Substantial Completion of such Subproject that does not meet the definition of Punchlist as provided in Section 1.1. In the event of a dispute regarding whether a specific item of Work meets the definition of Punchlist under Section 1.1, the Parties shall resolve such dispute in accordance with Section 18.1A. Owner shall provide Contractor with access to the Work after Substantial Completion of a Subproject sufficient to enable Contractor to complete all Punchlist items, so long as such access does not unreasonably interfere with operation of a Subproject after Substantial Completion of the Subproject or the Existing Facility and subject to any reasonable security or safety requirements of Owner. Upon Contractor’s completion or correction of any items necessary to achieve Substantial Completion of a Subproject, as modified by any Owner additions, such Punchlist shall govern Contractor’s performance of the Punchlist items up to Final Completion. All Work on the Punchlist shall be completed by the date required for Final Completion, as specified in Section 5.3C, or Owner may, in addition to any other rights that it may have under this Agreement, complete such Punchlist Work at the expense of Contractor. In the event Owner elects to complete such Punchlist Work, Contractor shall pay Owner, within ten (10) Days after receipt of written notice from Owner, all reasonable costs and expenses incurred by Owner in performing such Punchlist Work, or, at Owner’s sole discretion, Owner may withhold or offset amounts owed to Contractor or collect on the Letter of Credit in accordance with Section 7.8 in the amount of such costs and expenses. Any Defective Work identified after agreement between the Parties of the Punchlist shall be corrected by Contractor as a Warranty item under Article 12.

  • At Completion the Buyer shall:

Time is Money Join Law Insider Premium to draft better contracts faster.