Specifications and Drawings for Construction Sample Clauses

Specifications and Drawings for Construction. (a) The Contractor shall keep on the work site a copy of the drawings and specifications and shall at all times give the Contracting Officer access thereto. Anything mentioned in the specifications and not shown on the drawings, or shown on the drawings and not mentioned in the specifications, shall be of like effect as if shown or mentioned in both. In case of difference between drawings and specifications, the specifications shall govern. In case of discrepancy in the figures, in the drawings, or in the specifications, the matter shall be requirements, the Contractor shall describe such variations in writing, separate from the drawings, at the time of submission. If the Architect approves any such variation and the Contracting Officer concurs, the Contracting Officer shall issue an appropriate modification to the contract, except that, if the variation is minor or does not involve a change in price or in time of performance, a modification need not be issued. (g) It shall be the responsibility of the Contractor to make timely requests of the PHA for such large scale and full size drawings, color schemes, and other additional information, not already in his possession, which shall be required in the planning and production of the work. Such requests may be submitted as the need arises, but each such request shall be filed in ample time to permit appropriate action to be taken by all parties involved so as to avoid delay. (h) The Contractor shall submit to the Contracting Officer for approval four copies (unless otherwise indicated) of all shop drawings as called for under the various headings of these specifications. Three sets (unless otherwise indicated) of all shop drawings, will be retained by the PHA and one set will be returned to the Contractor. As required by the Contracting Officer, the Contractor, upon completing the work under this contract, shall furnish a complete set of all shop drawings as finally approved. These drawings shall show all changes and revisions machinery and mechanical and other equipment. When required by this contract or by the Contracting Officer, the Contractor shall also obtain the Contracting Officer’s approval of the material or articles which the Contractor contemplates incorporating into the work. When requesting approval, the Contractor shall provide full information concerning the material or articles. Machinery, equipment, material, and articles that do not have the required approval shall be installed or used at t...
Sample 1Sample 2Sample 3See All (29)
AutoNDA by SimpleDocs
Specifications and Drawings for Construction. (a) The Contractor shall keep on the work site a copy of the drawings and specifications and shall at all times give the Contracting Officer access thereto. Anything mentioned in the specifications and not shown on the drawings, or shown on the drawings and not mentioned in the specifications, shall be of like effect as if shown or mentioned in both. In case of difference between drawings and specifications, the specifications shall govern. In case of discrepancy in the figures, in the drawings, or in the specifications, the matter shall be promptly make a determination in writing. Any adjustment by the Contractor without such a determination shall be at its own risk and expense. The Contracting Officer shall furnish from time to time such detailed drawings and other information as considered necessary, unless otherwise provided. (b) Wherever in the specifications or upon the drawings the words “directed”, “required”, “ordered”, “designated”, “prescribed”, or words of like import are used, it shall be understood that the “direction”, “requirement”, “order”, “designation”, or “prescription”, of the Contracting Officer is intended and similarly the words “approved”, “acceptable”, “satisfactory”, or words of like import shall mean “approved by”, or “acceptable to”, or “satisfactory to” the Contracting Officer, unless otherwise expressly stated. (c) Where “as shown” “as indicated”, “as detailed”, or words of similar import are used, it shall be understood that the reference is made to the drawings accompanying this contract unless stated otherwise. The word “provided” as used herein shall be understood to mean “provide complete in place” that is “furnished and installed”.
Sample 1Sample 2Sample 3See All (24)
Specifications and Drawings for Construction. (a) Seller shall be furnished the number of drawings and specifications specified in Division One at no cost. (b) Seller shall keep on the work site a copy of the drawings and specifications and shall at all times give Company access thereto. Anything mentioned in the specifications and not shown on the drawings, or shown on the drawings and not mentioned in the specifications, shall be of like effect as if shown or mentioned in both. In case of difference between drawings and specifications, the specifications shall govern. Within the specifications, Division One (the "Special Conditions") shall govern. In case of discrepancy in the figures, in the drawings, or in the remainder of the specifications, the matter shall be promptly submitted to the Construction Engineer and the Subcontract Administrator, who shall promptly make a determination in writing. Any adjustment by Seller without such a determination shall be at its own risk and expense. Company shall furnish from time to time such detailed drawings and other information as considered necessary, unless otherwise provided. (1) The drawings and specifications incorporated into this Agreement are intended to include everything requisite and (2) Omissions from the drawings or specifications or the misdescription of details of work that are manifestly necessary to carry out the intent of the drawings and specifications, or that are customarily performed, shall not relieve Seller from performing such omitted or misdescribed details of the work, but they shall be performed as if fully and correctly set forth and described in the drawings and specifications. (3) The specifications and drawings may identify and list quantities of items to be furnished and installed by Seller. These identifications may be incomplete and the quantities are estimates only. Seller is responsible for furnishing the items and quantities manifestly necessary to carry out the intent of the drawings and specifications. (4) The drawings furnished by Company are, in general, to scale. Scales shown on a microfilmed reproduced drawing change in proportion to the reduction of the drawing from original size. Figured dimensions shall always be followed and the drawings not scaled. (5) Prior to fabricating any item (structural steel, piping, ductwork, etc.) Seller shall field-verify all dimensions critical to the installation. Any discrepancies between existing or new conditions and the drawings shall be reported to Company for resolution. (6...
Sample 1Sample 2See All (7)
Specifications and Drawings for Construction. (MAR 2019)
Sample 1Sample 2Sample 3See All (4)
Specifications and Drawings for Construction. (MAR 2019) The requirements of the clause entitled “Specifications and Drawings for Construction” at FAR 52.236-21, are supplemented as follows:
Sample 1Sample 2
Specifications and Drawings for Construction. The Donor shall keep on the work site a copy of the drawings and specifications and shall at all times give GSA and CBP access thereto. Anything mentioned in the specifications and not shown on the drawings, or shown on the drawings and not mentioned in the specifications, shall be of like effect as if shown or mentioned in both. In case of differences between drawings and specifications, the specifications shall govern. In case of discrepancies in the figures, in the drawings, or in the specifications, the matter shall be promptly submitted to GSA and CBP, who shall promptly make a determination in writing. Any adjustment by the Donor without such a determination shall be at its own risk and expense. If this project requires shop drawings, such as drawings on the mechanical and electrical work, such drawings must be submitted to the GSA Team Manager and CBP Project Manager for approval prior to work.
Sample 1
Specifications and Drawings for Construction. A. The Contractor will keep on the Work site a copy of the drawings and specifications and will at all times give the City access thereto. Anything mentioned in the Work Specifications and not shown on the drawings, or shown on the drawings and not mentioned in the Work Specifications, will be of like effect as if shown or mentioned in both. In case of difference between drawings and specifications, the Work Specifications will govern. In case of discrepancy in the figures, in the drawings, or in the specifications, the matter will be promptly submitted to the City, who will promptly make a determination in writing which will be binding on the Contractor. Any adjustment by the Contractor without City’s written authorization will be at its own risk and expense. The City will furnish from time to time such detailed drawings and other information as considered necessary, unless otherwise provided. B. If the Contract Documents require Shop Drawings, the Contractor will coordinate all such drawings, and review them for accuracy, completeness, and compliance with other requirements and will indicate its approval thereon as evidence of such coordination and review. Shop drawings submitted to the City without evidence of the Contractor's approval may be returned for resubmission. The City will indicate an approval or disapproval of the Shop Drawings and if not approved as submitted will indicate the Owner's reasons therefore. Any Work done before such approval will be at the Contractor's risk. Approval by the City will not relieve the Contractor from responsibility for any errors or omissions in such drawings, nor from responsibility for complying with the requirements under the Contract Documents. C. It will be the responsibility of the Contractor to make timely requests for such large scale and full size drawings, color schemes, and other additional information, not already in his possession, which will be required in the planning and production of the Work. Such requests may be submitted as the need arises, but each such request will be filed in ample time to permit appropriate action to be taken by all Parties involved so as to avoid delay. D. After approval of the shop drawings, the Contractor will submit three (3) copies (unless otherwise indicated) of all Shop Drawings as called for under the various headings of the specifications. One (1) set (unless otherwise indicated) of all Shop Drawings will be retained by the Owner, one will be retained by the City a...
Sample 1
AutoNDA by SimpleDocs
Specifications and Drawings for Construction. In accordance with FAR Clause 52.236-21 “Specifications and Drawings for Construction” (APR 1984), the Subcontractor shall keep a copy of the drawings and specifications on the work site and shall give project engineer access thereto. Anything mentioned in the specifications and not shown on the drawings or shown in the drawings and not mentioned in the specifications, shall be of like effect as if shown or mentioned in both. In the case of difference between drawings and specifications, the specifications shall govern. In the case of discrepancy in the figures, in the drawings, or in the specifications, the specifications shall govern. In the case of a discrepancy in the figures, the matter shall be promptly submitted to project engineer who shall promptly make a determination in writing. Any adjustment by the Subcontractor without such a determination shall be at its own risk and expense. Chemonics shall furnish, from time to time, clarifications of detailed drawings and other information as considered necessary.
Sample 1

Related to Specifications and Drawings for Construction

  • ADDITIONAL CONSTRUCTIONS The Promoter undertakes that it has no right to make additions or to put up additional structure(s) anywhere in the Project after the building plan has been approved by the competent authority(ies) except for as provided in the Act.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Selection of Architect/Construction Drawings Landlord shall retain, on behalf of Tenant, FPBA Architects (the “Architect”) to prepare the “Construction Drawings,” as that term is defined in this Section 3.1. Landlord shall retain, on behalf of Tenant, engineering consultants and/or design-build consultants designated by Landlord (the “Engineers”) to prepare all plans and engineering working drawings relating to the structural, mechanical, electrical, plumbing and HYAC work of the Improvements and any relevant components of the Landlord Work. The plans and drawings to be prepared by Architect and the Engineers hereunder shall be known collectively as the “Construction Drawings.” All Construction Drawings shall comply with the drawing format and specifications as determined by Landlord, and shall be subject to Landlord’s approval as more particularly set forth in Sections 3.2 and 3.3, below. Notwithstanding Landlord’s retention of the Architect and Engineers, Tenant shall be responsible for, and shall fully cooperate and coordinate in good faith with Landlord, the Architect and the Engineers to supply all of the necessary information within Tenant’s possession to allow the Architect and the Engineers to initially prepare and then complete, the Construction Drawings. Landlord hereby agrees (at no cost to Landlord) to cooperate, on a commercially reasonable basis, with Tenant to assist Tenant in the preparation of the Construction Drawings. Landlord’s review of the Construction Drawings applicable to the Improvements (as opposed to Landlord Work) and as set forth in this Section 3, shall be for its sole purpose and shall not imply Landlord’s review of the same, or obligate Landlord to review the same, for quality, design, Code compliance or other like matters. Accordingly, notwithstanding that any Improvement-related portions of such Construction Drawings are reviewed by Landlord, and notwithstanding any advice or assistance which may be rendered to Tenant by Landlord, Landlord shall have no liability whatsoever in connection therewith and shall not be responsible for any omissions or errors contained in such portions of the Construction Drawings, and Tenant’s waiver and indemnity set forth in this Lease shall specifically apply to such portions of the Construction Drawings.

  • Contract Construction 6.27.1 The parties acknowledge that each party and its counsel have reviewed this CONTRACT and that the normal rule of construction to the effect that any ambiguities are to be resolved against the drafting party shall not be employed in the interpretation of this CONTRACT or any amendment or exhibits hereto.

  • Design and Construction In complying with the requirements of the specification both with respect to arrangement and detail, design is to conform to the best current engineering practice. Each of the several parts of the material is to be of the maker’s standard design provided that this design is in general accordance with the specification. The essence of design should be simplicity and reliability in order to give long continuous service with high economy and low maintenance cost. Particular attention should be paid to internal and external access in order to facilitate inspection, cleaning and maintenance. The design dimensions and materials of all parts are to be such that they will not suffer damage as a result of stresses under the most severe conditions. Fully detailed specifications of the several parts of the material are to be submitted describing particularly the materials to be used. The materials used in the construction of the material are to be of the highest quality and selected particularly to meet the duties required of them. Mechanisms are to be constructed to avoid sticking due to rust or corrosion. Workmanship and general finish are to be of the highest class throughout. All similar parts of the material are to be interchangeable. All equipment is to operate without undue vibration and with the least possible amount of noise and is not to cause a nuisance. All equipment is to be designed to minimize the risk of fire and any damage, which may be caused in the event of fire. The equipment is also to be designed to prevent ingress of all vermin, accidental contact with live parts and to minimize the ingress of dust and dirt. The use of materials, which may be liable to attack by termites or other insects, is to be avoided.

  • General Construction 20.2.1. Binding Nature.............................................. 20.2.2. Entire Agreement............................................ 20.2.3. Governing Law............................................... 20.2.4. Indulgences Not Waivers..................................... 20.2.5. Titles Not to Affect Interpretation......................... 20.2.6.

  • Project Construction The Contractor agrees to provide continuous on-site supervision on each Job Order, while progress on the project is being accomplished. The Contractor’s Project Manager will ensure: 1. Coordination and providing supervision to all Subcontractor and workers; 2. Posting of the prevailing wage scale; 3. Maintaining a copy of the Contractors safety program manual made available to all construction personnel; 4. Conducting weekly on-site safety meetings; 5. Completing the daily labor and construction progress log on a daily basis and submit copies to the County on a daily basis. Copies of the previous day’s reports must be submitted by 9:00AM of the following day. a. Daily labor log is to include a listing of Subcontractor(s) and a count of workers by trade providing services for the day. b. Construction progress log is to include a narrative of the Work provided by trade(s). Narrative agrees to include the various areas of the jobsite where Work was performed and any problems or conditions that were encountered. c. In the event the Contractor fails to provide a daily log and/or construction progress log, the County may impose damages against the Contractor in the amount of fifty dollars ($50.00) for each log and deduct from the Contractor’s payment request, for each day the Contractor does not provide the documentation. 6. County may suspend Contractor operations if no Contractor Superintendent is observed. All delays caused by the suspension will be the responsibility of the Contractor. No time extension or claims for cost(s) associated with the suspension will be granted by the County.

  • Review and Construction of Documents Each Party herein expressly represents and warrants to all other Parties hereto that (a) before executing this Agreement, said Party has fully informed itself of the terms, contents, conditions and effects of this Agreement; (b) said Party has relied solely and completely upon its own judgment in executing this Agreement; (c) said Party has had the opportunity to seek and has obtained the advice of its own legal, tax and business advisors before executing this Agreement; (d) said Party has acted voluntarily and of its own free will in executing this Agreement; and (e) this Agreement is the result of arm’s length negotiations conducted by and among the Parties and their respective counsel.

  • Neutral Construction Neither party hereto may rely on any drafts of this Agreement in any interpretation of the Agreement. Both parties to this Agreement have reviewed this Agreement and have participated in its drafting and, accordingly, neither party shall attempt to invoke the normal rule of construction to the effect that ambiguities are to be resolved against the drafting party in any interpretation of this Agreement.

  • Commencement and Completion of Construction Subject to Unavoidable Delays, Developer shall cause construction of the Minimum Improvements to be undertaken and completed: (i) by no later than June 1, 2020; or (ii) by such other date as the parties shall mutually agree upon in writing. Time lost as a result of Unavoidable Delays shall be added to extend this date by a number of days equal to the number of days lost as a result of Unavoidable Delays. All work with respect to the Minimum Improvements shall be in conformity with the Construction Plans approved by the building official or any amendments thereto as may be approved by the building official. Developer agrees that it shall permit designated representatives of the City, upon reasonable notice (which does not have to be written), to enter upon the Development Property during the construction of the Minimum Improvements to inspect such construction and the progress thereof.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!