Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Tenant Delay If the Substantial Completion of the Tenant Improvement Work is delayed (a “Tenant Delay”) as a result of (a) any failure of Tenant to approve the Construction Pricing Proposal pursuant to Section 2.6 above on or before Tenant’s Approval Deadline; (b) Tenant’s failure to timely approve any matter requiring Tenant’s approval; (c) any breach by Tenant of this Work Letter or the Lease; (d) any request by Tenant for a revision to the Approved Construction Drawings (except to the extent such delay results from any failure of Landlord to perform its obligations under Section 2.7 above); (e) Tenant’s requirement for materials, components, finishes or improvements that are not available in a commercially reasonable time given the anticipated date of Substantial Completion of the Tenant Improvement Work as set forth in this Agreement; (f) any change to the base, shell or core of the Premises or Building required by the Approved Construction Drawings; or (g) any other act or omission of Tenant or any of its agents, employees or representatives, then, notwithstanding any contrary provision of this Agreement, and regardless of when the Tenant Improvement Work is actually Substantially Completed, the Tenant Improvement Work shall be deemed to be Substantially Completed on the date on which the Tenant Improvement Work would have been Substantially Completed if no such Tenant Delay had occurred.
Force Majeure In no event shall the Trustee be responsible or liable for any failure or delay in the performance of its obligations hereunder arising out of or caused by, directly or indirectly, forces beyond its control, including, without limitation, strikes, work stoppages, accidents, acts of war or terrorism, civil or military disturbances, nuclear or natural catastrophes or acts of God, and interruptions, loss or malfunctions of utilities, communications or computer (software and hardware) services; it being understood that the Trustee shall use reasonable efforts which are consistent with accepted practices in the banking industry to resume performance as soon as practicable under the circumstances.
Landlord Delay Landlord’s (a) failure to comply with any time requirements expressly set forth in Paragraph 2.d. above with respect to Landlord’s obligation to provide notice of approval or disapproval of the Space Plan, Working Drawings or Change Orders, or (b) Landlord’s unreasonable interference with the completion of Tenant Improvements, including any failure or refusal of Landlord or Landlord’s agents or contractors to permit Tenant, its agents or contractors, access to and use of the Building or any Building facilities or services (including hoists, elevators, and loading docks) which access or use is reasonably required for the orderly and continuous performance of the work necessary to complete Tenant Improvements, are referred to collectively herein as “Landlord Delay” (provided that no Landlord Delay as described in clause (b) above will be deemed to have occurred unless and until Tenant has notified Landlord of the event which Tenant claims constitutes a Landlord Delay and Landlord has failed to cure such event within five (5) Business Days thereafter). Tenant will use commercially reasonable efforts to mitigate its damages and/or construction delays in the event of an alleged Landlord Delay. Notwithstanding anything to the contrary in this Paragraph 2, if and to the extent Tenant reasonably incurs a net increased cost (taking into account any cost saving Landlord might have facilitated by its actions, including any Landlord Delay) of design or construction of the Tenant Improvements as a direct result of any Landlord Delay (as reasonably evidenced by Tenant, with supporting documentation), Landlord will be responsible for such reasonable increased costs and Landlord’s Allowance will be increased by the amount of such reasonable increased cost. Further, when determining whether a particular Landlord Delay delayed Substantial Completion of the Tenant Improvements, the subject Landlord Delay shall be offset by any action or response by Landlord that achieved a reduction in Tenant’s construction schedule (each day saved in Tenant’s construction schedule being a “Schedule Saving Day”) and any aggregate Landlord Delay as described in this Paragraph 2.f. shall first be offset against, and reduced on a day-for-day basis by, the aggregate number of Schedule Saving Days. In the event of a disagreement between Landlord and Tenant as to whether a Landlord Delay has occurred and/or as to the application of this grammatical paragraph, either party may submit the issue to the dispute resolution procedure set forth in Paragraph 2.j. below. This Paragraph 2.f. is inapplicable to delays in Delivery, whether caused by Landlord, Landlord’s Contractor or otherwise (such delays being expressly covered by Paragraph 2.a. above) and this Paragraph 2.f. only applies to delays in the commencement or Substantial Completion of the Tenant Improvements following Delivery.
Force Majeur Except with respect to obligations to make payments hereunder, neither party shall be deemed in default hereunder, nor shall it hold the other party responsible for, any cessation, interruption or delay in the performance of its obligations hereunder due to causes beyond its reasonable control including, but not limited to: earthquake, flood, fire, storm or other natural disaster, act of God, labor controversy or threat thereof, civil disturbance or commotion, disruption of the public markets, war or armed conflict or the inability to obtain sufficient material, supplies, labor, transportation, power or other essential commodity or service required in the conduct of its business, including internet access, or any change in or the adoption of any law, ordinance, rule, regulation, order, judgment or decree.
MAJEURE A party is not liable for failure to perform the party’s obligations if such failure is as a result of acts of God (including fire, flood, earthquake, storm, hurricane or other natural disaster), pandemic, war, invasion, act of foreign enemies, hostilities (regardless of whether war is declared), civil war, rebellion, revolution, insurrection, military or usurped power or confiscation, terrorist activities, nationalization, decrees of a court, tribunal or governmental authority, government sanction, blockage, embargo, labor dispute, strike, or lockout. If a party asserts any force majeure as an excuse for failure to perform, such non-performing party must prove that it took reasonable steps to minimize delay or damages caused by foreseeable events and that the other Party was timely notified of the likelihood or actual occurrence of a force majeure event. In the event of non-performance and/or termination pursuant to this Section 8.16, notwithstanding any other provision of this Agreement, the Xxxxxxx Money shall be returned to the Operating Partnership in full.
Force Majeure Event After giving effect to any applicable provision, disruption fallback or remedy specified in, or pursuant to, the relevant Confirmation or elsewhere in this Agreement, by reason of force majeure or act of state occurring after a Transaction is entered into, on any day:—
Unavoidable Delay Except for the monetary obligations of Tenant under this Lease, neither party shall be chargeable with, liable for, or responsible to the other for anything or in any amount for any Unavoidable Delay and any Unavoidable Delay shall not be deemed a breach of or default in the performance of this Lease, it being specifically agreed that any time limit provision contained in this Lease (other than the scheduled expiration of the Term) shall be extended for the same period of time lost by Unavoidable Delay.
No Force Majeure Event There shall not have been any delay, error, failure or interruption in the conduct of the business of the Acquiror Company, or any loss, injury, delay, damage, distress, or other casualty, due to force majeure including but not limited to (a) acts of God; (b) fire or explosion; (c) war, acts of terrorism or other civil unrest; or (d) national emergency.
