A-E SCOPE OF SERVICES Sample Clauses

A-E SCOPE OF SERVICES. A-E shall diligently perform in a competent and professional manner those tasks and duties set forth in Appendix 1 - Scope of Services, attached hereto, in the time set forth in the Article titled Time for Performance below. The attached Appendix 1 – Scope of Services is hereby incorporated into this Agreement by reference. COUNTY, at its discretion, may reduce, limit or amend the Scope of Services and the corresponding costs upon written notification to A-E as described in the Article titled Changes in Scope of Services of this Agreement.
Sample 1Sample 2Sample 3See All (7)
AutoNDA by SimpleDocs
A-E SCOPE OF SERVICES. Initiation of A-E services is under the control and supervision of JWA. A-E services are subject to the Airport’s approval before services are initiated, through the issuance of a Job Order. A-E services shall meet all federal, state and county applicable codes, State of California criteria for the physically handicapped, as well as applicable criteria and requirements of the State Department of Industrial safety and the Federal Aviation Administration, (FAA) for Airport Construction. A-E shall perform in a competent and professional manner those tasks and duties as set forth in the Scope of Services attached hereto as, “Scope of Services”- Attachment B.
Sample 1Sample 2Sample 3See All (5)
A-E SCOPE OF SERVICES. A. The A-E shall perform in a competent and professional manner those tasks and duties set forth in the attached Scope of Services for Project No. 0310-1900- OCENG (“Project”) which is incorporated into this Agreement as Appendix 1. B. The A-E shall comply with all applicable COUNTY procedures, guidelines, and rules pertaining to the management of architectural and engineering, construction management, and construction contracts, including, but not limited to the COUNTY’s Contract Policy Manual. The A-E shall fully familiarize itself with all contracts they are tasked with managing. A-E shall enforce all contractual requirements. C. The A-E is not authorized to amend any COUNTY contracts which it is assigned to manage. COUNTY contracts may only be amended by written change order first approved by JWA. D. The A-E’s duties shall include the review, verification and recommendation for payment of pay requests submitted by all architectural, engineering, design and construction contractors within the Scope of Services. The A-E shall review and verify that any such pay requests are accurate and in compliance with the applicable contract and COUNTY and JWA requirements. A-E’s recommendation of a pay request shall represent that A-E has reviewed the work, products or services for that pay request, and that the work, products or services for that pay request have been completed in a good and workmanlike manner and in compliance with the contract. The A-E shall promptly inform JWA, in writing, of any discovered work, products or services which have not been performed in compliance with the contract. The A-E shall recommend the appropriate payment for each pay request based on the A- E’s review. E. The A-E’s verification of pay requests shall include all documents necessary to support and justify the A-E‘s recommendations for payment. Such documentation shall include updated cost-loaded schedules and/or other applicable schedule formats as defined in contractors’ agreements with COUNTY, independent cost estimates, photos of completed work, delivery tickets, and purchase orders. A-E is responsible for assuring that project files contain all documentation necessary to justify payments prior to recommending payment. Electronic copies of documents shall be maintained in JWA’s electronic Project Document Management System, Oracle Primavera Unifier (“Unifier”), with the appropriate system security applied. F. The A-E shall make recommendations on any requests for extension...
Sample 1Sample 2Sample 3See All (4)
A-E SCOPE OF SERVICES. A-E Scope of Services for the above-referenced project (the "Project") shall be in accordance with the "Architect-Engineer Guide" as issued by Xxxx Xxxxx Airport and incorporated into this Agreement by reference, receipt of which is hereby acknowledged by A-E. A-E shall diligently perform in a competent and professional manner those tasks and duties set forth in Appendix 1 - Scope of Services, attached hereto, in the time set forth in Section 4 below. The attached Appendix 1 – Scope of Services is hereby incorporated into this Agreement by reference. COUNTY, at its discretion, may reduce, limit or amend the Scope of Services and the corresponding costs upon written notification to A-E as described in Section 8 of this Agreement.
Sample 1Sample 2
A-E SCOPE OF SERVICES. The A-E shall diligently perform on an on-call, as-needed basis and in a competent and professional manner those tasks and duties set forth in Task Orders based on Appendix 1 - Scope of Services, attached hereto, in the time set forth in the Article titled “Time for Performance” below. The attached Appendix 1 – Scope of Services is hereby incorporated into this Agreement by reference. Task Orders will detail specific services, deliverables, schedules and budgets. COUNTY, at its discretion, may reduce, limit or amend the Scope of Services and the corresponding costs upon written notification to A-E as described in the Article titled “Changes in Scope of Services” of this Agreement.
Sample 1Sample 2
A-E SCOPE OF SERVICES. A-E services for the above referenced project (the "Project") shall be in accordance with the latest "Architect-Engineer Guide" and CAD Drafting Standards as issued and to be provided by JWA and incorporated into this Agreement by reference.
Sample 1
A-E SCOPE OF SERVICES. Initiation of A-E services is under the control and supervision of JWA. A-E services are subject to the Airport’s approval before services are initiated, through the issuance of a Job Order. A-E services shall meet all federal, state and county applicable codes, State of California criteria for the physically handicapped, as well as applicable criteria and requirements of the State Department of Industrial safety and the Federal Aviation Administration, (FAA) for Airport Construction. A-E shall perform in a competent and professional manner those tasks and A-E shall perform in a competent and professional manner those tasks and duties as set forth in the Scope of Services attached hereto as, “Scope of Services”- Attachment B.
Sample 1
AutoNDA by SimpleDocs

Related to A-E SCOPE OF SERVICES

  • Attachment A, Scope of Services The scope of services is amended as follows:

  • Scope of Services The specific scope of work for each job shall be determined in advance and in writing between TIPS Member, Member’s design professionals and Vendor. It is permitted for the TIPS Member to provide a general scope description, but the awarded vendor should provide a written scope of work, and if applicable, according to the TIPS Member’s design Professional as part of the proposal. Once the scope of the job is agreed to, the TIPS Member will issue a PO and/or an Agreement or Contract with the Job Order Contract Proposal referenced or as an attachment along with bond and any other special provisions agreed by the TIPS Member. If special terms and conditions other than those covered within this solicitation and awarded Agreements are required, they will be attached to the PO and/or an Agreement or Contract and shall take precedence over those in this base TIPS Vendor Agreement.

  • General Scope of Services Contractor promises and agrees to furnish all labor, materials, tools, equipment, services, and incidental and customary work necessary to fully and adequately supply professional services, as more particularly described in Exhibit B (Statement of Work and Misc. Documents) attached hereto and incorporated herein by reference (collectively “Services”). All Services shall be subject to, and performed in accordance with, this Contract, the exhibits attached hereto and incorporated herein by reference, and all applicable local, state and federal laws, rules and regulations.

  • Scope of Service Interconnection Service shall be provided to the Interconnection Customer at the Point of Interconnection (a), in the case of interconnection of the Customer Facility of a Generation Interconnection Customer, up to the Maximum Facility Output, and (b), in the case of interconnection of the Customer Facility of a Transmission Interconnection Customer, up to the Nominal Rated Capability. The location of the Point of Interconnection shall be mutually agreed by the Interconnected Entities, provided, however, that if the Interconnected Entities are unable to agree on the Point of Interconnection, the Transmission Provider shall determine the Point of Interconnection, provided that Transmission Provider shall not select a Point of Interconnection that would impose excessive costs on either of the Interconnected Entities and shall take material system reliability considerations into account in such selection. Specifications for the Customer Facility and the location of the Point of Interconnection shall be set forth in an appendix to the Interconnection Service Agreement and shall conform to those stated in the Facilities Study.

  • SCOPE OF SERVICES/CASE HANDLING A. Upon execution by GPM, attorneys are retained to provide legal services for the purpose of seeking damages and other relief in the Litigation. Client provides authorization to seek appointment as Lead Plaintiff in the class action, while the Attorneys will seek to be appointed Class Counsel. If this occurs, the Litigation will be prosecuted as a class action. B. If you obtain access to non-public information during the pendency of the Litigation, you must not engage in transactions in securities. C. Attorneys are authorized to prosecute the Litigation. The appointed Lead Plaintiffs will monitor, review and participate with counsel in the prosecution of the Litigation. The Attorneys shall consult with the appointed Lead Plaintiffs concerning all major substantive matters related to the Litigation, including, but not limited to, the complaint, dispositive motions and settlement. Because of potential differences of opinion between Clients concerning, among other things, strategy, goals and objectives of the Litigation, the Attorneys shall consult with the appointed Lead Plaintiffs as to the courses of action to pursue. The Client agrees to abide by the decisions of the appointed Lead Plaintiffs, which shall be final and binding on all Clients. D. GPM is given the authority to opt the Client out of any class action proceeding relating to the claims authorized herein and/or pursue the Client claim individually in a group action, if the Client is not appointed Lead Plaintiff and GPM is not appointed Class Counsel. E. The Attorneys shall provide sufficient resources, including attorney time and capital for payment of costs and expenses, to vigorously prosecute the Litigation. F. Any recovery from defendants that the Attorneys are responsible for will be divided among class members based on the recognized loss by each class member as calculated by a damage allocation plan which will be prepared by a financial expert or consultant, provided to the appointed Lead Plaintiffs, be subject to the Court's approval and will account for such factors as size of securities ownership, date of purchase, date of sale and continued holdings, if any. Under the rules governing class action litigation, while the Lead Plaintiffs recover according to the same formula as other class members, the Court may approve, upon application therefore, reimbursement of the Lead Plaintiffs’ reasonable costs and expenses directly related to the representation of the class. Examples are lost wages and travel expenses associated with testifying in the action.

  • Supply of Services 7.1 Supplier shall provide the Services to Purchaser in accordance with the Order in all material respects using reasonable care and skill. 7.2 Supplier shall use reasonable endeavours to meet any performance dates for the Services specified in the Order but any dates shall be estimates only and time shall not be of the essence for the performance of the Services. 7.3 Supplier shall have the right to make any changes to the Services which are necessary to comply with any applicable law or safety requirements or which do not materially affect the nature or quality of the Services. 7.4 Purchaser shall: (a) ensure that the terms of Order are complete and (if submitted by Purchaser) the service specification are complete and accurate; (b) co-operate with Supplier in all matters relating to the Services; (c) provide Supplier, its employees, agents, consultants and subcontractors with access to Purchaser’s premises, machinery and other facilities as reasonably required by Supplier to provide the Services; and (d) provide Supplier with such information and materials as Supplier may reasonably require to supply the Services, and ensure that such information is accurate in all material respects. 7.5 If Supplier’s performance of any of its obligations in respect of the Services is prevented or delayed by an any act or omission by Purchaser or failure by Purchaser to performs its obligations (“Purchaser Default”) Supplier shall without limiting its other rights or remedies have the right to suspend performance of the Services until Purchaser remedied Purchaser Default and relieves Supplier from its obligations to the extent the Customer Default prevents or delays Supplier’s performance. Purchaser shall indemnify Supplier against all liabilities costs, losses and expenses which Supplier may incur by reason of Purchaser Default. 7.6 Where the Services consist of any experimental or developmental work, the results supplied or recommendations made under the Services are given in good faith within the limitations of the data available, but no warranty, expressed or implied, is given as to the ability of Supplier to achieve a specific outcome, nor the accuracy of results obtained. 7.7 Any claims by Purchaser which is based on defect in the Services shall be notified to Supplier within twenty-one (21) days of the services being performed and promptly after discovery of defect or failure. The sole and exclusive remedy of Purchaser for such defect hereunder shall be the re-performance or re- fund, at Supplier’s option, of any defective or non-conforming Services.

  • Service Scope The following Services are covered by this Agreement; o Manned telephone support o Monitored email support o Remote assistance using Remote Desktop and a Virtual Private Network where available o Planned or Emergency Onsite assistance (extra costs apply) o Monthly system health check

  • Schedule of Services Consultant shall perform the Services in a prompt and timely manner in accordance with the Schedule of Services set forth in Exhibit "B" attached hereto and incorporated herein by reference. Consultant represents that it has the professional and technical personnel required to perform the Services expeditiously. Upon request of City, Consultant shall provide a more detailed schedule of anticipated performance to meet the Schedule of Services.

  • Scope of Services and Term Subject to the provisions for early termination as set forth herein, the Contractor agrees that it will perform the Services enumerated in the scope of services attached hereto as Exhibit A and incorporated herein by reference (the “Scope of Services”) for a term of five years (5) beginning , 2023 through , 2028 (the “Term”). The Authority in its sole discretion may extend the Agreement for two (2) additional one-year periods, for a potential maximum term of *** (**) years. The Authority will provide any such renewal notice in writing at least thirty (30) days prior to expiration of the Agreement. The maximum payment for the Term is set forth in Section II(a). All work shall be diligently performed by the Contractor in an economical, expeditious and professional manner.

  • COMMERCIAL REUSE OF SERVICES The member or user herein agrees not to replicate, duplicate, copy, trade, sell, resell nor exploit for any commercial reason any part, use of, or access to 's sites.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!