Administration of Work Sample Clauses

Administration of Work. (a) After acceptance of bids, Landlord shall administer the construction of Tenant Improvements in accordance with the Working Drawings; provided, however, that Landlord shall not be required to install any Tenant Improvements that do not conform to the approved Working Drawings, or conflict with elements of the approved Working Drawings, or do not comply with applicable regulations, laws, ordinances, codes and rules; such conformity being the obligation of Tenant. (b) All Tenant Improvements shall be constructed by the general contractor or subcontractors selected for the work with the exception of floor coverings, wall finishes, mill work security systems (which shall not be connected to the life safety systems of the Building) and work stations which may be constructed, installed or provided by Tenant subject to the limitation hereinafter set forth. Furthermore, Tenant shall furnish and install all telephone equipment and wiring and office equipment and wiring, all of which shall be constructed, installed or provided by Tenant subject to the limitations hereinafter set forth. (c) All materials or equipment furnished and installed by Tenant shall be installed in a manner that conforms with the construction schedule established by Landlord and Tenant, and the work of installation shall be handled in such a manner as to maintain harmonious labor relations and as not to interfere with or delay the work of Landlord's contractors. No portion of the work to be performed by Landlord's contractor shall be dependent upon completion of any work of construction or installation to be performed by Tenant, and the work to be performed by Landlord's contractor shall have priority over any work to be performed by Tenant. Tenant's contractors, subcontractors and materialmen shall be subject to prior approval by Landlord and shall be subject to the administrative supervision of Landlord or Landlord's general contractor and rules of the site. Contractors, subcontractors and materialmen engaged by Tenant shall take the necessary steps to insure, so far as may be possible, the progress of the work without interruption on account of strikes, work stoppage or similar causes for delay. In the event that Tenant's contractors or subcontractors do not promptly cause any pickets to be withdrawn and all other disruptions to the operations of the Building promptly to cease, or in the event that Landlord notifies Tenant that Landlord has in good faith concluded that picketing or other...
Sample 1Sample 2See All (7)
AutoNDA by SimpleDocs
Administration of Work. (a) After acceptance of bids, Tenant shall cause the Contractor to construct and install the Tenant Improvements in strict accordance with the Working Drawings. Tenant shall not authorize or permit the Contractor to install any Tenant Improvements that do not conform to the approved Working Drawings, or conflict with elements of the approved Working Drawings, or do not comply with applicable Laws, such conformity being the obligation of Tenant. (b) All Tenant Improvements shall be constructed by the Contractor or subcontractors selected for the work. Tenant and Contractor shall have the right to select the subcontractors for the work; provided, however, that Landlord shall have the right to approve in writing in its reasonable discretion the mechanical, electrical, plumbing and data/telephone subcontractors. (c) The Contractor and all subcontractors and materialmen shall be subject to the rules of the site. Contractors, subcontractors and materialmen engaged by Tenant shall take the necessary steps to insure, so far as may be possible, the progress of the work without interruption on account of strikes, work stoppage or similar causes for delay. In the event that Tenant’s contractors or subcontractors do not promptly cause any pickets to be withdrawn and all other disruptions to the operations of the Building promptly to cease, or in the event that Landlord notifies Tenant that Landlord has in good faith concluded that picketing or other disruptive activities are an imminent threat, Tenant shall immediately cause the withdrawal from the job of all its contractors, subcontractors or materialmen involved in the dispute. (d) Tenant shall require that each of its contractors, subcontractors and materialmen maintain commercial general liability insurance in an amount of not less than Two Million Dollars ($2,000,000.00) per occurrence on a combined single limit basis and all worker’s compensation insurance required by law. (e) Landlord shall provide access and entry to the Leased Premises to Tenant following the mutual execution and delivery of the Lease by the parties hereto to allow Tenant to proceed with the construction and installation of the Tenant Improvements. Upon and following any entry into the Leased Premises by Tenant prior to the commencement of its Term, Tenant shall perform all of the obligations of Tenant applicable under the Lease during the Term (except the obligation to pay Base Rent and Basic Operating Cost), including, without limitation, o...
Sample 1
Administration of Work. (a) Tenant’s project manager will administer the construction of the TI Work in accordance with the final, approved and permitted Working Drawings. (b) Installation of office furniture, telecommunications equipment and wiring and cabling shall not be considered part of the TI Work, and shall be separately designed, constructed, installed or provided by Tenant in accordance with the Working Drawings. Connection of installed work stations to the Building’s electrical system shall be a part of the TI Work.
Sample 1
Administration of Work 
Sample 1

Related to Administration of Work

  • Location of Work The Executive shall be based in the United States in West Orange, New Jersey. However, the Executive agrees to undertake whatever domestic and worldwide travel is required by the Company. The Executive shall not be required or permitted to relocate without the mutual, written consent of the Executive and the Company.

  • Coordination of Work Licensee shall be responsible for coordination of its Equipment installation work to avoid any interference with existing utilities, substructures, facilities and/or SFMTA transit operations. Licensee shall be the City's point of contact for all Equipment installation and except in case of emergency, all communications concerning Equipment installation shall be through Licensee's field representatives.

  • PROTECTION OF WORK 12.1 Subcontractor shall effectually secure and protect the work done hereunder and assume full responsibility for the condition thereof until final acceptance by the OWNER and Contractor. Subcontractor further agrees to provide such protection as is necessary to protect the work and the workmen of Contractor, the OWNER, and other subcontractors from its operations. 12.2 Subcontractor shall be liable for any loss or damage to any work in place or to any equipment and materials on the job site caused by Subcontractor or its agents, employees or guests.

  • CORRECTION OF WORK 13.2.1 The Contractor shall be responsible for correcting all Work which the Architect has found to be defective or which fails to conform to the Contract Documents whether observed be- fore or after Substantial Completion and whether or not fabricated, installed or completed. The Contractor shall bear all costs of correcting such rejected Work, including compensation for the Architect's and the State’s additional services made necessary thereby. 13.2.2 If, within one year after the Date of Substantial Completion of the Work or designated portion thereof or within one year after acceptance by the State of designated equipment or within such longer period of time as may be prescribed by law or by the terms of any applicable special warranty required by the Contract Documents, any of the Work is found to be defective or not in accordance with the Contract Documents, the Contractor shall correct it promptly after receipt of a written notice from the State to do so unless the State has previously given the Contractor a written acceptance of such condition. This obligation shall survive termination of the Contract. The State shall give such notice promptly after discovery of the condition. 13.2.3 The Contractor shall remove from the site all portions of the Work which are defective or non-conforming and which have not been corrected under Subparagraphs 4.5.1, 13.2.1 and 13.2.4 If the Contractor fails to correct defective or nonconforming Work as provided in Subparagraphs 4.5.1, 13.2.1 and 13.2.2, the State may correct it in accordance with Paragraph 13.2.5 If the Contractor does not proceed with the correction of such defective or non- conforming Work within a reasonable time fixed by written notice from the Architect, the State may remove it and may store the materials or equipment at the expense of the Contractor. If the Contractor does not pay the cost of such removal and storage within ten days thereafter, the State may upon ten additional days written notice sell such Work at auction or at private sale and shall account for the net proceeds thereof, after deducting all the costs that should have been borne by the Contractor, including compensation for the Architect's and the State’s additional services and expenses made necessary thereby. If such proceeds of sale do not cover all costs which the Contractor should have borne, the difference shall be charged to the Contractor and an appropriate Change Order shall be issued. If the payments then or thereafter due the Contractor are not sufficient to cover such amount, the Contractor shall pay the difference to the State. 13.2.6 The Contractor shall bear the cost of making good all work of the State or separate contractors destroyed or damaged by such correction or removal. 13.2.7 Nothing contained in this Paragraph 13.2 shall be construed to establish a period of limitation with respect to any other obligation which the Contractor might have under the

  • Prosecution of Work FIRST PARTY will employ a sufficient staff to prosecute the work diligently and continuously and will complete the work in accordance with the schedule of work approved by the CITY. (See Exhibit "A," Scope of Services).

  • NO CESSATION OF WORK 6.01 Neither the Union nor any employee shall take part in or call or encourage any strike, sit-down, slow-down, or any suspension of work against the Company which shall in any way affect the operations of the Company; nor shall the Company engage in any lockout at its Plants or Mines in the Sudbury District.

  • Rejection of Work Using the Notice of Non-Conforming Work procedures outlined in the General Conditions, the Design Professional shall reject work that does not comply with the requirements of the Contract Documents or that does not comply with the applicable laws and codes. The Design Professional shall have authority to order testing of the Work, as is provided in the Contract Documents or as otherwise required in its judgment, whether such work is fabricated, installed, or completed.

  • Inspection of Work It is FIRST PARTY's obligation to make the work product available for CITY's inspections and periodic reviews upon request by CITY.

  • Completion of Work The Contractor agrees to complete the work on, or before October 29, 2021.

  • Continuation of Work Pending the resolution of any dispute or claim pursuant to this Article 11, the Parties agree that performance of all obligations will be pursued diligently.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!