Approval by Landlord. Tenant’s Plans and any revisions thereof shall be subject to Landlord’s approval, which approval or disapproval:
(i) shall not be unreasonably withheld, provided however, that Landlord may disapprove Tenant’s Plans in its sole and absolute discretion if they (a) adversely affect the structural integrity of the Building, including applicable floor loading capacity; (b) adversely affect any of the Building Systems (as defined below), the Common Areas or any other tenant space (whether or not currently occupied); (c) fail to fully comply with Laws, (d) affect the exterior appearance of the Building; (e) provide for improvements which do not meet or exceed the Building Standards; or (f) involve any installation on the roof, or otherwise affect the roof, roof membrane or any warranties regarding either. Building Systems collectively shall mean the structural, electrical, mechanical (including, without limitation, heating, ventilating and air conditioning), plumbing, fire and life-safety (including, without limitation, fire protection system and any fire alarm), communication, utility, gas (if any), and security (if any) systems in the Building.
(ii) shall not be delayed beyond ten (10) business days with respect to initial submissions and major change orders (those which impact Building Systems or any other item listed in subpart (i) of Section 3.2 above) and beyond five (5) business days with respect to required revisions and any other change orders. If Landlord disapproves of any of Tenant’s Plans, Landlord shall advise Tenant of what Landlord disapproves in reasonable detail. After being so advised by Landlord, Tenant shall submit a redesign, incorporating the revisions required by Landlord, for Landlord’s approval. The approval procedure shall be repeated as necessary until Tenant’s Plans are ultimately approved. Approval by Landlord shall not be deemed to be a representation or warranty by Landlord with respect to the safety, adequacy, correctness, efficiency or compliance with Laws of Tenant’s Plans. Tenant shall be fully and solely responsible for the safety, adequacy, correctness and efficiency of Tenant’s Plans and for the compliance of Tenant’s Plans with any and all Laws.
Approval by Landlord. Landlord’s approval of, or requirements concerning, Lines and Equipment, the plans, specifications or drawings related thereto or Tenant’s contractors, subcontractors, or service provider, shall not be deemed a warranty as to the adequacy thereof, and Landlord hereby disclaims any responsibility or liability for the same. Landlord further disclaims all responsibility for the condition, security or utility of Lines and Equipment, and makes no representation regarding the suitability of any such Lines or Equipment for Tenant’s intended use or the adequacy or fitness of the Building Systems for any such Lines or Equipment.
Approval by Landlord. No approval by Landlord of any insurer shall be construed to be a representation, certification or warranty of its solvency and no approval by Landlord as to the amount, type or form of any insurance shall be construed to be a representation, certification or warranty of its sufficiency.
Approval by Landlord. Tenant's Plans shall be subject to Landlord's approval, which approval shall not be unreasonably withheld or delayed. Landlord shall be entitled to withhold approval if the proposed plans and specifications
(i) interfere with the structural integrity of the Buildings, (ii) overload the utility systems of the Buildings, (iii) violate any applicable laws or regulations, (iv) materially affect the architectural integrity of the Buildings, or (v) affect the future marketability of the Buildings. If Landlord disapproves of any of Tenant's Plans, Landlord shall advise Tenant in reasonable detail of required revisions and the reasons therefor. After being so advised by Landlord, Tenant shall promptly submit a redesign, incorporating the revisions required by Landlord, for Landlord's approval. If Tenant has reason to dispute any Landlord disapproval, then the parties shall meet within 5 days and attempt to resolve the dispute. If the Parties are unable to resolve their differences as to Tenant's Preliminary Plans within 5 days after meeting, then either party may initiate an arbitration procedure by notifying the other Party of the need to submit their disagreements to binding and final arbitration by a mutually acceptable arbitrator with at least ten (10) years commercial office design experience. If the parties are unable to agree on the arbitrator within a period of ten (10) days of notice, then either party may request resolution by a single arbitrator before the American Arbitration Association, as set forth at the end of Lease Section 21.
Approval by Landlord. Tenant shall, at its sole cost and expense, provide to Landlord for its prior written approval, detailed plans and specifications for the installation by Tenant within and outside the Premises of all communications switching equipment and associated ancillary equipment used in Tenant’s business operations, including the Generator (defined below), the Transmission Equipment (defined below), HVAC equipment, chillers and condensing units, and all conduits installed by or for Tenant as described below (collectively, “Tenant’s Equipment”).
Approval by Landlord. This Sublease is conditional upon written --------------------- consent being obtained from the Landlord. In the event the Landlord does not give its consent, either the undersigned parties may, at its option, rescind its signature and this Sublease shall thereafter be of no force or effect.
Approval by Landlord. Tenant’s Plans shall be subject to Landlord’s approval, which approval shall not be unreasonably withheld. As promptly as reasonably possible, but in no event later than ten (10) days after Tenant’s submission of completed Tenant’s Plans, Landlord shall notify Tenant of its approval or disapproval thereof. If Landlord disapproves Tenant’s Plans, or any portion thereof, Landlord shall notify of the revisions which Landlord reasonably requires in order to obtain Landlord’s approval. As promptly as reasonably possible thereafter, but in no event later than ten (10) days after Landlord’s notice, Tenant shall submit to Landlord plans and specifications incorporating the revisions required by Landlord. Said revisions shall be subject to Landlord’s approval, which shall not be unreasonably withheld or delayed and shall be given within the same period as Landlord’s original approval; if Landlord disapproves revised Tenant’s Plans, Landlord shall notify Tenant of the further revisions Landlord reasonably requires in order to obtain Landlord’s approval. The foregoing process shall be repeated until Landlord finally approves all of Tenant’s Plans required for the Tenant Improvements of the Premises, so that Landlord and Tenant have an agreed upon a set of final plans and specifications. The final plans and specifications approved by Landlord shall be referred to as the “Final Plans.” Approval by Landlord shall not be deemed to be a representation by Landlord as to the adequacy or correctness of the design of the Tenant Improvements.
Approval by Landlord. Tenant’s Plans shall be subject to Landlord’s approval, which approval shall not be unreasonably conditioned, withheld or delayed. Landlord agrees to approve or disapprove Tenant’s Plans within ten (10) business days after receipt thereof.
Approval by Landlord. Tenant's Plans shall be subject to Landlord's reasonable approval. Landlord shall have ten (10) business days following receipt of Tenant's Plans to approve or disapprove the submissions by Tenant. If Landlord reasonably disapproves of any of Tenant's Plans, Landlord shall advise Tenant of the required revisions concurrently with such disapproval. After being so advised by Landlord, Tenant shall promptly submit a redesign, addressing the revisions required by Landlord, for Landlord's reasonable approval. Landlord shall then have five (5) business days to approve or disapprove any re-submittal of Tenant's plans, and failure to respond within such 5-business day period shall be deemed Landlord's approval of such re-submitted plans and specifications. If Tenant's Plans have not been approved within thirty (30) days from the date of this Lease, the parties agree to promptly meet in good faith to attempt to reach agreement regarding Tenant's Plans. Approval by Landlord shall not be deemed to be a representation or warranty by Landlord with respect to the safety, adequacy, correctness, efficiency or compliance with law of Tenant's Plans.
Approval by Landlord. Tenant Plans shall be subject to Landlord's prior written approval. Landlord agrees that it will not unreasonably withhold its approval of the Tenant Plans, provided, however, that Landlord will have sole and absolute discretion to approve or disapprove any element(s) of the Tenant Plans that will (i) be visible from the exterior of the Demised Premises or Building, or (ii) involve or may affect any structural or exterior element of the Building or any area or element of any Common Facility or delay completion of the Demised Premises or Building, or (iii) increase the cost of construction or of insurance or taxes on the Building, or (iv) require unusual expense to readapt the Demised Premises or Building to normal use on lease termination or increase the cost of construction or of insurance or taxes on the Building, unless Tenant first gives assurance reasonably acceptable to Landlord for payment of such Tenant Plans, changes or modifications by Landlord will not constitute approval of any delays caused by Tenant or in implementing the work shown on such plans and shall not be deemed a waiver of any rights or remedies that may arise as a result of such delays.
