Authority of Engineer. During prosecution of the work, the Engineer will answer all questions that may arise as to the quantity, quality, and acceptability of materials furnished and work performed; rate of progress of the work; interpretation of the plans and Specifications; acceptable fulfillment of the Contract by the Contractor; disputes and mutual rights between contractors; and compensation. The Engineer has the authority to suspend the work wholly or in part if the Contractor has created conditions that are unsafe or fails to correct conditions that are unsafe for workers or the general public or fails to carry out the provisions of the Contract. The Engineer may also suspend work for such periods as he may deem necessary because of catastrophic or extraordinary weather in accordance with the definition of such in Section 108.04, conditions considered unsuitable for prosecution of the work, or any other condition or reason deemed to be in the public interest. The Engineer may issue written clarifications or directives that either enhance or alter Contract Documents. The Engineer may order such work as may be necessary to complete the Contract satisfactorily.
Authority of Engineer. The Engineer shall decide any and all questions which may arise as to (1) the quality and acceptability of materials furnished and Work performed; (2) the manner of performance and rate of progress of the Work; (3) the interpretation of the Plans and Specifications; (4) the acceptable fulfillment of the Contract on the part of Contractor; and (5) the amount and quantity of the several kinds of Work performed and materials furnished under the Contract.
Authority of Engineer. 3.1 The County authorizes the County Engineer, and the City authorizes the City Engineer to administer and carry out the provisions of this contract on its behalf and to take such necessary actions to complete the Project as contemplated by this Agreement. Such authority will not include approval of agreements or obligations upon the county that would otherwise require County or City approval, except where specifically enumerated within this Agreement.
Authority of Engineer. The Engineer is authorized to reject or condemn all work or material, which does not conform to this Agreement. If any tools or equipment are unsafe, defective or inadequate for carrying out the Work, the Engineer may require the removal of such equipment and Contractor shall, without delay, substitute satisfactory equipment therefore.
Authority of Engineer. IN - CHARGE Save in so far as it is legally or physically impossible, the contractor shall execute complete and maintain the works in strict accordance with the contract under the directions and to the entire satisfaction of the Engineer - in - charge and shall comply with and adhere strictly to the Engineer - in - charge instructions and directions on any matter (Whether mentioned in the contract or not) pertaining to this work. The Engineer - in - charge shall decide all questions which may arise as to quality and acceptability of materials furnished and work executed, manner of executions, rate of progress of work, interpretations of the plans and specifications and acceptability of fulfillment of the contract on the part of contractor. He shall determine the amount and quality of work performed and materials furnished and his decision and measurements shall be final. In all such matters and in any technical questions which may arise touching the contract, his decision shall be binding on the contractor. The engineer in charge shall have power to enforce such decisions and orders if the contractor fails to carry out them promptly. If the contractor fails to execute the work order by the engineer in charge, the engineer in charge may give notice to the contractor specifying a reasonable period therein and on the expiry of that period proceed to execute such work as may be deemed necessary and recover the cost thereof from the contractor.
Authority of Engineer. All Work shall be subject to the review of the Engineer. He shall decide all questions as to interpretation of the plans, specifications, and questions of mutual rights between Contractors. He shall decide on an acceptable rate of progress, on the manner of performance, and on the acceptable fulfillment of the Contract Documents. The Engineer shall have the right to determine the points at which the Contractor may begin work and the order in which the Work shall be prosecuted to the best interest of the Owner and within the intent of the terms of the Contract Documents.
Authority of Engineer. 1.05.02—Plans, Working Drawings and Shop Drawings 1.05.03—Conformity with Plans and Specifications
Authority of Engineer. All work shall be subject to the review of the Engineer. He shall decide all questions as to interpretation of the plans and specifications, and questions of mutual or respective rights of the Contractor and other Department contractors. The Engineer shall decide on an acceptable rate of progress, on the manner of performance, and on what shall be deemed acceptable fulfillment of the Contract. The Engineer shall have the right to determine the points at which the Contractor may begin work and the order in which the work shall be prosecuted in the best interests of the State within the intent of the terms in the Contract. If a Project-related dispute arises between the Contractor and Department personnel assigned to the Project, and if those parties prove unable to resolve it, the Contractor may submit a detailed written description of the dispute to the Department’s Assistant District Engineer administering the Contract. It must be understood, though, that at no time may the Contractor, because of its disagreement with the Engineer, either disregard the orders of the Engineer or halt Project construction. If the Contractor cannot resolve a Project work or pricing dispute with the Engineer, the Contractor’s proper remedy is a claim under CGS Section 4-61. A Contractor that disregards the orders of the Engineer with regard to the prosecution of Project work, or who refuses to continue Project work because of a disagreement with the Engineer, may be subject to termination of its Contract.
Authority of Engineer. 7.1 The Engineer shall decide any and all questions which may arise as to the quality and acceptability of the materials furnished, the quality of the Work performed, the general manner of performance and the rate of progress of the Work. He shall decide all questions which may arise as to the interpretation of the Contract Drawings, General Conditions, Supplemental Conditions, and Specifications, all questions as to acceptable fulfillment of the Agreement, all disputes and mutual rights by the Contractors, if there be more than one Contractor on the Work, and, with the approval of the Owner, all questions as to compensation. The decision of the Engineer shall be final and he shall have executive authority to make effective such decisions and to request the Contractor to carry out all orders promptly. Drawings and Shop Drawings:
Authority of Engineer. In these Specifications or in other contract documents where these Specifications govern, the term Engineer shall mean authorized personnel from the City of Lindsay. The work shall be done under the direction of the Engineer, and the materials used shall comply with these Specifications and to be to the satisfaction of the Engineer. The Engineer shall have authority to stop the work, authority to reject any work or materials which do not conform to the contract documents, to direct the application of forces to such portion of the work as in his judgment is required, to order the force increased or diminished, to direct the sequence of the work and to decide questions which arise in the execution of the work. All work under this contract shall be done under the direction and to the satisfaction of the Engineer.
