Award and Execution of Contract. 30-1 CONSIDERATION OF PROPOSALS. After the proposals are publicly opened and read, they will be compared on the basis of price. If there is a discrepancy between the price written in words and the price written in numbers, the price written in words shall govern. Until the award of a contract is made, the Owner reserves the right to reject a bidder's proposal for any of the following reasons:
Award and Execution of Contract. The award of the contract, if it be awarded, will be to the lowest responsive, responsible bidder, determined as provided on the Proposal Form, whose proposal complies with all the requirements prescribed. Such award, if made, will be made within the shortest time feasible. If the lowest responsible bidder refuses or fails to execute the contract, the County may consider the next lowest bidder to be the lowest responsible bidder, or may rebid the Project. The periods of time specified above within which the award of contract may be made shall be subject to extension for such further period as may be agreed upon in writing between the County and the bidder concerned. All bids will be compared on the basis of the quantities and unit prices, or lump sums, as shown on the Bid Proposal. Before award, the bidders may be required to furnish acceptable evidence of adequate capability, equipment, and financial resources to adequately perform the job. Bidders found not to be so qualified may have their bids rejected. Any or all bids may be rejected if there is sound, documented reason. If reasonable cause exists to believe collusion exists among bidders, or that prices are unbalanced between bid items, any or all proposals may be rejected.
Award and Execution of Contract. 1-03.1 Consideration of Bids After opening and reading proposals, the Contracting Agency will check them for correctness of extensions of the prices per unit and the total price. If a discrepancy exists between the price per unit and the extended amount of any bid item, the price per unit will control. The total of extensions, corrected where necessary, will be used by the Contracting Agency for award purposes and to fix the amount of the contract bond. The right is reserved by the Contracting Agency to waive informalities in the bidding, accept a proposal of the lowest responsible bidder, reject any or all bids, republish the call for bids, revise or cancel the work, or require the work to be done in another way if the best interest of the Contracting Agency is served. A bidder who wishes to claim error after the bids have been publicly opened and read as required by RCW 47.28.090 shall promptly notify the Contracting Agency that an error occurred. The bidder shall submit a notarized affidavit or declaration under penalty of perjury signed by the bidder and accompanied by the work sheets used in the preparation of the bid, requesting relief from the responsibilities of award. The affidavit or declaration shall describe the specific error(s) and certify that the work sheets are the ones used in preparing the bid. The affidavit or declaration shall be submitted no later than 5:00 p.m. on the first business day after bid opening or the claim will not be considered. The Contracting Agency will review the affidavit or declaration and the certified work sheets to determine the validity of the claimed error and if the error is of the kind for which the law allows relief from forfeiture of the bid deposit. If the Contracting Agency concurs in the claim of error and determines that the error is of the kind which allows relief from forfeiture, the bidder will be relieved of responsibility and the bid deposit of the bidder will be returned. If the Contracting Agency does not concur in the error or determines that the error is not the kind for which the law allows relief, the Contracting Agency may award the contract and if the bidder refuses to execute the contract, the bidder’s bid deposit shall be forfeited as required by RCW 47.28.100.
Award and Execution of Contract. City of Paris will provide written notice to the successful Proponent, to advise that the proposal has been accepted. The successful firm shall be required to enter into a contract with City of Paris.
Award and Execution of Contract. LCRA shall evaluate the proposals in accordance with the RFP requirements. The contract will be awarded to the best evaluated Offeror. Contracts shall be neither considered awarded nor binding until such time that both parties have executed the Contract. LCRA shall not be liable for any delays prior to the award or execution of Contract.
Award and Execution of Contract. Awarding of bids shall be in accordance with Section B, "Instructions to Bidders," in the Contract Documents.
Award and Execution of Contract. The bidder's attention is directed to the provisions in Section 3, "Award and Execution of Contract," of the Standard Specifications and these special provisions for the requirements and conditions concerning award and execution of contract. Bid protests are to be delivered to the following address: 000 X. 00xx Xxxxxx, Xx Xxxxxx, Xx, 00000 The award of the contract, if it be awarded, will be to the lowest responsible bidder whose proposal complies with all the requirements prescribed. The contract shall be executed by the successful bidder and shall be returned, together with the contract bonds, to the Agency so that it is received within 10 days, not including Saturdays, Sundays and legal holidays, after the bidder has received the contract for execution. Failure to do so shall be just cause for forfeiture of the proposal guaranty. The executed contract documents shall be delivered to the following address: 000 X. 00xx Xxxxxx, Xx Xxxxxx, Xx, 00000
Award and Execution of Contract. A. Award of contract, if made, will be in accordance with the IFB to a responsible Bidder submitting a bid compliant with all the requirements of the IFB and any addenda thereto (including any administrative or technical requirements), except for such immaterial defects as may be waived by the Court.
Award and Execution of Contract. Except as provided herein to the contrary, the respective rights and remedies of the parties to this Contract shall be cumulative and in addition to any rights and remedies not specified in this Contract. It is understood that there are no oral or written agreements or representations between the parties hereto affecting this Contract, and that this Contract supersedes any and all prior negotiations, arrangements, representations, and understandings between the parties. No provision of this Contract may be amended except by an agreement in writing signed by City. This Contract, including exhibits and attachments attached hereto, signed by City and Contractor, constitutes the entire agreement between the parties. This Contract shall be in full force and effect only after it has been awarded by the City Council of Tempe, Arizona. Contractor shall execute the Contract and all exhibits and attachments thereto, counterparts permitted, within ten (10) calendar days after being given formal notice of City Council’s award of the Contract. Contractor’s failure to execute this Contract and to file satisfactory contract bonds and insurance certificates as provided herein within ten (10) calendar days after being given formal notice of Contract award shall result in immediate cancellation of the award.
Award and Execution of Contract. Contract shall commence upon an initial work order. Multiple work orders will be issued during contract period. Each work order will contain 1) begin start date, 2) specific work to be performed, and 3) allotted working days for completion. Working days for a mowing cycle are based on an average production rate of 60 acres per day. CRP is required to provide adequate equipment and resources to achieve this production rate. The estimated number of working days for a Mowing and Litter Cycle is 32 working days. The estimated number of working days for Litter Cycle is 14 working days. A new work order shall not be issued until the current work order is completed. Reference Item 8, Prosecution and Progress, 6. Failure to Complete Work on Time with respect to liquidated damages.