Contractor’s Notice of Delay Sample Clauses

Contractor’s Notice of Delay. 16.1.1. In addition to the requirements indicated in this subsection, Contractor shall notify the District pursuant to the claims provisions in these General Conditions of any anticipated delay and its cause. 16.1.2. Contractor shall, within FIVE (5) calendar days of any delay impacting the critical path in completing the Work, notify District in writing of the causes of the delay including documentation and facts explaining the delay.
AutoNDA by SimpleDocs
Contractor’s Notice of Delay. 15.1.1. In addition to the requirements indicated in this subsection, Contractor shall submit any request for an adjustment of the Contract Price or the Contract Time through the Change Order provisions in this Exhibit D. 15.1.2. Contractor shall, within FIVE (5) Days of any delay impacting the critical path in completing the Work, notify District in writing of the causes of the delay including documentation and facts explaining the delay. 15.1.3. Any request by Contractor for an adjustment of the Contract Price or the Contract Time for a delay shall be submitted in accordance with the provisions in the Contract Documents governing changes in Work. When requesting time, requests must be submitted with full justification and documentation. Such justification must be based on the official Construction Schedule as updated at the time of occurrence of the delay or execution of Work related to any changes to the Scope of Work.
Contractor’s Notice of Delay. In addition to the requirements indicated in this subsection, Contractor shall notify the AOC of any anticipated delay and its cause. 1. Contractor shall, within seven (7) calendar days of any delay impacting the critical path in completing the Work, notify AOC in writing of the causes of the delay including documentation and facts explaining the delay. 2. In the event the Contractor requests an extension of Contract Time for a delay in this notice, that request shall be submitted in accordance with the provisions in the Contract Documents governing changes in Work. When requesting time, requests must be submitted with full justification and documentation. If the Contractor fails to submit justification, it waives its right to a time extension at a later date. Such justification must be based on the official Construction Schedule as updated at the time of occurrence of the delay or execution of Work related to any changes to the Scope of Work. 3. Any claim for delay must include the following information as support, without limitation: (a) The duration of the activity relating to the changes in the Work and the resources (manpower, equipment, material, etc.) required to perform the activities within the stated duration. 4. AOC shall review the facts and extent of any noticed delay and shall grant Contract Time extension(s) of time for completing Work when, in the AOC’s judgment, the findings of fact justify an extension. 5. Any extension granted by the AOC shall be based on the Master Project Schedule as updated at the time of occurrence of the delay or execution of work related to any changes to the scope of the Work. Extension(s) of time shall apply only to that portion of Work affected by delay, and shall not apply to other portions of Work not so affected. 6. An extension of time may only be granted if Contractor has timely submitted the Construction Schedule as required herein. 7. Following submission of a notice of delay, the AOC may determine whether the delay is to be considered: (a) Excusable and Compensable, Excusable, or Unexcused; (b) How long the delay continues; and (c) To what extent the prosecution and Completion of the Work might be delayed thereby.
Contractor’s Notice of Delay. 17.1.1. In addition to the requirements indicated in this subsection, Contractor must submit any request for an adjustment of the Contract Price or Contract Time through the Change Order provisions in these General Conditions. 17.1.2. Contractor must, within FIVE (5) Days of any delay impacting the critical path in completing the Work, notify Judicial Council in writing of the causes of the delay including documentation and facts explaining the delay. 17.1.3. Any request by Contractor for an adjustment of the Contract Price or the Contract Time for a delay must be submitted in accordance with the provisions in the Contract Documents governing Changes in Work. When requesting time, requests must be submitted with full justification and documentation. Such justification must be based on the official Construction Schedule as updated at the time of occurrence of the delay or execution of Work related to any changes to the scope of Work. 17.1.4. Any claim for delay must include the following information as support, without limitation: 17.1.4.1. The duration of the activity relating to the changes in the Work and the resources (manpower, equipment, material, etc.) required to perform the activities within the stated duration. 17.1.4.2. Specific logical ties to the Construction Schedule for the proposed changes and/or delay showing the activity(ies) in the Construction Schedule that are affected by the change and/or delay. Include a “fragnet” analysis for the portion of the schedule and the activities Contractor contends are impacted by the delay. 17.1.4.3. A recovery or updated Construction Schedule must be submitted. 17.1.5. Judicial Council will review the facts and extent of any noticed delay and may grant Contract Time extension(s) for Completion of the Work when, in Judicial Council’s judgment, the findings of fact justify an extension. 17.1.6. Contract Time extension(s) may be limited to only those portions of Work affected by delay and may not apply to other portions of Work not so affected, in the sole discretion of the Judicial Council. 17.1.7. There are three (3) types of delay: 17.1.7.1. Excusable and Compensable Delay; 17.1.7.2. Excusable Delay; and
Contractor’s Notice of Delay. In addition to the requirements indicated in this subsection, Contractor shall notify the District pursuant to the claims provisions in these General Conditions of any anticipated delay and its cause. Contractor shall, within FIVE (5) calendar days of any delay impacting the critical path in completing the Work, notify District in writing of the causes of the delay including documentation and facts explaining the delay. Any request by Contractor for an adjustment of the Contract Price or the Contract Time for a delay shall be submitted in accordance with the provisions in the Contract Documents governing changes in Work. When requesting time, requests must be submitted with full justification and documentation. Such justification must be based on the official Construction Schedule as updated at the time of occurrence of the delay or execution of Work related to any changes to the Scope of Work. Any claim for delay must include the following information as support, without limitation:

Related to Contractor’s Notice of Delay

  • Force Majeure, Notice of Delay, and No Damages for Delay The Contractor will not be responsible for delay resulting from its failure to perform if neither the fault nor the negligence of the Contractor or its employees or agents contributed to the delay and the delay is due directly to acts of God, wars, acts of public enemies, strikes, fires, floods, or other similar cause wholly beyond the Contractor’s control, or for any of the foregoing that affect subcontractors or suppliers if no alternate source of supply is available to the Contractor. In case of any delay the Contractor believes is excusable, the Contractor will notify the Department or Customer in writing of the delay or potential delay and describe the cause of the delay either (1) within 10 days after the cause that creates or will create the delay first arose, if the Contractor could reasonably foresee that a delay could occur as a result, or (2) if delay is not reasonably foreseeable, within five days after the date the Contractor first had reason to believe that a delay could result. The foregoing will constitute the Contractor’s sole remedy or excuse with respect to delay. Providing notice in strict accordance with this paragraph is a condition precedent to such remedy. No claim for damages will be asserted by the Contractor. The Contractor will not be entitled to an increase in the Contract price or payment of any kind from the Department or Customer for direct, indirect, consequential, impact or other costs, expenses or damages, including but not limited to costs of acceleration or inefficiency, arising because of delay, disruption, interference, or hindrance from any cause whatsoever. If performance is suspended or delayed, in whole or in part, due to any of the causes described in this paragraph, after the causes have ceased to exist the Contractor will perform at no increased cost, unless the Department or Customer determines, in its sole discretion, that the delay will significantly impair the value of the Contract to the State of Florida or to Customers, in which case the Department or Customer may (1) accept allocated performance or deliveries from the Contractor, provided that the Contractor grants preferential treatment to Customers with respect to commodities or contractual services subjected to allocation, or (2) purchase from other sources (without recourse to and by the Contractor for the related costs and expenses) to replace all or part of the commodity or contractual services that are the subject of the delay, which purchases may be deducted from the Contract quantity, or (3) terminate the Contract in whole or in part.

  • Notice of Force Majeure If performance is delayed as a result of Force Majeure, the affected party shall provide prompt Notice to the other party and shall be excused from default or delay in performance while such circumstances prevail so long as such party continues to use commercially reasonable efforts to recommence performance as soon as possible.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!