Contractor’s Standard of Performance Sample Clauses

Contractor’s Standard of Performance. Contractor shall carry out all its operations under this Agreement on a Turnkey basis. For purposes hereof the term “Turnkey basis” means Contractor shall furnish equipment, labor and perform services as herein provided, for a specified sum per well as per the program provided by Company and agreed by Contractor. Extra Works will be performed if required on a “Dayrate basis.”
AutoNDA by SimpleDocs
Contractor’s Standard of Performance. Contractor shall carry out all operations hereunder on a daywork basis. For purposes hereof the term “daywork basis” means Contractor shall furnish equipment, labor, and perform services as herein provided, for a specified sum per day under the direction and supervision of Operator (inclusive of any employee, agent, consultant or subcontractor engaged by Operator to direct drilling operations). When operating on a daywork basis, Contractor shall be fully paid at the applicable rates of payment and assumes only the obligations and liabilities stated herein. Except for such obligations and liabilities specifically assumed by Contractor, Operator shall be solely responsible and assumes liability for all consequences of operations by both parties while on a daywork basis, including results and all other risks or liabilities incurred in or incident to such operations, notwithstanding any breach of representation or warranty, either expressed or implied, or the negligence or fault of any degree or character of Contractor, Contractor’s Personnel, its subcontractors, consultants, agents or servants, including sole, concurrent or gross negligence, either active or passive, latent defects or unseaworthiness of any vessel or vessels, including the Drilling Unit (whether or not preexisting), and any liability based on any theory of tort, breach of contract, breach of duty (whether statutory, contractual or otherwise), regulatory or statutory liability, or strict liability, including defect or ruin of premises, either latent or patent.
Contractor’s Standard of Performance. While performing the Work, Contractor shall exercise the reasonable care and skill customarily exercised by reputable members of Contractor’s profession practicing in the Phoenix Metropolitan Area, and shall use reasonable diligence and best judgment while exercising its skill and expertise. Contractor shall be responsible for all errors and omissions Contractor commits in the performance of the Agreement and this Addendum that are a breach of this standard.
Contractor’s Standard of Performance. Except as provided in Appendix C, Contractor shall provide Workover Services on a daywork basis. For purposes hereof, the term "daywork basis" means Contractor shall furnish Workover Equipment, Contractor's Personnel and perform Workover Services as herein provided, for a specified sum per day under the general direction and supervision of Company.
Contractor’s Standard of Performance. A. Contractor and Contractor's Project Manager shall be responsible for performance in accordance with the Contract. The Contractor shall be solely responsible for implementation of all means, methods, techniques, sequences, and procedures for any required coordination under the Contract. The Contractor shall be solely responsible for the safety of its employees and third parties. B. Contractor’s services shall be performed in accordance with generally-accepted professional practices and principles and in a manner consistent with the level of care and skill ordinarily exercised by members of the profession currently practicing under similar conditions. All services shall be performed to the reasonable satisfaction of the Authority. The work of Contractor’s Subcontractors will be deemed to be the work of Contractor. C. Contractor shall be responsible for the professional quality, technical accuracy, completeness, and coordination of the Contract, it being understood that the Authority will be relying upon Contractor’s professional competency. D. The Contractor shall be bound by all determinations or orders and shall promptly obey and follow every order of the Project Manager, including the withdrawal or modification of any previous order and regardless of whether Contractor agrees with the Project Manager's determination or order. Orders shall be in writing unless not practicable, in which event any oral order must be confirmed in writing by the Project Manager as soon thereafter as practicable. E. Notwithstanding anything in the Contract to the contrary, it is understood by Contractor that the Scope of Work and Contract Drawings are provided by the Authority solely for the purpose of describing in general terms the performance required from the systems or equipment and do not in any way constitute a design by the Authority of such systems or equipment. It is further understood that the Authority makes no warranties whatsoever concerning such Scope of Work. It is the ultimate responsibility of Contractor to meet the performance requirements and other requirements of the Contract.
Contractor’s Standard of Performance. Contractor warrants that it will diligently and effectively perform all work to the satisfaction of BRETSA. BRETSA shall be the sole judge of the quality of performance. Contractor expressly agrees that excessive defects in the Services and Products, repeated failures of the Services or Products, or failures of the Services and Products to meet the specifications therefor, shall constitute a breach of this Agreement.
Contractor’s Standard of Performance. Contractor shall carry out all Work on a daywork basis. For purposes hereof, the term “daywork basis” means Contractor shall furnish equipment and labor and perform services as herein provided for a specified sum per day under the direction and supervision of Operator or any Operator Personnel engaged by Operator to direct drilling and other Well operations. When operating on a daywork basis, Contractor shall be fully paid at the applicable Rates of payment and assumes only the obligations and liabilities stated herein. Except for such
AutoNDA by SimpleDocs

Related to Contractor’s Standard of Performance

  • Standard of Performance Consultant represents and warrants that it has the qualifications, experience and facilities necessary to properly perform the services required under this Agreement in a thorough, competent and professional manner. Consultant shall at all times faithfully, competently and to the best of its ability, experience and talent, perform all services described herein. In meeting its obligations under this Agreement, Consultant shall employ, at a minimum, generally accepted standards and practices utilized by persons engaged in providing services similar to those required of Consultant under this Agreement.

  • Standards of Performance Provider must perform all Services required of it under this Agreement with that degree of skill, care, and diligence normally shown by a Provider performing services of a scope, purpose, and magnitude comparable with the nature of the Services to be provided under this Agreement. Provider acknowledges that, if in the course of providing Services hereunder, it is entrusted with or has access to valuable and confidential information and records of the Board, Provider agrees to be held to the standard of care of a fiduciary with respect to that information. Any review, approval, acceptance of Services or deliverables, or payment by the Board for any Services does not relieve Provider of its responsibility for the professional skill and care and technical accuracy of its Services and deliverables. This provision in no way limits the Board’s rights against Provider under this Agreement, at law or in equity. When and where applicable, all members of Provider’s staff must hold and maintain throughout the Term and any Renewal Term, valid certificates and/or licenses from the State of Illinois or such other relevant jurisdiction that authorize those individuals to perform the Services. Provider agrees to promptly furnish a copy of the license(s) of any and all direct service providers to the Board on request. Throughout the Term and any Renewal Term, Provider must maintain and use sufficient staff to assure the effective and efficient operation of its programs. Provider must cause its staff to devote such time, attention, skill, knowledge, and professional ability as necessary to effectively and efficiently fulfill Provider’s obligations under this Agreement.

  • Review of Performance The Board of Directors shall periodically review and evaluate the performance of Employee under this Employment Agreement with Employee.

  • Excuse of Performance Seller shall not be liable for delays in performance or for non-performance due to failure or interruption of computer or telecommunication systems, acts of God, war, riot, fire, terrorism, labor trouble, unavailability of materials or components, explosion, accident, compliance with governmental requests, laws, regulations, orders or actions, or other unforeseen circumstances or causes beyond Seller's reasonable control. In the event of such delay, the time for performance or delivery shall be extended by a period of time reasonably necessary to overcome the effect of the delay.

  • Acceptance of Employment; Standard of Performance The Subadviser accepts its employment as a discretionary series adviser of the Designated Series and agrees to use its best professional judgment to make investment decisions for the Designated Series in accordance with the provisions of this Agreement and as set forth in Schedule D attached hereto and made a part hereof.

  • Standard and Manner of Performance Contractor shall perform its obligations under this Agreement in accordance with the highest standards of care, skill and diligence in Contractor’s industry, trade, or profession. Not Exclusive. Contractor is not guaranteed any work except as expressly stated herein, and this Agreement does not create an exclusive contract for the Work.

  • Continuity of Performance In the event of a dispute between the Party and the State, each party will continue to perform its obligations under this Agreement during the resolution of the dispute until this Agreement is terminated in accordance with its terms.

  • Failure of Performance (Art. 44)

  • Commencement of Performance This Agreement is of no force and effect until signed by both parties and all JBE-required approvals are secured. Any commencement of performance prior to Agreement approval shall be at Contractor's own risk.

  • PERIOD OF PERFORMANCE The period of performance for this contract begins , and ends .

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!