Dispute Adjudication Board (DAB Sample Clauses

Dispute Adjudication Board (DAB. 24.2.1 A dispute/s if not settled through conciliation, shall be referred to DAB. The DAB shall consist of a panel of three Retired Railway Officers not below senior administrative grade (SAG). The DAB shall be formed within 90 days of signing of Contract Agreement. For this purpose, the Authority will maintain a panel of DAB members. The complete panel, which shall not be less than five members, shall be sent by Authority to the Contractor to nominate one member of the DAB from the panel as Contractor’s nominee within two weeks of receipt of the panel. On receipt of Contractor’s nominee, the Authority shall nominate one member from the same panel as Authority’s nominee for the DAB. Both above nominees shall jointly select presiding member of the DAB from the same panel. 24.2.2 The appointment of DAB shall be effectuated by way of a tri-partite agreement among the Authority, Contractor and the respective DAB members. The terms of the remuneration of each member shall be as fixed by Ministry of Railways from time to time. Each party shall be responsible for paying one-half of this remuneration. 24.2.3 If one or more of the members appointed refuses to act as DAB member, or is unable or unwilling to perform his functions as DAB member for any reason whatsoever or dies or in the opinion of the Authority fails to act without undue delay, the parties shall terminate the mandate of such DAB member and thereupon new DAB member shall be appointed in the same manner, as the outgoing DAB member had been appointed. 24.2.4 The appointment of any member may be terminated by mutual agreement of both Parties, but not by the Authority or the Contractor acting alone. Unless otherwise agreed by both the Parties, the appointment of the DAB (including each member) shall expire upon expiry of this Contract Agreement. 24.2.5 Before start of DAB proceedings, each DAB member shall give the following certificate to the Authority and the Contractor: 24.2.6 DAB proceedings shall be conducted as decided by the DAB. The DAB shall give its decision within 90 days of a Dispute referred to it by any of the Parties, duly recording the reasons before arriving at the decision. The DAB shall decide the issue within terms and conditions of the contract. This time limit shall be extendable subject to the Parties mutual agreement. 24.2.7 The DAB decision shall not be binding on both the Parties. In case any party is not satisfied by the decision of DAB, then the aggrieved party may approach Sta...
AutoNDA by SimpleDocs
Dispute Adjudication Board (DAB. This clause is applicable in the tender having advertised value more than Rs 50 Crore.

Related to Dispute Adjudication Board (DAB

  • Arbitration Board Where the parties agree to a Board of Arbitration, the party referring the grievance to arbitration shall also provide the name of that party’s nominee to the Board of Arbitration. Within ten (10) days thereafter, the other party shall answer by registered mail, indicating the name and address of its nominee to the Board of Arbitration. The selection of the Chair shall be in accordance with the list of arbitrators above.

  • Expenses of Arbitration Board ‌ Each party shall pay: (a) the fees and expenses of the nominee it appoints; and (b) one-half of the fees and expenses of the Chairperson.

  • Selection of Reviewing Party; Change in Control If there has not been a Change in Control, any Reviewing Party shall be selected by the Board of Directors, and if there has been such a Change in Control (other than a Change in Control which has been approved by a majority of the Company's Board of Directors who were directors immediately prior to such Change in Control), any Reviewing Party with respect to all matters thereafter arising concerning the rights of Indemnitee to indemnification of Expenses under this Agreement or any other agreement or under the Company's Certificate of Incorporation or Bylaws as now or hereafter in effect, or under any other applicable law, if desired by Indemnitee, shall be Independent Legal Counsel selected by Indemnitee and approved by the Company (which approval shall not be unreasonably withheld). Such counsel, among other things, shall render its written opinion to the Company and Indemnitee as to whether and to what extent Indemnitee would be entitled to be indemnified hereunder under applicable law and the Company agrees to abide by such opinion. The Company agrees to pay the reasonable fees of the Independent Legal Counsel referred to above and to indemnify fully such counsel against any and all expenses (including attorneys' fees), claims, liabilities and damages arising out of or relating to this Agreement or its engagement pursuant hereto. Notwithstanding any other provision of this Agreement, the Company shall not be required to pay Expenses of more than one Independent Legal Counsel in connection with all matters concerning a single Indemnitee, and such Independent Legal Counsel shall be the Independent Legal Counsel for any or all other Indemnitees unless (i) the employment of separate counsel by one or more Indemnitees has been previously authorized by the Company in writing, or (ii) an Indemnitee shall have provided to the Company a written statement that such Indemnitee has reasonably concluded that there may be a conflict of interest between such Indemnitee and the other Indemnitees with respect to the matters arising under this Agreement.

  • Arbitration Decision The arbitrator’s decision will be final and binding. The arbitrator shall issue a written arbitration decision revealing the essential findings and conclusions upon which the decision and/or award is based. A party’s right to appeal the decision is limited to grounds provided under applicable federal or state law.

  • Dispute Resolution Mandatory Arbitration Class Action Waiver SAMPLE (a) Claims Subject to Arbitration. Except as expressly provided below, the parties agree that to the fullest extent permitted by applicable law, any dispute arising out of or relating in any way to this Agreement or a similar prior agreement, the Property or the relationship between Resident and Owner or Manager (including matters occurring prior to the date of this Agreement and disputes also involving third parties) (collectively, “Claims”) will, at the election of either party, be resolved by arbitration, including any dispute about arbitrability, such as scope and enforceability.

  • Reviewing Party Notwithstanding the foregoing, (i) the obligations of the Company under Section l(a) shall be subject to the condition that the Reviewing Party (as described in Section 10(e) hereof) shall not have determined (in a written opinion, in any case in which the Independent Legal Counsel referred to in Section 1(c) hereof is involved) that Indemnitee would not be permitted to be indemnified under applicable law, and (ii) the obligation of the Company to make an advance payment of Expenses to Indemnitee pursuant to Section 2(a) (an "Expense Advance") shall be subject to the condition that, if, when and to the extent that the Reviewing Party determines that Indemnitee would not be permitted to be so indemnified under applicable law, the Company shall be entitled to be reimbursed by Indemnitee (who hereby agrees to reimburse the Company) for all such amounts theretofore paid; provided, however, that if Indemnitee has commenced or thereafter commences legal proceedings in a court of competent jurisdiction to secure a determination that Indemnitee should be indemnified under applicable law, any determination made by the Reviewing Party that Indemnitee would not be permitted to be indemnified under applicable law shall not be binding and Indemnitee shall not be required to reimburse the Company for any Expense Advance until a final judicial determination is made with respect thereto (as to which all rights of appeal therefrom have been exhausted or lapsed). Indemnitee’s obligation to reimburse the Company for any Expense Advance shall be unsecured and no interest shall be charged thereon. If there has not been a Change in Control (as defined in Section 10(c) hereof), the Reviewing Party shall be selected by the Board of Directors, and if there has been such a Change in Control (other than a Change in Control which has been approved by a majority of the Company’s Board of Directors who were directors immediately prior to such Change in Control), the Reviewing Party shall be the Independent Legal Counsel referred to in Section l(c) hereof. If there has been no determination by the Reviewing Party or if the Reviewing Party determines that Indemnitee substantively would not be permitted to be indemnified in whole or in part under applicable law, Indemnitee shall have the right to commence litigation seeking an initial determination by the court or challenging any such determination by the Reviewing Party or any aspect thereof, including the legal or factual bases therefor, and the Company hereby consents to service of process and to appear in any such proceeding. Any determination by the Reviewing Party otherwise shall be conclusive and binding on the Company and Indemnitee.

  • Arbitration Decisions Unless otherwise agreed by the Parties, the arbitrator(s) shall render a decision within ninety (90) Calendar Days of appointment and shall notify the Parties in writing of such decision and the reasons therefor. The arbitrator(s) shall be authorized only to interpret and apply the provisions of this LGIA and shall have no power to modify or change any provision of this Agreement in any manner. The decision of the arbitrator(s) shall be final and binding upon the Parties, and judgment on the award may be entered in any court having jurisdiction. The decision of the arbitrator(s) may be appealed solely on the grounds that the conduct of the arbitrator(s), or the decision itself, violated the standards set forth in the Federal Arbitration Act or the Administrative Dispute Resolution Act. The final decision of the arbitrator(s) must also be filed with FERC if it affects jurisdictional rates, terms and conditions of service, Interconnection Facilities, or Network Upgrades.

  • Determination by the Reviewing Party If the Company reasonably believes that it is not obligated under this Agreement to indemnify the Indemnitee, the Company shall, within 10 days after the Indemnitee’s written request for an advancement or reimbursement of Expenses, notify the Indemnitee that the request for advancement of Expenses or reimbursement of Expenses will be submitted to the Reviewing Party (as hereinafter defined). The Reviewing Party shall make a determination on the request within 30 days after the Indemnitee’s written request for an advancement or reimbursement of Expenses. Notwithstanding anything foregoing to the contrary, in the event the Reviewing Party informs the Company that Indemnitee is not entitled to indemnification in connection with a Proceeding under this Agreement or applicable law, the Company shall be entitled to be reimbursed by Indemnitee for all the Expenses previously advanced or otherwise paid to Indemnitee in connection with such Proceeding; provided, however, that Indemnitee may bring a suit to enforce his/her indemnification right in accordance with Section C.3 below.

  • Expert Determination If a Dispute relates to any aspect of the technology underlying the provision of the Goods and/or Services or otherwise relates to a financial technical or other aspect of a technical nature (as the Parties may agree) and the Dispute has not been resolved by discussion or mediation, then either Party may request (which request will not be unreasonably withheld or delayed) by written notice to the other that the Dispute is referred to an Expert for determination. The Expert shall be appointed by agreement in writing between the Parties, but in the event of a failure to agree within ten (10) Working Days, or if the person appointed is unable or unwilling to act, the Expert shall be appointed on the instructions of the relevant professional body. The Expert shall act on the following basis: he/she shall act as an expert and not as an arbitrator and shall act fairly and impartially; the Expert's determination shall (in the absence of a material failure to follow the agreed procedures) be final and binding on the Parties; the Expert shall decide the procedure to be followed in the determination and shall be requested to make his/her determination within thirty (30) Working Days of his appointment or as soon as reasonably practicable thereafter and the Parties shall assist and provide the documentation that the Expert requires for the purpose of the determination; any amount payable by one Party to another as a result of the Expert's determination shall be due and payable within twenty (20) Working Days of the Expert's determination being notified to the Parties; the process shall be conducted in private and shall be confidential; and the Expert shall determine how and by whom the costs of the determination, including his/her fees and expenses, are to be paid.

  • Disagreement on Decision Should the parties disagree as to the meaning of the Board's decision, either party may apply to the Chairperson of the Arbitration Board to reconvene the Board to clarify the decision, which it shall make every effort to do within seven days.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!