LIABILITY FOR FAILURE TO COMPLETE TRANSACTIONS If We do not
Our Liability for Failure to Complete Transactions If we do not properly complete a transaction from your Card on time or in the correct amount according to our Agreement with you, we will be liable for your losses or damages. However, there are some exceptions. We will not be liable, for instance:
Failure to Comply 8.2.1 If the Developer fails to observe or perform any condition of this Agreement after the Municipality has given the Developer 30 days written notice of the failure or default, then in each such case: (a) The Municipality shall be entitled to apply to any court of competent jurisdiction for injunctive relief including an order prohibiting the Developer from continuing such default and the Developer hereby submits to the jurisdiction of such Court and waives any defence based upon the allegation that damages would be an adequate remedy; (b) The Municipality may enter onto the Lands and perform any of the covenants contained in this Agreement or take such remedial action as is considered necessary to correct a breach of the Agreement, whereupon all reasonable expenses whether arising out of the entry onto the Lands or from the performance of the covenants or remedial action, shall be a first lien on the Lands and be shown on any tax certificate issued under the Assessment Act; (c) The Municipality may by resolution discharge this Agreement whereupon this Agreement shall have no further force or effect and henceforth the development of the Lands shall conform with the provisions of the Land Use By-law; or (d) In addition to the above remedies, the Municipality reserves the right to pursue any other remedy under the Halifax Regional Municipality Charter or Common Law in order to ensure compliance with this Agreement.
Failure to Perform In the event of a failure of performance due under this Agreement and if it becomes necessary for either party to undertake legal action against the other on account thereof, then the prevailing party shall be entitled to reasonable attorney’s fees in addition to costs and necessary disbursements.