Maintenance of the Services Sample Clauses

Maintenance of the Services. 5.1. During the Term of this Agreement if Hynix or any third party supplier (including Third Party Suppliers) has scheduled, or otherwise has planned to undertake inspection, testing, preventative maintenance, corrective maintenance, repairs, replacement, improvement or other similar activities to all or any portion of the Service Facilities (collectively, the “Maintenance Activities”), Hynix or the relevant third party supplier, as applicable, may, for the duration of such Maintenance Activities, interrupt, suspend or curtail the provision of relevant Services to the extent that the Maintenance Activities for the affected parts of the Service Facilities are necessary or advisable. In the event that Hynix is required to perform corrective maintenance, repairs due to malfunction or non-routine inspection due to a suspected malfunction, Hynix shall give NewCo prior written notice of such activities to the extent reasonably possible. In the event that Hynix proposes to conduct any other Maintenance Activities, Hynix shall give NewCo as much prior written notice as reasonably possible of such activities, which in any event shall not be less than 30 days prior written notice, and Hynix shall consult with NewCo prior to undertaking or permitting to occur any such Maintenance Activity. Upon Hynix’s receipt of any notice of any Maintenance Activities by any third party suppliers, Hynix promptly shall provide NewCo written notice thereof and shall consult with NewCo to the extent reasonably possible prior to permitting any such Maintenance Activities to occur. 5.2. If NewCo receives such notice as set forth in Section 5.1, then to the extent that the affected Services are insufficient to meet NewCo’s requirements for NewCo’s use thereof in accordance with the terms and conditions hereof, Hynix shall (i) to the extent Hynix has alternative sources available internally, provide alternate sources for the affected Services for the duration of the Maintenance Activities, (ii) to the extent that Hynix obtains any alternate sources for such Services, Hynix shall make available a pro-rata share of these alternate sources to NewCo, and (iii) if the foregoing are not available or are insufficient to meet NewCo’s requirements, Hynix shall cooperate with NewCo to locate alternate sources for such Services. To the extent the foregoing alternate sources are provided by Hynix, there shall be no incremental cost or expense to NewCo. To the extent the foregoing alternate sources ar...
Sample 1Sample 2Sample 3See All (6)
AutoNDA by SimpleDocs
Maintenance of the Services. 2.1. The Service Provider will make endeavours to maintain the Services for the Client during the term of the SLA. 2.2. The maintenance work can result in that the Services will temporarily not be available, or only to a limited extent. The Service Provider will always coordinate the time at which the Planned Maintenance is executed in advance with the Client, for the limitation of the inconvenience caused by the work to be executed by LGD. In derogation from further provisions of this SLA, it is permitted to execute Planned Maintenance also without prior permission from the Client, if the work to be executed is not expected to result in any disruption or limitation of the Availability. 2.3. In derogation from further provisions of this SLA, it is permitted to execute Emergency Maintenance also without prior permission from the Client, if this work cannot be postponed due to the Impact and Urgency. The Service Provider will make endeavours to inform the Client as soon as possible of the nature and expected duration of the work. 2.4. The Maintenance can result in that existing Functionalities are adjusted and/or become redundant. The Service Provider will inform the Client in a timely manner if there is an essential change in the Functionality.
Sample 1Sample 2
Maintenance of the Services. 2.1. Let's Get Digital will make endeavours to maintain the Services for the Client during the term of the Service Level Agreement. 2.2. The maintenance work can result in that the Services will temporarily not be Available, or only to a limited extent. Let's Get Digital will always coordinate the time at which the Planned Maintenance is executed in advance with the Client, for the limitation of the inconvenience caused by the work to be executed by Let's Get Digital. In derogation from further provisions of this Service Level Agreement, it is permitted to execute Planned Maintenance also without prior permission from the Client, if the work to be executed is not expected to result in any disruption or limitation of the Availability. 2.3. In derogation from further provisions of this Service Level Agreement, it is permitted to execute Emergency Maintenance also without prior permission from the Client, if this work cannot be postponed due to the Impact and Urgency. Let's Get Digital will make endeavours to inform the Client as soon as possible of the nature and expected duration of the work. 2.4. The Maintenance can result in that existing Functionalities are adjusted and/or become redundant. Let's Get Digital will inform the Client in a timely manner if there is an essential change in the Functionality.
Sample 1
Maintenance of the Services. Cleura is entitled to perform up to two (2) pre- announced maintenance windows per year and per region. The time and date of such maintenance windows shall be notified to Customer no less than fourteen (14) days in advance via Cleura Status Page. Each maintenance window will primarily be managed weekdays during 08-17 CET/CEST. Customer is responsible to configure and setup its environment in a redundant and effective manner to minimise the impact of Cleura’s service windows. • Rebuild and/or expand storage clusters, • Perform preventive measures for on-going vulnerability or non-compliance impacting activities external to Cleura, • Add new services.
Sample 1
Maintenance of the Services. Cirium reserves the right to make alterations to the Service or any of their parts. In particular, (i) to make changes in the maintenance hours and in user identification procedures provided that Cirium will not make changes in the maintenance hours except in the case of emergency without giving at least 14 days’ notice to the Customer; (ii) to add, amend, delete or otherwise vary all or any of the Licensed Material; (iii) to withdraw the Service from any particular network or to make the Service available through any additional or alternative network.
Sample 1
Maintenance of the Services. 8.1. Scheduled Maintenance
Sample 1

Related to Maintenance of the Services

  • Maintenance of Services A. Reseller will adopt and adhere to the standards contained in the applicable BellSouth Work Center Interface Agreement regarding maintenance and installation of service. B. Services resold under the Company’s Tariffs and facilities and equipment provided by the Company shall be maintained by the Company. C. Reseller or its end users may not rearrange, move, disconnect, remove or attempt to repair any facilities owned by the Company, other than by connection or disconnection to any interface means used, except with the written consent of the Company. D. Reseller accepts responsibility to notify the Company of situations that arise that may result in a service problem. E. Reseller will be the Company's single point of contact for all repair calls on behalf of Reseller’s end users. The parties agree to provide one another with toll-free contact numbers for such purposes. F. Reseller will contact the appropriate repair centers in accordance with procedures established by the Company. G. For all repair requests, Reseller accepts responsibility for adhering to the Company's prescreening guidelines prior to referring the trouble to the Company. H. The Company will xxxx Reseller for handling troubles that are found not to be in the Company's network pursuant to its standard time and material charges. The standard time and material charges will be no more than what BellSouth charges to its retail customers for the same services. I. The Company reserves the right to contact Reseller’s customers, if deemed necessary, for maintenance purposes.

  • Performance of the Services In addition to the Common Articles, it is specified that:

  • MAINTENANCE OF THE SAID BUILDING APARTMENT / PROJECT

  • Scope of the Services UNOPS intends to retain the Contractor for the implementation of the Services, and the Contractor intends to provide the Services. The Contractor has represented to UNOPS that it has the appropriate experience, expertise, licences, and resources to undertake the Services and has agreed to undertake the Services in accordance with the Contract. In reliance on the Contractor’s representations UNOPS has entered into the Contract. The Contract sets out the terms and conditions upon which the Contractor will undertake the Services.

  • B1 The Services The Contractor shall supply the Services during the Contract Period in accordance with the Authority’s requirements as set out in the Specification and the provisions of the Contract in consideration of the payment of the Contract Price. The Authority may inspect and examine the manner in which the Contractor supplies the Services at the Premises during normal business hours on reasonable notice.

  • Use of the Services 1.1 We will make the Oracle services listed in Your order (the “Services”) available to You pursuant to this Agreement and Your order. Except as otherwise stated in this Agreement or Your order, You have the non- exclusive, worldwide, limited right to use the Services during the period defined in Your order, unless earlier terminated in accordance with this Agreement or Your order (the “Services Period”), solely for Your internal business operations. You may allow Your Users (as defined below) to use the Services for this purpose, and You are responsible for their compliance with this Agreement and Your order. 1.2 The Service Specifications describe and govern the Services. During the Services Period, we may update the Services and Service Specifications (with the exception of the Data Processing Agreement as described below) to reflect changes in, among other things, laws, regulations, rules, technology, industry practices, patterns of system use, and availability of Third Party Content (as defined below). Oracle updates to the Services or Service Specifications will not materially reduce the level of performance, functionality, security or availability of the Services during the Services Period of Your order. 1.3 You may not, and may not cause or permit others to: (a) use the Services to harass any person; cause damage or injury to any person or property; publish any material that is false, defamatory, harassing or obscene; violate privacy rights; promote bigotry, racism, hatred or harm; send unsolicited bulk e-mail, junk mail, spam or chain letters; infringe property rights; or otherwise violate applicable laws, ordinances or regulations; (b) perform or disclose any benchmarking or availability testing of the Services; (c) perform or disclose any performance or vulnerability testing of the Services without Oracle’s prior written approval, or perform or disclose network discovery, port and service identification, vulnerability scanning, password cracking or remote access testing of the Services; or (d) use the Services to perform cyber currency or crypto currency mining ((a) through (d) collectively, the “Acceptable Use Policy”). In addition to other rights that we have in this Agreement and Your order, we have the right to take remedial action if the Acceptable Use Policy is violated, and such remedial action may include removing or disabling access to material that violates the policy.

  • Maintenance of Business The Borrower shall, and shall cause each Subsidiary to, preserve and maintain its existence, except as otherwise provided in Section 8.10(c)

  • Access to the Services ID’s for access to Vendor Core Research and Analyst Inquiry may not be shared. Access to the Services is restricted to the number of named individuals (each a “Licensed User”) as identified in the Customer Purchase Order.

  • Description of the Services 1.1 The scope of the service to be rendered is described more fully in the Annexures and Schedules referred to below: ❑ Annexure A – Scope / Specification ❑ Annexure C – Pricing Schedule The Deliverables, due for completion by and governed by this Schedule 1. In the event that the Service Provider fails to meet the delivery dates as agreed, the following penalties will be imposed:

  • Maintenance and Support Services If this Agreement is for IT goods or services, this section applies: Unless otherwise specified in this Agreement: The Contractor shall promptly provide the Court with all Upgrades, including without limitation: (i) all Upgrades generally made available by Contractor to its other customers; (ii) Upgrades as necessary so that the Work complies with the Specifications and Applicable Law (including changes in Applicable Law); (iii) Upgrades as necessary so that the Work operates under new versions or releases of the Court’s operating system or database platform; and (iv) all on-site services necessary for installation of Upgrades. Without limiting any other obligation of Contractor under this Agreement, Contractor represents and warrants that it will maintain services, equipment, software or any other part of the Work so that they operate in accordance with their Specifications and Documentation; and The Contractor shall respond to the Court within four (4) hours after the Court reports a Technical Support Incident (such hours all occurring during Standard M&S Hours) to Contractor. DELIVERY, ACCEPTANCE, AND PAYMENT Delivery. Contractor shall deliver to the Court the Deliverables in accordance with this Agreement, including the Statement of Work. Unless otherwise specified by this Agreement, Contractor will deliver all goods purchased by the Court “Free on Board Destination Freight Prepaid” to the Court at the address and location specified by the Court. Title to all goods purchased by the Court vests in the Court upon payment of the applicable purchase price. Contractor will bear the risk of loss for any Work being delivered until received by the Court at the proper location. All shipments by Contractor or its Subcontractors must include packing sheets identifying: this Agreement number, the Court’s purchase order number, item number, quantity and unit of measure, part number and description of the goods shipped, and appropriate evidence of inspection, if required. Goods for different Agreements shall be listed on separate packing sheets.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!