PERIOD OF SERVICE. The Grant Services will commence on the Start Date and shall expire on the End Date as set forth in the SUMMARY PAGE.
PERIOD OF SERVICE. The Consultant shall complete the Services on or before December 31, 2019 (the “Deadline”), unless the Authority agrees to extend the Deadline for good reason; provided, however, that the Authority may terminate this Contract at any time in accordance with Section 14. Time is of the essence in performance of this Contract. There will be no obligation established between Authority and the Consultant for performance of the Services until Authority provides the Consultant execution of this Contract and receipt by the Authority of appropriate Certificates of Insurance and other documentation as may be required herein. The term of this Contract (“Term”) shall begin on the Effective Date and shall end on the first to occur of the following: (1) the Deadline, as the same may have been extended by the Authority, (2) the date on which, in the opinion of Authority, all of the Services have been rendered, (3) the date on which this Contract is terminated by the Authority pursuant to Section 14, or (4) the date on which this Contract is terminated by the Consultant pursuant to Section 14.
PERIOD OF SERVICE. This Work Authorization shall become effective on the date of final acceptance of the parties hereto, and terminate upon completion of scopes of the work authorization.
PERIOD OF SERVICE. The term “Period of Service” means the continuous period of the Participant’s Employment up to the Termination Date, and also includes any prior period of Employment separated by: (i) any break in Employment as a result of a leave of absence authorized by the Company or by law; and (ii) any break in Employment not authorized by the Company or by law lasting twelve (12) months or less.
PERIOD OF SERVICE. The Grant Services will commence upon date of execution and continue through July 31, 2022.
PERIOD OF SERVICE. The CONSULTANT’S period of service shall complete the scope of work stated in Exhibit A by April 30, 2020, provided a written “Notice to Proceed” is issued by September 30, 2019. The CONSULTANT’S services shall be provided in general accordance with the schedule as defined in Exhibit B. The OWNER may consider a failure by CONSULTANT to meet the schedule in Exhibit B with regard to any phase of the work as a breach of this Agreement.
PERIOD OF SERVICE. (A) The services, and if more than one, then each phase thereof, shall be completed in accordance with the schedule contained in Exhibit VI, "Performance Schedule," attached hereto and made a part of this Agreement. The Consultant and the Sponsor will be required to meet this schedule.
(B) The Consultant and Sponsor will be required to meet the schedules in this Agreement. The Sponsor will grant time extensions for delays due to unforeseeable causes beyond the control of and without fault or negligence of the Consultant and no claim for damage shall be made by either party. Requests for extensions of time shall be made in writing by the Consultant before that phase of work is scheduled to be completed, stating fully the events giving rise to the request and justification for the time extension requested. The anticipated date of completion of the work, including review time, is stated in Exhibit VI of this Agreement. An extension of time shall be the sole allowable compensation for any such delays, except as otherwise provided in Section (3) for additional/changed work and differing/unforeseen conditions. Any extensions or additional costs shall be subject to MoDOT approval.
(C) As used in this provision, the term "delays due to unforeseeable causes" include but are not limited to the following:
1. War or acts of war, declared or undeclared;
2. Flooding, earthquake, or other major natural disaster preventing the Consultant from performing necessary services at the project site, or in the Consultant's offices, at the time such services must be performed;
3. The discovery on the project of differing site conditions, hazardous substances, or other conditions which, in the sole judgment of the Sponsor, justifies a suspension of the services or necessitates modifications of the project design or plans by the Consultant;
4. Court proceedings;
5. Changes in services or extra services.
PERIOD OF SERVICE. Upon receipt of written authorization to proceed, ENGINEER shall perform the services described in Exhibit A within a reasonable period of time. Unless otherwise stated in this Agreement, the rates of compensation for ENGINEER’S services have been agreed to in anticipation of the orderly and continuous progress of the project through completion. If any specified dates for the completion of ENGINEER’S services are exceeded through no fault of the ENGINEER, the time for performance of those services shall be automatically extended for a period which may be reasonably required for their completion and all rates, measures and amounts of ENGINEER’S compensation shall be equitably adjusted.
PERIOD OF SERVICE. The Engineer shall complete the Services on or before June 30, 2022 (the “Deadline”), unless the Authority agrees to extend the Deadline for good reason; provided, however, that the Authority may terminate this Contract at any time in accordance with Section 14. Time is of the essence in performance of this Contract. There will be no obligation established between Authority and the Engineer for performance of the Services until Authority provides the Engineer with a written notice to proceed which shall be issued upon execution of this Contract and receipt by the Authority of appropriate Certificates of Insurance and other documentation as may be required herein. The term of this Contract (“Term”) shall begin on the Effective Date and shall end on the first to occur of the following: (1) the Deadline, as the same may have been extended by the Authority, (2) the date on which, in the opinion of Authority, all of the Services have been rendered, (3) the date on which this Contract is terminated by the Authority pursuant to Section 14, or (4) the date on which this Contract is terminated by the Engineer pursuant to Section 14.
PERIOD OF SERVICE. Consultant must perform the services described in Exhibit “A” for the term of this Agreement. Unless amended in writing by the Parties, the Agreement term expires calendar days after the Notice to Proceed (NTP) Date.
