Personnel and Subcontractors. 12.1 The Contractor shall be responsible for providing at its own cost and expense all personnel necessary to perform the Services.
12.2 The Contractor accepts that DCC may refuse to admit to any premises occupied by or on behalf of DCC any person employed or engaged by the Contractor, or by any other person whose admission would be, in the reasonable opinion of DCC, undesirable. The Contractor will not be responsible for any delays in scheduling or performance of the Services caused by such refusal.
12.3 If requested by DCC, the Contractor shall within seven (7) days provide a list of the names of all persons who it expects may require admission in connection with the performance of a Call-Off Contract to any premises occupied by or on behalf of DCC specifying the capacities in which they are concerned with a Call-Off Contract and giving such other particulars as DCC may reasonably require, subject to the Contractor’s confidentiality and privacy provisions.
12.4 The Contractor shall not engage any agents or sub-contractors to provide the Services or any part of the Services without DCC’s prior written consent (such consent not to be unreasonably withheld or delayed). The Contractor shall remain responsible for obligations which are performed by its permitted agents or sub-contractors and for the acts or omissions of those agents and sub-contractors as if they were acts or omissions of the Contractor.
Personnel and Subcontractors. 8.1 The Contractor will provide only personnel who have the qualifications, experience and capabilities to provide the Goods and perform the Services.
8.2 The Contractor will provide the Goods and Services using the personnel and sub- contractors as may be listed in the Quotation, and the Contractor will not remove any such listed personnel or sub-contractors from the Services without the prior written approval of the City.
8.3 If the City reasonably objects to the performance, qualifications, experience or suitability of any of the Contractor's personnel or sub-contractors then the Contractor will, on written request from the City, replace such personnel or sub-contractors.
8.4 Except as provided for in Section 8.2, the Contractor will not engage any personnel or sub-contractors, or sub-contract or assign its obligations under this Agreement, in whole or in part, without the prior written approval of the City.
8.5 The Contractor will preserve and protect the rights of the City with respect to any Services performed under sub-contract and incorporate the conditions of this Agreement into all sub-contracts as necessary to preserve the rights of the City under this Agreement. The Contractor will be as fully responsible to the City for acts and omissions of sub-contractors and of persons directly or indirectly employed by them as for acts and omissions of persons directly employed by the Contractor.
Personnel and Subcontractors. ACRPC shall employ only qualified personnel, to carry out and supervise the work. ACRPC shall also be responsible for hiring any subcontractors supervising their work and ensuring their compliance with the terms of this agreement. Bristol shall have the right to approve or disapprove key personnel and Subcontractors, and their personnel, assigned to administer activities related to the agreement.
Personnel and Subcontractors. (a) The Supplier must ensure its Personnel are of good character, suitably skilled, experienced and qualified, and hold all necessary authorisations, visas, licences, approvals and permits, to perform the responsibilities assigned to them.
(b) The Supplier must not subcontract any of its obligations under the Agreement without HKE’s prior written consent.
(c) The Supplier remains liable for the acts and omissions of its subcontractors and Personnel in connection with the Agreement as if they were the acts and omissions of the Supplier.
Personnel and Subcontractors. 1. If the services of [NAME of Primary Monitor] (“Primary Monitor”) with Contractor are terminated either by Contractor or the Primary Monitor for any reason whatsoever, with or without cause, or if the Primary Monitor is otherwise unavailable to perform the Services, or any part thereof, under this Agreement, the City and the Court reserve the right to terminate this Agreement. Contractor agrees to provide the City and the Court with ninety days written notice prior to the effective date of the Primary Monitor’s termination.
2. Contractor shall maintain a physical presence in New Orleans. The Primary Monitor shall spend a minimum of 70 weekdays in New Orleans during the first year of this Agreement and shall be present in New Orleans at least once a month thereafter for the duration of this Agreement. A senior member of the monitoring team shall be present in New Orleans every weekday of the year, except federal and state holidays.
Personnel and Subcontractors. C5.1 Personnel Tenderer to provide details of staff who will be involved in the installation and commissioning of the Goods, and their previous experience installing and commission the Goods in a similar environment.
C5.2 Local staff Tenderer to advise if any of the staff assigned to the project in different roles are located in Brisbane.
C5.3 Non-local staff For staff located outside of Brisbane, Tenderer to set out its proposal in relation to travel and other expenses in Tender Schedule 2 (Prices and Additional Pricing Information). Tenderer to detail the degree to which travel and other expenses are expected to be incurred in the performance by the Tenderer of the Project Plan proposed. (See also Tender Schedule 6 (Project Plan))
C4.1 Sub- contractors Tenderer to detail any subcontractors, and provide their individual CVs where relevant, it proposes to use for the Supply of the Goods
Personnel and Subcontractors. For all purposes under the Agreement, in no event shall any employee, agent or Subcontractor of Seller be considered a borrowed servant, unless and only to the extent that the Purchase Order expressly provides that one or more of Seller’s employees, agents or Subcontractors is being supplied to Buyer without supervision by Xxxxxx and who will be under the exclusive direction and control of Buyer. In all other cases, all employees, agents or Subcontractors of Seller performing Services or work in connection with the Agreement shall be considered employees of an independent contractor. Notwithstanding the foregoing or any other provision in the Agreement to the contrary, Xxxxxx’s duties to defend, indemnify, protect and hold harmless Buyer under the terms of the Agreement shall apply and continue regardless of the characterization of an employee, agent or Subcontractor as a borrowed servant or the employee of an independent contractor. Buyer reserves the right to approve any subcontractor which is retained by Seller for the purposes of subcontracting any portion of the Services (each a “Subcontractor”) in its sole discretion and, without limitation, can require the replacement of a Subcontractor for cause (in which case Seller will pay all costs associated with such replacement) or without cause (in which case Buyer will pay all costs associated with such replacement). Such Subcontractors shall not be changed without Buyer’s prior consent. Seller acknowledges and agrees that the fees for any Subcontractors are included in Seller’s compensation as provided in the Purchase Order.
Personnel and Subcontractors.
10.8.4.1 Smoking is prohibited in all areas of the Project Site except in designated smoking areas. Contractor and Project Manager to determine a designated smoking area.
10.8.4.2 Prejudicial remarks, actions, slurs, and jokes in the workplace that are offensive to people relative to their race, color, religion, national origin, sex, age, marital status, veteran status, disability, or sexual orientation are strictly prohibited. Sexual harassment is strictly prohibited. Contractors are expected to use a reasonable person’s standard of good judgment in their working relationships. No person shall be subjected to deliberate or repeated unsolicited verbal comments, gestures, or physical contact of a sexual nature, or that which is offensive, hostile, or intimidating. the Project Site:
Personnel and Subcontractors. 12.1 The Contractor shall ensure that, at all times:-
12.1.1 each of the Contractor Personnel is suitably qualified, adequately trained and capable of providing the applicable Services in respect of which they are engaged;
12.1.2 there is an adequate number of Contractor Personnel to perform its obligations under this Agreement (including in relation to the supply of Services) in accordance with this Agreement;
12.1.3 only those people who are authorised by the Contractor (and who comply with the obligations on the Contractor under this Agreement) are involved in providing the Services; and
12.1.4 all of the Contractor Personnel comply with all of the Mandatory Requirements and the Contractor's other obligations in connection with this Agreement, including those that apply to persons who are allowed access to any of the DCC Premises.
12.2 The Contractor accepts that DCC may refuse to admit to any premises occupied by or on behalf of the DCC any person employed or engaged by the Contractor, or by any other person whose admission would be, in the reasonable opinion of the DCC, undesirable.
12.3 If requested by the DCC, the Contractor shall within thirty (30) days provide a list of the names of all persons who it expects may require admission in connection with the performance of this Agreement to any premises occupied by or on behalf of the DCC specifying the capacities in which they are concerned with this Agreement and giving such other particulars as the DCC may reasonably require, subject to the Contractor’s confidentiality and privacy provisions.
12.4 The Contractor shall not engage any agents or subcontractors to provide the Services or any part of the Services without the DCC’s prior written consent (such consent not to be unreasonably withheld or delayed). A list of the Contractor’s subcontractors is included at Schedule 4.3 (Subcontractors)
12.5 The Contractor shall remain responsible for obligations which are performed by its permitted agents or subcontractors and for the acts or omissions of those agents and subcontractors as if they were acts or omissions of the Contractor.
Personnel and Subcontractors. Lonza shall retain appropriately qualified and trained personnel with the requisite knowledge and experience to perform the Services in accordance with this Agreement. Lonza may subcontract and/or delegate any of its rights and/or obligations under this Agreement to perform the Services solely with Customer’s prior written approval (such approval not to be unreasonably withheld and/or delayed), provided that such Subcontractors are appropriately and fully qualified in all respects to perform the applicable Services, that such Subcontractors are subject to obligations of confidentiality at least as stringent and as protective of Customer as those obligations of confidence and non-use imposed upon Lonza, and that such Subcontractors are subject to obligations to act diligently and in accordance with best practice in respect of cGMP manufacture as contained in this Agreement. [Redacted]
