Requirements for Completion Sample Clauses

Requirements for Completion. Completion is when the Contractor has done all the work, which the Works Information states he is to do by the Completion Date and has corrected notified Defects, which would have prevented the Employer from using the works. The Site is handed back to the Employer in a condition acceptable to the Service Manager.
Sample 1Sample 2Sample 3See All (8)
AutoNDA by SimpleDocs
Requirements for Completion. 4A shall promptly notify Owner of any additional requirements necessary to facilitate each project’s completion (i.e. -If trenching is included: Excavation of rock harder than “highly weathered"). Any subsequent amendment, modification or agreement, which operates to alter this Contract, and which is signed by 4A and Owner, shall be deemed a part of this Contract and shall be controlling in case of conflict, to the extent that it alters this Contract. CORRECTIVE WORK: 4A will perform minor corrective or repair work that may remain to be finished after each project completion. Owner shall not withhold any payment pending completion of such work. If major corrective or repair work remains to be finished after each project is completed and the cost exceeds one (1) percent of the gross Contract price, the Owner may withhold payment sufficient to pay for completion of the work, pending completion of the work, but may not withhold an amount which is greater. ITEMS NOT RESPONSIBILITY OF 4A: Owner represents that the property being improved does not contain hazardous materials. 4A shall not be held responsible for any existing violations of applicable building regulations or ordinances. Correction of such violations or abnormal conditions by 4A shall be considered additional work and shall be treated as “Extra Work”. 4A agrees to start and diligently pursue work through to completion, but shall not be responsible for delays for any of the following reasons; failure of the issuance of all necessary building permits within a reasonable length of time, acts of neglect or omission of Owner, Owner’s employees or Owner’s agent, acts of God, stormy or inclement weather, labor union activities, extra work ordered by Owner, acts of public enemy, riots or civil commotion, inability to secure material through regular recognized channels, imposition of Government priority or allocation of materials, failure of Owner to make payments when due, delays caused by inspection or changes ordered by the inspectors of authorized governmental bodies, acts of independent contractors, holidays or other causes beyond 4A’s reasonable control.
Sample 1
Requirements for Completion. ESKOM HOLDINGS SOC LTD CONTRACT NUMBER MAINTENANCE AND REPAIRS OF FIRE DETECTION SYSTEM AT TUTUKA POWER STATION FOR A PERIOD OF 5 YEARS Completion is when the contractor has done all the work, which the Works Information states he is to do by the Completion Date and has corrected notified Defects, which would have prevented the Employer from using the works. The Site is handed back to the Employer in a condition acceptable to the Service Manager.
Sample 1
Requirements for Completion. Students must successfully fulfill program objectives, meet course requirements of 75% or higher, finished 1500 hours of education, and receive a certificate are eligible* to submit an application to take the National Council Licensing Examination for Practical Nurses. *Excerpts from the Pennsylvania Nurse Practice Act for Practical Nurses: (Act 110): "The State Board shall not issue a license or certificate to an applicant who has been convicted of a felonious act prohibited by the Controlled Substance, Drug, Device and Cosmetic Act, or convicted of a felony relating to a controlled substance in court of law of the United States or any other State, Territory, or Country unless: (1) at least ten years have elapsed since the date of conviction; (2) the applicant satisfactorily demonstrates significant progress in rehabilitation since the conviction and the licensure of the applicant should not be expected to create a substantial risk of harm to the health and safety of patients or the public; (3) the applicant otherwise satisfies the qualifications contained in or authorized by the act. (Convicted shall include a judgment, an admission of guilt or a plea of Nolo Contendere.)" Conviction of a misdemeanor/felony may also result in denial of licensure.
Sample 1
Requirements for Completion. Matriculating students must satisfy SPC's requirements for the Bachelor's in Applied Science in Health Services Administration for Respiratory Care. These requirements for graduation and completion are as fo11ows: a. Students must earn at least 120 college level credit hours.
Sample 1

Related to Requirements for Completion

  • Time for Completion The Contractor shall deliver the material and/or services called for in the specifications/proposal and within the delivery time specified and in accordance with the terms of the contract. Work shall be completed within 30 days from the Notice to Proceed issued by the City of Sparks Purchasing Division. The Contractor shall not alter or vary any terms or conditions contained or incorporated herein, including but not limited to, the quantity, price, delivery date or date designated as After Receipt of Order (ARO) or date for commencement or completion of services as mutually agreed upon, unless such alteration or variation is consented to in writing by a duly authorized representative of the City. The City reserves the right to cancel resultant Contract upon ten days written notice in the event the type and quality of the product or work performance is unsatisfactory or in default, subject to Contractor’s right to cure as outlined in termination clause. This is a non-exclusive Contract and the City reserves the right to acquire the material and/or services at its discretion, from other sources during the term of this Contract.

  • Time for Compliance Consultant shall not commence work under this Agreement until it has provided evidence satisfactory to the City that it has secured all insurance required under this section. In addition, Consultant shall not allow any subconsultant to commence work on any subcontract until it has provided evidence satisfactory to the City that the subconsultant has secured all insurance required under this section. Failure to provide and maintain all required insurance shall be grounds for the City to terminate this Agreement for cause.

  • Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.

  • Requirements for E- Bidders 3.1. For Individual/ Joint E-Bidders, the following documents shall be uploaded during online registration; 3.1.1. Copy of Identification Documents (both sides) 3.1.2. Evidence of deposit payment 3.2. For Agent acting for Individual/ Joint Online Bidders, the following documents shall be uploaded during online registration; 3.2.1. Copy of Identification Documents (both sides) of Individual/ Joint Online Bidder 3.2.2. Copy of Identification Documents (both sides) of Agent 3.2.3. Copy of letter of authorization to bid 3.2.4. Evidence of deposit payment 3.3. For Company, the following documents shall be uploaded during online registration: 3.3.1. Copy of Identification Documents (both sides) of the representative. 3.3.2. Copy of letter of authorization to bid under the Company’s Letter Head 3.3.3. Form 24; Form 44; Form 49 (or their equivalent forms under the Companies Act 2016)

  • Certain State Law Requirements for Contracts The contents of this Section are required by Texas Law and are included by County regardless of content. For purposes of Sections 2252.152, 2271.002, and 2274.002, Texas Government Code, as amended, C&T hereby verifies that C&T and any parent company, wholly owned subsidiary, majority-owned subsidiary, and affiliate: a. Unless affirmatively declared by the United States government to be excluded from its federal sanctions regime relating to Sudan or Iran or any federal sanctions regime relating to a foreign terrorist organization, is not identified on a list prepared and maintained by the Texas Comptroller of Public Accounts under Sections 806.051, 807.051, or 2252.153 of the Texas Government Code. b. If employing ten (10) or more full-time employees and this Agreement has a value of

  • Quality Assurance Requirements There are no special Quality Assurance requirements under this Agreement.

  • Additional Requirements for Sleeping Rooms The Contractor shall provide departing Attendees a secured area for storing belongings.

  • Inspection; Compliance Lessor and Lessor's Lender(s) (as defined in Paragraph 8.3(a)) shall have the right to enter the Premises at any time, in the case of an emergency, and otherwise at reasonable times, for the purpose of inspecting the condition of the Premises and for verifying compliance by Lessee with this Lease and all Applicable Laws (as defined in Paragraph 6.3), and to employ experts and/or consultants in connection therewith and/or to advise Lessor with respect to Lessee's activities, including but not limited to the installation, operation, use, monitoring, maintenance, or removal of any Hazardous Substance or storage tank on or from the Premises. The costs and expenses of any such inspections shall be paid by the party requesting same, unless a Default or Breach of this Lease, violation of Applicable Law, or a contamination, caused or materially contributed to by Lessee is found to exist or be imminent, or unless the inspection is requested or ordered by a governmental authority as the result of any such existing or imminent violation or contamination. In any such case, Lessee shall upon request reimburse Lessor or Lessor's Lender, as the case may be, for the costs and expenses of such inspections.

  • PROGRESS AND COMPLETION 8.2.1 All time limits stated in the Contract Documents are material terms and time is the essence of the Contract. A failure by Contractor to do what is required by the time specified in the Contract Documents is a breach of the contract. 8.2.2 The Contractor shall begin the Work on the date of commencement as defined in 8.2.3 If in the sole opinion of the State, the Contractor fails to commence work on the project or to complete the work of said project within the time specified above, or to prosecute the work in such a manner that it appears that the completion date can be assured, the State shall have the right to notify the Contractor by Certified Mail that the terms of the Contract have been violated, and that effective immediately the Contract is terminated and the State has the right to and in fact is taking over and attending to completion of the project without prejudice to the State's remedies for any losses sustained

  • Requirements for Transfer (a) This Warrant and the Warrant Shares shall not be sold or transferred unless either (i) they first shall have been registered under the Securities Act of 1933, as amended (the "Act"), or (ii) the Company first shall have been furnished with an opinion of legal counsel, reasonably satisfactory to the Company, to the effect that such sale or transfer is exempt from the registration requirements of the Act. (b) Notwithstanding the foregoing, no registration or opinion of counsel shall be required for (i) a transfer by a Registered Holder which is a corporation to a wholly owned subsidiary, parent or affiliate of such corporation, a transfer by a Registered Holder which is a partnership to a partner of such partnership or a retired partner of such partnership or to the estate of any such partner or retired partner, or a transfer by a Registered Holder which is a limited liability company to a member of such limited liability company or a retired member or to the estate of any such member or retired member, provided that the transferee in each case agrees in writing to be subject to the terms of this Section 4, or (ii) a transfer made in accordance with Rule 144 under the Act. (c) Each certificate representing Warrant Shares shall bear a legend substantially in the following form: "The securities represented by this certificate have not been registered under the Securities Act of 1933, as amended, and may not be offered, sold or otherwise transferred, pledged or hypothecated unless and until such securities are registered under such Act or an opinion of counsel satisfactory to the Company is obtained to the effect that such registration is not required." The foregoing legend shall be removed from the certificates representing any Warrant Shares, at the request of the holder thereof, at such time as they become eligible for resale pursuant to Rule 144(k) under the Act.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!