Settlement Meeting. The Parties shall attempt in good faith to resolve promptly through negotiations any Claim or dispute under this Agreement. If any such Claim or dispute should arise, the Parties shall meet at least once to attempt to resolve the matter (the "Settlement Meeting"). Any Party may request the other Parties to attend a Settlement Meeting at a mutually agreed time and place within ten days after delivery of a notice of a Claim or dispute. The occurrence of a Settlement Meeting with respect to a Claim or dispute shall be a condition precedent to seeking any arbitration or judicial remedy, provided that if a Party refuses to attend a Settlement Meeting the other Parties may proceed to seek such remedy.
Settlement Meeting. Either the grievant or the appropriate administrator in Step I and Step II shall have the right to request a settlement meeting at the appropriate step. Such request must be made during the applicable response period of the party making the request. If such request is made it shall be forwarded by the other party and a meeting shall be set at a mutually agreeable time that will not delay possible processing to the next step. Such a meeting shall be between the grievant and appropriate administrator. However, both parties may have one additional representative present.
Settlement Meeting. In the event of a Dispute which is not resolved in the normal course of business, either party may deliver a Dispute Notice to the other party. Within five Business Days from the delivery of the Dispute Notice, officials designated by the Province and the Contractor will meet at a mutually acceptable time and place to attempt to resolve the Dispute (a "Settlement Meeting"). The parties through their representatives will make all reasonable efforts to resolve the Dispute. If the Dispute is not resolved through the Settlement Meeting within 15 days from delivery of the Dispute Notice, then the Dispute will be referred to a Referee in accordance with Section 2.4. All negotiations held pursuant to Section 2.3 are to be held on a without prejudice basis and will not be used by either party as evidence at any other proceeding.
Settlement Meeting. 23 Section 11.2
Settlement Meeting. In the event any such claim or controversy arises, the Parties shall first attempt to settle their differences amicably between themselves. Either Party may initiate such informal dispute resolution by sending written notice of the dispute to the other Party, and within twenty (20) days after receipt of such notice appropriate representatives of the Parties, each with full authority from the chief executive officer of the Party to settle the dispute, shall meet for attempted resolution of the claim or controversy by good faith negotiations. If the representative of either Party intends to be accompanied at the settlement meeting by counsel, the other Party shall be given at least seven (7) days notice of such intention and may also be accompanied by counsel. All negotiations pursuant to this Section 12.17 shall be confidential and treated as compromise and settlement negotiations and shall not be admissible in any arbitration or other proceeding
Settlement Meeting. In the event of a Dispute which is not resolved in the normal course of business, either party may deliver a Dispute Notice to the other party. Within five Business Days from the delivery of the Dispute Notice, officials designated by the Province and the Contractor will meet at a mutually acceptable time and place to attempt to resolve the Dispute (a "Settlement Meeting"). The parties through their representatives will make all reasonable efforts to resolve the Dispute. If the Dispute is not resolved through the Settlement Meeting within 10 Business Days from delivery of the Dispute Notice, then the Dispute will be referred to a Referee in accordance with Section 2.4. All negotiations held pursuant to Section 2.3 are to be held on a without prejudice basis and will not be used by either party as evidence at any other proceeding. All information exchanged in connection with a Settlement Meeting shall be “Confidential Information” for purposes of the DBFM Agreement.
Settlement Meeting. The Parties will attempt in good faith to resolve promptly through negotiations any dispute under this Agreement. If any such dispute should arise, the Parties will meet at least once to attempt to resolve the matter (the "Settlement Meeting"). Any Party may request the other Parties to attend a Settlement Meeting at a mutually agreed time and place within ten days after delivery of a notice of a dispute. The occurrence of a Settlement Meeting with respect to a dispute will be a condition precedent to seeking any arbitration or judicial remedy, provided that if a Party refuses to attend a Settlement Meeting or does not avail itself to a Settlement Meeting within twenty days after delivery of a notice of dispute the other Party may proceed to seek such remedy.
Settlement Meeting. 22 Section 11.2 Arbitration Proceedings....................... 22 Section 11.3
Settlement Meeting. In the event of a termination pursuant to this Article 19, a termination settlement meeting shall be held at a mutually agreed time and place no later than thirty (30) days or such later date as the Parties may agree, after submission of a claim by Contractor pursuant to Article 19.1. At or prior to the date of such termination settlement meeting, Contractor shall provide Purchaser with such documentation of the costs set forth in Articles 19.1 and 19.2 as Purchaser may reasonably request including a detailed invoice of claimed costs. Contractor shall permit Purchaser, at Purchaser’s sole cost, to retain an audit firm acceptable to Contractor, which acceptance shall not be unreasonably withheld or delayed, to audit at a reasonable time, Contractor’s termination claim. Contractor shall have the right to redact from any audit report any detailed rate information, and such report shall be considered as Contractor Confidential Information and shall be protected pursuant to Article 26, regardless of how marked. Upon completion of the termination settlement meeting, Contractor may submit an invoice to Purchaser for payment in accordance with the terms of Article 5.2, for any amounts determined to be due from Purchaser pursuant to Article 10.1. Upon receipt of the termination payment, title to, and risk of loss of, all Deliverable Items referred to in Article 19.1(a), and all other partially completed or incomplete Deliverable Items for which Contractor is to be paid under this Article 19 shall transfer to Purchaser and Contractor shall deliver to Purchaser all Deliverable Items within thirty (30) days from the date of Contractor’s receipt of such payment, except for such Deliverable Items not desired by Purchaser as notified by Purchaser to Contractor. Purchaser may direct Contractor to undertake to sell or reallocate to other uses items subject to termination under this Article 19 for the purpose of receiving a price refund or offset against Contractor’s termination claim. Upon receipt of such direction, Contractor shall use reasonable commercial efforts to sell or reallocate the items and provide a refund to Purchaser or an offset against Contractor’s termination claim, less any reasonable selling expenses.
Settlement Meeting. If any dispute arises between the parties relating to 923 this Agreement, then the parties shall meet and seek to resolve the dispute, in good faith, 924 within ten (10) days after a Party’s request for such a meeting. The City shall send the 925 Designated Official and persons with information relating to the dispute, and Owner shall 926 send an owner’s representative and any consultant or other person with technical 927 information or expertise related to the dispute.
