Site Visits and Reports Sample Clauses

Site Visits and Reports. Prior to commencement of construction, the Operator will submit a proposed site visit and progress update schedule to the District corresponding to the appropriate proposed construction schedule milestones. The Operator will visit the construction site at intervals appropriate to the stage of construction, to become generally familiar with the progress and quality of the portion of the work completed, and to determine in general if the work observed is being performed in a manner indicating that the work, when fully completed, will be in accordance with the Contract Documents. On the basis of the site visits, the Operator will keep the District informed through regularly scheduled Parish Council Utility Committee (the “Utility Committee”) meetings about the progress and quality of the portion of the work completed. The District reserves the right to conduct substantial completion walk through, and have opportunity to formally comment on the punch-list items, and review subsequent contractor activities prior to completion of the construction project.
Sample 1Sample 2Sample 3See All (4)
AutoNDA by SimpleDocs
Site Visits and Reports i. The Architect and its Consultants shall visit the site at intervals appropriate to the stage of the Contractor’s operations, progress, and completion efforts, or as otherwise agreed by the Owner and Architect to: (1) become generally familiar with and to keep the Owner informed about the progress and quality of the portion of the Work completed; (2) endeavor to guard the Owner against defects and deficiencies in the Work; and (3) determine in general if the Work is being performed in a manner indicating that the Work, when fully completed, will be in accordance with the Contract Documents. The Architect shall carefully review the quality and quantity of the Work at least on a monthly basis as part of the Architect’s Basic Services and shall identify Work not in conformance with the Construction Documents. The Architect shall report to the Owner, in writing, known deviations from the Contract Documents and from the most recent construction schedule submitted by the Contractor.
Sample 1Sample 2See All (4)
Site Visits and Reports. The County shall have the right to view the construction of the City Project upon reasonable request to the City and coordination of the logistics of any such site visits with the City and the general contractor. Upon reasonable request, the City shall provide the County with a copy of construction progress reports or other regularly prepared reports on the construction of the City Project
Sample 1
Site Visits and Reports. 2.6.4.1 Architect and its Consultants, as representatives of Owner, shall visit the site of each Project at intervals appropriate to the stage of Contractor's operations for such Project, or at such intervals otherwise agreed by Owner and Architect in writing, but in no event less than one (1) full day per week: (a) to become generally familiar with and to keep Owner informed about the progress and quality of the Work completed for such Project;
Sample 1

Related to Site Visits and Reports

  • Inspections and Reports 2.1 The department may inspect, in the manner and at reasonable times it considers appropriate, all the contractor's facilities and activities under this contract.

  • Data and Reports The School is consistent in providing information, data, documentation, evindence and reports requested by the Commission pursuant to HRS §302D-17. x Review of submissions.

  • Records and Reports The contractor shall keep such records as necessary to document compliance with the EEO requirements. Such records shall be retained for a period of three years following the date of the final payment to the contractor for all contract work and shall be available at reasonable times and places for inspection by authorized representatives of the contracting agency and the FHWA.

  • RECORDS, INFORMATION AND REPORTS Contractor shall maintain full and accurate records with respect to all matters covered under this Agreement. To the extent permitted by law, County shall have free access at all proper times or until the expiration of four (4) years after the furnishing of services to such records, and the right to examine and audit the same and to make transcripts therefrom, and to inspect all data, documents, proceedings, and activities pertaining to this Agreement. To the extent permitted by law, Contractor shall furnish County such periodic reports as County may request pertaining to the work or services undertaken pursuant to this Agreement. The costs and obligations incurred or to be incurred in connection therewith shall be borne by the Contractor.

  • PAYMENTS AND REPORTS All payments and reports due hereunder shall be made on or before the day such payments and reports are due. Nothing in this paragraph shall be construed to extend the expiration of the primary term hereof. Oil royalty payments and supporting documents shall be submitted prior to the last day of the month following each month's sale of production, and gas royalty payments and supporting documents shall be submitted prior to the last day of the second month following each month's sale of production. All payments shall be made by cash, check, certified check, or money order. Payment having restrictions, qualifications, or encumbrances of any kind whatsoever shall not be accepted by Lessor. A penalty for a late payment shall be charged as set forth in the PENALTIES paragraph herein.

  • Information and Reports The contractor will provide all information and reports required by the Acts, the Regulations, and directives issued pursuant thereto and will permit access to its books, records, accounts, other sources of information, and its facilities as may be determined by the sponsor or the Federal Aviation Administration to be pertinent to ascertain compliance with such Nondiscrimination Acts And Authorities and instructions. Where any information required of a contractor is in the exclusive possession of another who fails or refuses to furnish the information, the contractor will so certify to the sponsor or the Federal Aviation Administration, as appropriate, and will set forth what efforts it has made to obtain the information.

  • BOOKS, RECORDS, AND REPORTS 6 19. The Contractor shall establish and maintain accounts and other books and records 7 pertaining to administration of the terms and conditions of this Settlement Contract, including: 8 the Contractor's financial transactions, water supply data, and Project land and right-of-way 9 agreements; the water users' land-use (crop census), land ownership, land-leasing and water use 10 data; and other matters that the Contracting Officer may require. Reports thereon shall be 11 furnished to the Contracting Officer in such form and on such date or dates as the Contracting 12 Officer may require. Subject to applicable Federal laws and regulations, each party to this 13 Settlement Contract shall have the right during office hours to examine and make copies of each 14 other’s books and official records relating to matters covered by this Settlement Contract.

  • Financial Records and Reports Except as otherwise provided in this Agreement, the Participant’s relevant financial records associated with this Agreement shall not be subject to examination or audit by NASA.

  • Filings and Reports (a) Each year during the term of the Fee Agreement, the Company and any Sponsor Affiliates shall deliver to the County, the County Auditor, the County Assessor and the County Treasurer a copy of their most recent annual filings with the Department with respect to the Project, not later than thirty (30) days following delivery thereof to the Department.

  • Studies and Reports All copies in the Seller’s possession of studies and/or reports which have previously been performed in connection with or for the Property, including without limitation, environmental reports, soils studies, seismic studies, physical inspection reports, site plans and surveys, and identification of such studies of which the Seller is aware but that are not in their possession;

Time is Money Join Law Insider Premium to draft better contracts faster.