Technical Refreshment Sample Clauses

Technical Refreshment. H. 14.1 After contract award, the Government may implement technical refreshment of the contract scope (Section C) and/or the labor categories consistent with the appropriate changes clause in order to improve performance and/or adapt to changes in information technology.
Sample 1Sample 2Sample 3See All (6)
AutoNDA by SimpleDocs
Technical Refreshment. 20.1. After contract award, the Government may implement technical refreshment of the scope and/or the labor categories consistent with FAR 52.212-4 in order to improve performance or react to changes in technology.
Sample 1Sample 2Sample 3See All (5)
Technical Refreshment. After contract award, the Procuring Contracting Officer (PCO) may, pursuant to the FAR Clause 52.243-1, Changes – Fixed Price, Alternate II or FAR Clause 52.243-3, Changes – Time and Materials or Labor Hours, order changes within the scope of the contract to benefit all industry partners, and not a single or subset of industry partners. These changes may be required to improve performance, or react to changes in technology.
Sample 1Sample 2
Technical Refreshment. H.14.1After contract award, the Government may implement technical refreshment of the contract scope (Section C) and/or the labor categories consistent with the appropriate changes clause in order to improve performance and/or adapt to changes in information technology. H.14.2This refreshment includes, but is not limited to, identifying new Emerging Technology-focused information technology solutions as well as removing those activities which have matured to the point where they are no longer considered ET. GSA will consider various industry and Government information sources to identify new ET-focused information technology solutions as they arise and to determine when existing ET activities are no longer considered as ET.
Sample 1
Technical Refreshment. 9.1 The Contractor shall notify the Authority of any technical advances within the relevant industry of which the Contractor becomes aware, which are or may be relevant to any of the Goods supplied under the terms of this agreement. The parties shall review the Technical Specification set out at Appendix A – Technical Specification to this Specification and the other requirements of this Section throughout the Contract Period. So far as possible, the Parties shall seek to ensure continuous improvement and development by agreement, including where appropriate, by means of a Variation to this Section.
Sample 1
Technical Refreshment. The Supplier shall notify the Authority of any technical advances within the relevant industry of which the Supplier becomes aware, which are, or may be, relevant to any of the Goods or Services described in the Specification. The parties shall review the Technical Specification set out in this section throughout the Contract Period. So far as possible, the Parties shall seek to ensure continuous improvement and development by agreement, including where appropriate, by means of a Variation to this Section.
Sample 1
Technical Refreshment. After contract award, the Procuring Contracting Officer (PCO) may, pursuant to the FAR Clause 52.243-1, Changes – Fixed Price, Alternate II or FAR Clause 52.243-3, Changes – Time and Materials or Labor Hours, order changes within the scope of the contract to benefit all industry partners, and not a single or subset of industry partners. These changes may be required to improve performance, or react to changes in technology. (a) The Government may solicit, and the Industry Partner is encouraged to propose independently, improvements to the services, features, or other requirements of the Contract. These improvements may be proposed to save money, to improve performance, or for any other purpose which presents a service advantage to the Government. Those proposed service improvements that are acceptable to the PCO will be processed as modifications to the Contract. (b) As a minimum, the following information shall be submitted by the Industry Partner with each proposal: (1) A description of the difference between the existing Contract and the proposed change, and the comparative advantages and disadvantages of each; (2) Itemized requirements of the Contract which must be changed if the proposal is adopted, and the proposed revision to the Contract for each such change; (3) An estimate of the changes in performance and cost, if any, that will result from adoption of the proposal; (4) An evaluation of the effects that the proposed changes would have on collateral costs to the Government, such as Government-furnished property costs, costs of related items, and costs of maintenance, operation, and conversion (including Government-premise equipment); (5) Any effect on the Contract or TO completion time or delivery schedule shall be identified. (a) The Government will not be liable for proposal preparation costs or any delay in acting upon any proposal submitted pursuant to this clause. The Industry Partner has the right to withdraw, in whole or in part, any proposal not accepted by the Government within the period specified in the proposal. The decision of the PCO as to the acceptance of any such proposal under this Contract is final and not subject to the "Disputes" clause of this Contract. (b) The PCO may accept any proposal submitted pursuant to this clause by giving the Industry Partner written notice thereof. Such changes are intended to benefit the entire industry partner pool, and not a single one, so only engage this process if you want your suggested imp...
Sample 1
AutoNDA by SimpleDocs

Related to Technical Refreshment

  • TECHNICAL EVALUATION (a) Detailed technical evaluation shall be carried out by Purchase Committee pursuant to conditions in the tender document to determine the substantial responsiveness of each tender. For this clause, the substantially responsive bid is one that conforms to all the eligibility and terms and condition of the tender without any material deviation. The Institute’s determination of bid’s responsiveness is to be based on the contents of the bid itself without recourse to extrinsic evidence. The Institute shall evaluate the technical bids also to determine whether they are complete, whether required sureties have been furnished, whether the documents have been properly signed and whether the bids are in order. (b) The technical evaluation committee may call the responsive bidders for discussion or presentation to facilitate and assess their understanding of the scope of work and its execution. However, the committee shall have sole discretion to call for discussion / presentation. (c) Financial bids of only those bidders who qualify the technical criteria will be opened provided all other requirements are fulfilled. (d) AIIMS Jodhpur shall have right to accept or reject any or all tenders without assigning any reasons thereof.

  • Configuration Management The Contractor shall maintain a configuration management program, which shall provide for the administrative and functional systems necessary for configuration identification, control, status accounting and reporting, to ensure configuration identity with the UCEU and associated cables produced by the Contractor. The Contractor shall maintain a Contractor approved Configuration Management Plan that complies with ANSI/EIA-649 2011. Notwithstanding ANSI/EIA-649 2011, the Contractor’s configuration management program shall comply with the VLS Configuration Management Plans, TL130-AD-PLN-010-VLS, and shall comply with the following:

  • Technical Support Services 2.1 The technical support services (the "Services"): Party A agrees to provide to Party B the relevant services requested by Party B, which are specified in Exhibit 1 attached hereto ("Exhibit 1").

  • Technical Regulations 1. The rights and obligations of the Parties in respect of technical regulations, standards and conformity assessment shall be governed by the WTO Agreement on Technical Barriers to Trade. 2. The Parties shall strengthen their co-operation in the field of technical regulations, standards and conformity assessment, with a view to increasing the mutual understanding of their respective systems and facilitating access to their respective markets.

  • Technical Reports All technical reports are to be prepared jointly by the Recipient/Institution conducting Work and all collaborating institutions or as deemed acceptable by the Centre’s contact.

  • Maintenance and Support Services If this Agreement is for IT goods or services, this section applies: Unless otherwise specified in this Agreement: The Contractor shall promptly provide the Court with all Upgrades, including without limitation: (i) all Upgrades generally made available by Contractor to its other customers; (ii) Upgrades as necessary so that the Work complies with the Specifications and Applicable Law (including changes in Applicable Law); (iii) Upgrades as necessary so that the Work operates under new versions or releases of the Court’s operating system or database platform; and (iv) all on-site services necessary for installation of Upgrades. Without limiting any other obligation of Contractor under this Agreement, Contractor represents and warrants that it will maintain services, equipment, software or any other part of the Work so that they operate in accordance with their Specifications and Documentation; and The Contractor shall respond to the Court within four (4) hours after the Court reports a Technical Support Incident (such hours all occurring during Standard M&S Hours) to Contractor. DELIVERY, ACCEPTANCE, AND PAYMENT Delivery. Contractor shall deliver to the Court the Deliverables in accordance with this Agreement, including the Statement of Work. Unless otherwise specified by this Agreement, Contractor will deliver all goods purchased by the Court “Free on Board Destination Freight Prepaid” to the Court at the address and location specified by the Court. Title to all goods purchased by the Court vests in the Court upon payment of the applicable purchase price. Contractor will bear the risk of loss for any Work being delivered until received by the Court at the proper location. All shipments by Contractor or its Subcontractors must include packing sheets identifying: this Agreement number, the Court’s purchase order number, item number, quantity and unit of measure, part number and description of the goods shipped, and appropriate evidence of inspection, if required. Goods for different Agreements shall be listed on separate packing sheets.

  • Quality Management System Supplier hereby undertakes, warrants and confirms, and will ensue same for its subcontractors, to remain certified in accordance with ISO 9001 standard or equivalent. At any time during the term of this Agreement, the Supplier shall, if so instructed by ISR, provide evidence of such certifications. In any event, Supplier must notify ISR, in writing, in the event said certification is suspended and/or canceled and/or not continued.

  • STATEWIDE CONTRACT MANAGEMENT SYSTEM If the maximum amount payable to Contractor under this Contract is $100,000 or greater, either on the Effective Date or at any time thereafter, this section shall apply. Contractor agrees to be governed by and comply with the provisions of §§00-000-000, 00-000-000, 00-000-000, and 00- 000-000, C.R.S. regarding the monitoring of vendor performance and the reporting of contract information in the State’s contract management system (“Contract Management System” or “CMS”). Contractor’s performance shall be subject to evaluation and review in accordance with the terms and conditions of this Contract, Colorado statutes governing CMS, and State Fiscal Rules and State Controller policies.

  • Support Services Rehabilitation, counselling and EAP’s. Support is strictly non- punitive, and can be accessed at anytime (self-identification of the need for help is strongly encouraged).

  • Technology Research Analyst Job# 1810 General Characteristics

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!