THE SCOPE OF THE SERVICE Sample Clauses

THE SCOPE OF THE SERVICE. 1.1 The Service refers to the services and systems that the Licensee through registration on LogTrade’s website xxx.xxxxxxxx.xx (the “Website”) or through the License Agreement has accepted to acquire directly from LogTrade and which can be acquired on and reached by the Licensee’s computer through the Website, or that has been installed on the Licensee’s own server. The Licensee is entitled to support in accordance with the terms provided in these General Terms. 1.2 LogTrade commits to ensure that the Licensee gets access to the Service within reasonable time and to provide the Service during the period of the License Agreement, see Clause 11.1 below. LogTrade aspire to ensure that support is provided for different suppliers. LogTrade is not responsible for all the services of the specified supplier or that the specified functions are supported by the Service at any time. The Licensee must on each occasion control which services and functions at the specified supplier that has support. If the demand from different suppliers changes it might entail that LogTrade changes the existing support for EDI, or other electronic communication, or other for these suppliers, for example by expanding or removing the support. 1.3 Regarding the Licensee’s shipments an agreement is concluded between the Licensee and the respective supplier, which means that LogTrade is not a contracting party and therefore has no responsibility for the execution of these supplier’s services. The Licensee will be liable for any costs that may arise from the supplier. 1.4 LogTrade’s objective is that the Service shall be available for the Licensee via the Internet 24 hours a day and all days of the year. However, the Licensee is aware that LogTrade may have to make arrangements that affect the availability of the Service if and when LogTrade finds it necessary due to technical, maintenance, operational or security-related reasons. If possible LogTrade shall inform the Licensee in advance about planned interruptions in the Service. The Licensee is also aware that the availability to the Internet cannot be guaranteed overall. LogTrade is not liable for potential damages to the Licensee or a third party due to planned or unplanned interruptions in the availability to the Service. LogTrade will always take reasonable precautions to avoid interruptions and to remedy interruptions that have occurred without unnecessary delay. 1.5 LogTrade cannot be held responsible for any damage that might arise...
Sample 1
THE SCOPE OF THE SERVICE. 2.1 The Service consists of a marketplace where Users can transfer/buy a license to use Contributor’s Content.
Sample 1
THE SCOPE OF THE SERVICE. 2.1 The Service is offered as a SaaS service available through the site xxx.xxxxxxxxxxxxxxxx.xxx, tailored sites, or mobile apps. The Service is a technical platform built on both inhouse-developed and open-source machine-learning algorithms that allows users to analyse structured and unstructured data (text, voice, images etc), build models, and visualise results. 2.2 Dcipher is provided as a Software as a Service-solution (SaaS) and local installation is not necessary for using the Service. However, it requires the latest versions of browsers Internet Explorer, Microsoft Edge, Firefox, Chrome or Safari for optimal functionality. Dcipher owns the right to discontinue support for older versions of browsers and mobile operative systems (such as iOS and Android) when updating Dcipher. 2.3 The Customer is granted a non-exclusive and non-transferable Subscription to use the Service. The Subscription may consequently only be used for the specific Customer’s internal purposes and may not be resold. 2.4 The Customer shall use the Site and the Service in accordance with the Agreement, instructions from Dcipher as well as in accordance with applicable law, rules and regulations. You shall furthermore ensure that you and each of your designated Users accept and comply with the Agreement. 2.5 The Customer are responsible for obtaining and maintaining all hardware, software, communications equipment and network infrastructures required to access and use the Site and the Service, as well as paying all third-party fees and access charges incurred while using the Service.
Sample 1

Related to THE SCOPE OF THE SERVICE

  • Scope of the Services UNOPS intends to retain the Contractor for the implementation of the Services, and the Contractor intends to provide the Services. The Contractor has represented to UNOPS that it has the appropriate experience, expertise, licences, and resources to undertake the Services and has agreed to undertake the Services in accordance with the Contract. In reliance on the Contractor’s representations UNOPS has entered into the Contract. The Contract sets out the terms and conditions upon which the Contractor will undertake the Services.

  • SCOPE OF THE CONTRACT The Contractor shall perform the Services set out [in Schedule 1] [below2] in accordance with the Contract. [The Contractor’s key personnel assigned to perform the Services are: [provide a list] During the provision of the Services, if substitution of Contractor’s [key personnel] [experts] is necessary, the Contractor shall propose other experts or at least the same level of qualifications for approval by the Fund. [The Contractor shall obtain the Fund’s prior approval in writing before entering into a subcontract for engaging a subconsultant for the performance of any part of the Services.]

  • Scope of Service Interconnection Service shall be provided to the Interconnection Customer at the Point of Interconnection (a), in the case of interconnection of the Customer Facility of a Generation Interconnection Customer, up to the Maximum Facility Output, and (b), in the case of interconnection of the Customer Facility of a Transmission Interconnection Customer, up to the Nominal Rated Capability. The location of the Point of Interconnection shall be mutually agreed by the Interconnected Entities, provided, however, that if the Interconnected Entities are unable to agree on the Point of Interconnection, the Transmission Provider shall determine the Point of Interconnection, provided that Transmission Provider shall not select a Point of Interconnection that would impose excessive costs on either of the Interconnected Entities and shall take material system reliability considerations into account in such selection. Specifications for the Customer Facility and the location of the Point of Interconnection shall be set forth in an appendix to the Interconnection Service Agreement and shall conform to those stated in the Facilities Study.

  • Service Scope The following Services are covered by this Agreement; o Manned telephone support o Monitored email support o Remote assistance using Remote Desktop and a Virtual Private Network where available o Planned or Emergency Onsite assistance (extra costs apply) o Monthly system health check

  • Attachment A, Scope of Services The scope of services is amended as follows:

  • General Scope of Services Consultant promises and agrees to furnish to the City all labor, materials, tools, equipment, services, and incidental and customary work necessary to fully and adequately supply the services necessary for the Project ("Services"). The Services are more particularly described in Exhibit "A" attached hereto and incorporated herein by reference. All Services shall be subject to, and performed in accordance with, this Agreement, the exhibits attached hereto and incorporated herein by reference, and all applicable local, state and federal laws, rules and regulations.

  • SCOPE OF THE WORK The Contractor shall furnish all the materials, perform all of the Work, and do all things required by the Contract Documents.

  • Performance of the Services In addition to the Common Articles, it is specified that:

  • Scope of Services The specific scope of work for each job shall be determined in advance and in writing between TIPS Member, Member’s design professionals and Vendor. It is permitted for the TIPS Member to provide a general scope description, but the awarded vendor should provide a written scope of work, and if applicable, according to the TIPS Member’s design Professional as part of the proposal. Once the scope of the job is agreed to, the TIPS Member will issue a PO and/or an Agreement or Contract with the Job Order Contract Proposal referenced or as an attachment along with bond and any other special provisions agreed by the TIPS Member. If special terms and conditions other than those covered within this solicitation and awarded Agreements are required, they will be attached to the PO and/or an Agreement or Contract and shall take precedence over those in this base TIPS Vendor Agreement.

  • SCOPE OF SERVICES/CASE HANDLING A. Upon execution by GPM, attorneys are retained to provide legal services for the purpose of seeking damages and other relief in the Litigation. Client provides authorization to seek appointment as Lead Plaintiff in the class action, while the Attorneys will seek to be appointed Class Counsel. If this occurs, the Litigation will be prosecuted as a class action. B. If you obtain access to non-public information during the pendency of the Litigation, you must not engage in transactions in securities. C. Attorneys are authorized to prosecute the Litigation. The appointed Lead Plaintiffs will monitor, review and participate with counsel in the prosecution of the Litigation. The Attorneys shall consult with the appointed Lead Plaintiffs concerning all major substantive matters related to the Litigation, including, but not limited to, the complaint, dispositive motions and settlement. Because of potential differences of opinion between Clients concerning, among other things, strategy, goals and objectives of the Litigation, the Attorneys shall consult with the appointed Lead Plaintiffs as to the courses of action to pursue. The Client agrees to abide by the decisions of the appointed Lead Plaintiffs, which shall be final and binding on all Clients. D. GPM is given the authority to opt the Client out of any class action proceeding relating to the claims authorized herein and/or pursue the Client claim individually in a group action, if the Client is not appointed Lead Plaintiff and GPM is not appointed Class Counsel. E. The Attorneys shall provide sufficient resources, including attorney time and capital for payment of costs and expenses, to vigorously prosecute the Litigation. F. Any recovery from defendants that the Attorneys are responsible for will be divided among class members based on the recognized loss by each class member as calculated by a damage allocation plan which will be prepared by a financial expert or consultant, provided to the appointed Lead Plaintiffs, be subject to the Court's approval and will account for such factors as size of securities ownership, date of purchase, date of sale and continued holdings, if any. Under the rules governing class action litigation, while the Lead Plaintiffs recover according to the same formula as other class members, the Court may approve, upon application therefore, reimbursement of the Lead Plaintiffs’ reasonable costs and expenses directly related to the representation of the class. Examples are lost wages and travel expenses associated with testifying in the action.