Tenant Delay as used in the Lease or this Agreement shall mean any delay that Landlord may encounter in the performance of Landlord’s obligations under the Lease or this Agreement because of any act or omission of any nature by Tenant or its agents or contractors, including any: (1) delay attributable to changes in or additions to the Approved Plans or to the Landlord’s Work requested by Tenant; (2) delay attributable to the postponement of any Landlord’s Work at the request of Tenant; (3) delay caused by a Change Order requested by Tenant; (4) delay attributable to the failure of Tenant to pay, when due, any amounts required to be paid by Tenant pursuant to the Lease; or (5) delay attributable to a failure of Tenant to employ union labor for Tenant’s work at the Premises during the time the Landlord’s Work is being constructed. Tenant shall pay all actual costs and expenses incurred by Landlord which result from any Tenant Delay and the Commencement Date of the Lease shall be accelerated one (1) day for each day the Premises is not Ready for Occupancy as a result of a Tenant Delay. No Tenant Delay shall be deemed to have occurred unless Landlord gives Tenant prior written notice or written notice within five (5) days of the occurrence, as reasonable under the circumstances, specifying the claimed reasons for such Tenant Delay, and Tenant shall fail to promptly correct or cure such Tenant Delay. There shall be excluded from the number of days of any Tenant Delay, or any of the following events of force majeure: labor disputes, fire, unusual delay in transportation, adverse weather conditions not reasonably anticipatable, unavoidable casualties, delays in obtaining permits or governmental approvals or any other causes beyond Landlord’s or its contractor’s reasonable control (and other than for financial reasons) (collectively, “Force Majeure Delays”).
Tenant Delays means delays caused by: (i) requirements of the Plans and Specifications requested by Tenant that do not conform to Landlord’s building standards for office and lab build-out, or which contain long lead-time or non-standard items requested by Tenant; provided that Landlord has notified Tenant of such deviations upon execution of this Lease (ii) any material change in the Plans and Specifications requested by Tenant and agreed to by Landlord; (iii) any request by Tenant for a delay in the commencement or completion of the Initial Tenant Improvements for any reason; (iv) Tenant delay in finalizing and approving the design of the vivarium and value engineering of same or (v) any other act or omission of Tenant or its employees, agents or contractors which reasonably inhibits the Landlord from timely completing the Initial Tenant Improvements including, without limitation any delays caused by Tenant’s presence in the Premises prior to the Term Commencement Date. The Premises shall not be deemed to be incomplete if only minor or insubstantial details of construction, decoration or mechanical adjustments remain to be done which do not unreasonably interfere with Tenant’s occupancy of the Premises. If as a result of Tenant Delays the Premises are deemed ready for Tenant’s occupancy, pursuant to the foregoing (and the term shall have commenced by reason thereof), but the Premises are not in fact actually ready for Tenant’s occupancy, Tenant shall not (except with Landlord’s consent not to be unreasonably withheld, conditioned or delayed) be entitled to take possession of the Premises for the permitted use until the Premises are in fact actually ready for such occupancy.
Force Majeure Delay means with respect to the Servicer, any cause or event which is beyond the control and not due to the negligence of the Servicer, which delays, prevents or prohibits such Person’s delivery of the reports required to be delivered or the performance of any other duty or obligation of the Servicer under the Indenture, as the case may be, including, without limitation, computer, electrical and mechanical failures, acts of God or the elements and fire; provided, that no such cause or event shall be deemed to be a Force Majeure Delay unless the Servicer shall have given the Indenture Trustee written notice thereof as soon as practicable after the beginning of such delay.
Landlord Delay shall occur if either: (i) Landlord fails to complete the Base Building and/or other improvements on the Project that are required by the DDA, the Parking REA and/or the CC&Rs, and as a direct result of such failure Tenant is unable to obtain a temporary or permanent certificate of occupancy for the Premises upon substantial completion of the Tenant Improvements; or (ii) substantial completion of the Warm Shell Improvements or Tenant Improvements is delayed directly and solely as a result of any of the following and such delay could not have been mitigated by Tenant using commercially reasonable measures, which delay occurs after the Delivery Date and before the Commencement Date and does not result from Tenant's interference or delay in connection with completion of the Tenant Improvements or after a Tenant Default or Work Letter Draw Event: (a) subject to Paragraph 8 above, unreasonable interference by Landlord or Landlord's Contractor with the construction of the Warm Shell Improvements or the Tenant Improvements; (b) Landlord's failure to comply with any deadlines for response to, or submissions from, Tenant as required by this Work Letter; (c) any material Discretionary Changes to Landlord's Plans or the Warm Shell Plans after their final approval by applicable governmental entities (other than Tenant Modifications) that directly affect Tenant's Plans or the Tenant Improvements; and/or (d) Landlord failure to complete portions of the Base Building and/or other improvements on the Project that are Landlord's obligation to complete hereunder, and as a direct result of such failure Tenant and Tenant's contractors do not have access to the Premises to the extent required to complete the Warm Shell Improvements and/or Tenant Improvements. Tenant shall give Landlord at least five (5) days prior notice if Tenant becomes aware that Landlord is in danger of causing a Landlord Delay, and if Landlord takes appropriate measures to prevent such delay within such five (5) day period, no adjustment to the Commencement Date shall be made on account of such Landlord; provided, however, that if such delay was not reasonably foreseeable by Tenant, the five (5) day period for prior notice and opportunity to mitigate provided above shall be changed to forty-eight (48) hours after Tenant becomes aware of such delay or potential delay.
Force Majeure Delays means any actual delay in the construction of the Tenant Improvements, which is beyond the reasonable control of Landlord or Tenant, as the case may be, as described in Paragraph 33 of the Lease.
Excusable Delay means a delay due to acts of God, governmental restrictions, stays, judgments, orders, decrees, enemy actions, civil commotion, fire, casualty, strikes, work stoppages, shortages of labor or materials or other causes beyond the reasonable control of Borrower, but lack of funds in and of itself shall not be deemed a cause beyond the control of Borrower.
Developmental delay means that a child has not reached developmental milestones expected for his or her chronological age as measured by qualified professionals using appropriate diagnostic instruments and/or procedures.
Construction Budget means the fully-budgeted costs for the acquisition and construction of a given parcel of real property (including, without limitation, the cost of acquiring such parcel of real property, reserves for construction interest and operating deficits, tenant improvements, leasing commissions, and infrastructure costs) as reasonably determined by the Parent in good faith.
Excusable Delays means delays due to acts of terrorism, acts of war or civil insurrection, strikes, riots, floods, earthquakes, fires, tornadoes, casualties, acts of God, labor disputes, governmental restrictions or priorities, embargoes, national or regional material shortages, failure to obtain regulatory approval from any Federal or State regulatory body, unforeseen site conditions, extraordinary rainfall or snowfall, or any other condition or circumstances beyond the reasonable or foreseeable control of the applicable Party using reasonable diligence to overcome which prevents such Party from performing its specific duties or obligation hereunder in a timely manner; provided, however, Excusable Delay does not include lack of financing, unanticipated or unexpected increases in the costs of construction, or errors in business judgment by a Party; and provided further that Excusable Delay shall only extend the time of performance for the period of such Excusable Delay, which shall begin on the date which the event of Excusable Delay first occurs and extend until the date which the event which has caused the Excusable Delay has been corrected or performed, or reasonably should have been corrected or performed.
Construction Work means any work in connection with⎯
Allowed Delay has the meaning set forth in Section 2(c)(ii).
Permit revision means any permit modification or administrative permit amendment.
Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:
Landlord’s Work means the work of constructing the Tenant Improvements.
Additional Work to mean additions or deletions or modifications to the amount, type or value of the Work and Services as required in this Contract, as directed and/or approved by the County.
demolition work means a method to dismantle, wreck, break, pull down or knock down of a structure or part thereof by way of manual labour, machinery, or the use of explosives;
Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.
Construction Commencement Date means the date set out in the Addendum, if applicable, by which you must commence construction of the Hotel. For the Hotel to be considered under construction, youmust have begun to pour concrete foundations for the Hotel or otherwise satisfied any site-specific criteria for “under construction” set out in the Addendum.
Substantial Completion Date means the date on which Substantial Completion occurs.
Construction project means the same as that term is defined in Section 38-1a-102.
Phase I Environmental Assessment A “Phase I assessment” as described in, and meeting the criteria of, the ASTM, plus a radon and asbestos inspection.
tidal work means so much of any work authorised by this Order as is on, under or over tidal waters or tidal lands below the level of high water;
Construction Change Directive means a written order prepared by Owner Parties and signed by Owner directing Contractor to perform a change in the Work prior to agreeing to a change, if any, to the Contract Time, schedule of performance of the Work, Contract Sum, or Contractor’s compensation.
Unavoidable Delay means an event which delays Closing which is a strike, fire, explosion, flood, act of God, civil insurrection, act of war, act of terrorism or pandemic, plus any period of delay directly caused by the event, which are beyond the reasonable control of the Vendor and are not caused or contributed to by the fault of the Vendor. “Unavoidable Delay Period” means the number of days between the Purchaser’s receipt of written notice of the commencement of the Unavoidable Delay, as required by paragraph 5(b), and the date on which the Unavoidable Delay concludes.
Construction Phase means that Phase of the Project which shall commence after the Authority provides the Trade Contractor with written Notice to Proceed with the Construction Phase.
Project Completion Date means the date on which the Completion Certificate is issued;