Construction Management Plan Contractor shall prepare and furnish to the Owner a thorough and complete plan for the management of the Project from issuance of the Proceed Order through the issuance of the Design Professional's Certificate of Material Completion. Such plan shall include, without limitation, an estimate of the manpower requirements for each trade and the anticipated availability of such manpower, a schedule prepared using the critical path method that will amplify and support the schedule required in Article 2.1.5 below, and the Submittal Schedule as required in Article 2.2.3. The Contractor shall include in his plan the names and resumés of the Project Superintendent, Project Manager and the person in charge of Safety.
Configuration Management The Contractor shall maintain a configuration management program, which shall provide for the administrative and functional systems necessary for configuration identification, control, status accounting and reporting, to ensure configuration identity with the UCEU and associated cables produced by the Contractor. The Contractor shall maintain a Contractor approved Configuration Management Plan that complies with ANSI/EIA-649 2011. Notwithstanding ANSI/EIA-649 2011, the Contractor’s configuration management program shall comply with the VLS Configuration Management Plans, TL130-AD-PLN-010-VLS, and shall comply with the following:
Construction Management Landlord or its Affiliate or agent shall supervise the Work, make disbursements required to be made to the contractor, and act as a liaison between the contractor and Tenant and coordinate the relationship between the Work, the Building and the Building’s Systems. In consideration for Landlord’s construction supervision services, Tenant shall pay to Landlord a construction supervision fee equal to three percent (3%) of Tenant’s Costs specified in Section 7.
Construction Management Fee The Construction Management Fee for the Project shall be either a ☒Lump Sum or ☐Not-To-Exceed Fee of Thirty-Six Thousand, Eight Hundred Forty-Six Dollars and Twenty-Six Cents ($36,846.26). NOTE: Allowances will be on a Not-To-Exceed basis. All unused funds will be returned to the School District at the time of construction closeout. Fee will be paid only on cost of work for these items. Exhibit C- Project Assignment Page 2 of 4
Construction Drawings After approving the Additional Programming Information, Landlord shall cause the Architect and the Engineers to prepare and deliver to Tenant Construction Drawings that conform to the approved Space Plan and the approved Additional Programming Information. Such preparation and delivery shall occur within 15 business days after the later of Landlord’s approval of the Additional Programming Information or the mutual execution and delivery of this Agreement. Tenant shall approve or disapprove the Construction Drawings by notice to Landlord. If Tenant disapproves the Construction Drawings, Tenant’s notice of disapproval shall specify any revisions Tenant desires in the Construction Drawings. After receiving such notice of disapproval, Landlord shall cause the Architect and/or the Engineers to revise the Construction Drawings, taking into account the reasons for Tenant’s disapproval (provided, however, that Landlord shall not be required to cause the Architect or the Engineers to make any revision to the Construction Drawings that is inconsistent with the Landlord Requirements or that Landlord otherwise reasonably disapproves), and resubmit the Construction Drawings to Tenant for its approval. Such revision and resubmission shall occur within five (5) business days after the later of Landlord’s receipt of Tenant’s notice of disapproval or the mutual execution and delivery of this Agreement if such revision is not material, and within such longer period of time as may be reasonably necessary (but not more than 15 business days after the later of such receipt or such mutual execution and delivery) if such revision is material. Such procedure shall be repeated as necessary until Tenant has approved the Construction Drawings. The Construction Drawings approved by Landlord and Tenant are referred to in this Work Letter as the “Approved Construction Drawings”.
Professional Fees Borrower promises to pay Lender’s fees and expenses necessary to finalize the loan documentation, including but not limited to reasonable attorneys fees, UCC searches, filing costs, and other miscellaneous expenses. In addition, Borrower promises to pay any and all reasonable attorneys’ and other professionals’ fees and expenses (including fees and expenses of in-house counsel) incurred by Lender after the Closing Date in connection with or related to: (a) the Loan; (b) the administration, collection, or enforcement of the Loan; (c) the amendment or modification of the Loan Documents; (d) any waiver, consent, release, or termination under the Loan Documents; (e) the protection, preservation, sale, lease, liquidation, or disposition of Collateral or the exercise of remedies with respect to the Collateral; (f) any legal, litigation, administrative, arbitration, or out of court proceeding in connection with or related to Borrower or the Collateral, and any appeal or review thereof; and (g) any bankruptcy, restructuring, reorganization, assignment for the benefit of creditors, workout, foreclosure, or other action related to Borrower, the Collateral, the Loan Documents, including representing Lender in any adversary proceeding or contested matter commenced or continued by or on behalf of Borrower’s estate, and any appeal or review thereof.
Bidding Phase 2.8.1 The Professional, following the Owner's approval of the Construction Document Phase, shall assist the Owner in obtaining bids and in award and preparation of Construction Contracts.
2.8.2 The Professional shall attend the bid opening and furnish a suitably detailed tabulation sheet for recording the name of each Bidder, the Bidder's Certificate of Responsibility Number, Bid Security, Base Bid, Alternates, and remarks. The Professional shall furnish sufficient tabulation sheets for all in attendance. Immediately after receipt of bids, the Professional shall submit to the Owner a certified tabulation of all bids received, along with his recommendation as to Contract award.
2.8.3 The Professional, following the award of a Construction Contract, shall prepare and submit to the Owner, two (2) copies of updated Construction Documents (Plans/Specifications). Each copy shall be marked OFFICIAL CONTRACT DOCUMENTS and shall include an executed bid Proposal Form, Agreement Form, Contract Bond, Power of Attorney, Certificate of Insurance, all bulletins, Addenda, and supplemental Drawings. One (1) copy shall be retained by the Owner, one (1) copy shall be for the Contractor. Any other contract document guidelines will be distributed to the Professional at the bid opening.
2.8.4 The Professional shall also furnish the area and volume of the building computed in accordance with criteria of the American Institute of Architects; and the square foot and cubic foot costs of only the building, the mechanical system, the electrical system, special built-in equipment, and the total Project cost.
2.8.5 The Professional shall, unless waived by the Owner, also submit one electronic format copy of the updated Contract Documents (plans and specifications) in coordination with said Contract Documents in 2.8.3 above. Said electronic submittal to be submitted within thirty (30) days after award by Owner in .pdf format. The actual cost of the electronic submittal shall be paid by the Owner, with cost approval by the Owner before printing is ordered in accordance with 3.4.
Project Implementation Manual The Recipient, through the PCU, shall: (i) take all action required to carry out Parts 1.1, 1.3, 1.4, 2, 3.1(b), 3.2, 3.3 and 4 (ii) of the Project in accordance with the provisions and requirements set forth or referred to in the Project Implementation Manual; (ii) submit recommendations to the Association for its consideration for changes and updates of the Project Implementation Manual as they may become necessary or advisable during Project implementation in order to achieve the objective of Parts 1.1, 1.3, 1.4, 2, 3.1(b), 3.2, 3.3 and 4(ii) of the Project; and (iii) not assign, amend, abrogate or waive the Project Implementation Manual or any of its provisions without the Association’s prior agreement. Notwithstanding the foregoing, if any of the provisions of the Project Implementation Manual is inconsistent with the provisions of this Agreement, the provisions of this Agreement shall prevail and govern.
Site Preparation Axon will provide a hardcopy or digital copy of current user documentation for the Axon Devices ("User Documentation"). User Documentation will include all required environmental specifications for the professional services and Axon Devices to operate per the Axon Device User Documentation. Before installation of Axon Devices (whether performed by Customer or Axon), Customer must prepare the location(s) where Axon Devices are to be installed ("Installation Site") per the environmental specifications in the Axon Device User Documentation. Following installation, Customer must maintain the Installation Site per the environmental specifications. If Axon modifies Axon Device User Documentation for any Axon Devices under this Agreement, Axon will provide the update to Customer when Axon generally releases it
Class Counsel Fees include the fees, disbursements, costs, interest, GST or HST (as the case may be) and other applicable taxes or charges thereon, including any amounts payable by Class Counsel or the Settlement Class Members to any other body or Person as a result of the Settlement Agreement, including the Fonds d’aide aux actions collectives in Québec.
