Framework Agreement 4.1.2.1 The Parties shall enter into a Framework Agreement within 28 days after the Contractor receives the Letter of Acceptance, unless the Particular Conditions establish otherwise. The Framework Agreement shall be based upon FORM No. 3 – FRAMEWORK AGREEMENT annexed to the Particular Conditions. The costs of stamp duties and similar charges (if any) imposed by law in connection with entry into the Framework Agreement shall be borne by the Procuring Entity.
MUTUAL AGREEMENT PROCEDURES 1. Where difficulties or doubts arise between the Parties regarding the implementation or interpretation of this Agreement, the respective competent authorities shall use their best efforts to resolve the matter by mutual agreement.
Agreement Scope The scope of this Agreement is as prescribed in section 46 of the Act, setting out: • the health services to be provided to the State by the HSP, • the TTR in support of the health services to be provided, • the funding to be provided to the HSP for the provision of the health services, including the way in which the funding is to be provided, • the performance measures and operational targets for the provision of the health services by the HSP, • how the evaluation and review of results in relation to the performance measures and operational targets is to be carried out, • the performance data and other data to be provided by the HSP to the Department CEO, including how, and how often, the data is to be provided, and • any other matter the Department CEO considers relevant to the provision of the health services by the HSP. Where appropriate, reference will be made in this Agreement to Policy Frameworks issued by the Department CEO pursuant to Part 3, Division 2 of the Act.
Contract Modification The conditions of this timber sale are completely set forth in this contract. Except as provided in B8.32 and B8.33, this contract can be modified only by written agreement between the parties. Only Contracting Officer may make contract modifications, with compensating adjustments to Current Contract Rates where appropriate, on behalf of Forest Service.
Cooperation Agreement At the Closing, PCC and Buyer shall, and PCC shall cause PCC Parent to, execute and deliver the Cooperation Agreement pursuant to which Buyer, PCC Parent and PCC shall provide each other certain information and other assistance in connection with the collection, administration and/or satisfaction of certain of the Retained Liabilities.
ARTICULATION AGREEMENT FOLLOW-UP PROCEDURES
Interconnection Agreement On or before December 31, 2015, Wholesale Market Participant must enter into an Interconnection Agreement with the Transmission Owner in order to effectuate the WMPA. Wholesale Market Participant shall demonstrate the occurrence of each of the foregoing milestones to Transmission Provider’s reasonable satisfaction. Transmission Provider may reasonably extend any such milestone dates, in the event of delays that Wholesale Market Participant (i) did not cause and (ii) could not have remedied through the exercise of due diligence. If (i) the Wholesale Market Participant suspends work pursuant to a suspension provision contained in an interconnection and/or construction agreement with the Transmission Owner or (ii) the Transmission Owner extends the date by which Wholesale Market Participant must enter into an interconnection agreement relative to this WMPA, and (iii) the Wholesale Market Participant has not made a wholesale sale under this WMPA, the Wholesale Market Participant may suspend this WMPA by notifying the Transmission Provider and the Transmission Owner in writing that it wishes to suspend this WMPA, with the condition that, notwithstanding such suspension, the Transmission System shall be left in a safe and reliable condition in accordance with Good Utility Practice and Transmission Provider’s safety and reliability criteria. Wholesale Market Participant’s notice of suspension shall include an estimated duration of the suspension period and other information related to the suspension. Pursuant to this section 3.1, Wholesale Market Participant may request one or more suspensions of work under this WMPA for a cumulative period of up to a maximum of three years. If, however, the suspension will result in a Material Modification as defined in Part I, Section 1.18A.02 of the Tariff, then such suspension period shall be no greater than one (1) year. If the Wholesale Market Participant suspends this WMPA pursuant to this Section 3.1 and has not provided written notice that it will exit such suspension on or before the expiration of the suspension period described herein, this WMPA shall be deemed terminated as of the end of such suspension period. The suspension time shall begin on the date the suspension is requested or on the date of the Wholesale Market Participant’s written notice of suspension to Transmission Provider, if no effective date was specified. All milestone dates stated in this Section 3.1 shall be deemed to be extended coextensively with any suspension period permitted pursuant to this provision.
Agreement Modification 15.1 Any agreement to change the terms of this Agreement in any way shall be valid only if the change is made in writing and approved by mutual agreement of authorized representatives of the parties hereto.
Agreement Xxx 0000 Part 3 Provisions relating to Balmoral South Iron Ore Project and certain other matters Division 2 Main provisions s. 14
MUTUAL AGREEMENT PROCEDURE 1. Where a person considers that the actions of one or both of the Contracting States result or will result for him in taxation not in accordance with the provisions of this Agreement, he may, irrespective of the remedies provided by the domestic law of those States, present his case to the competent authority of the Contracting State of which he is a resident or, if his case comes under paragraph 1 of Article 24, to that of the Contracting State of which he is a national. The case must be presented within three years from the first notification of the action resulting in taxation not in accordance with the provisions of the Agreement.
