Claims/Disputes. Any dispute relative to the adjudication of any insurance claim shall be between the insured individual and the insurance carrier or third-party claims administrator and shall not involve the District (without its consent) nor create any liability whatsoever for the District.
Claims/Disputes. All claims or disputes arising out of or under this Agreement shall be governed by the terms of the Standard Contract Provisions (Exhibit G).
Claims/Disputes. Each Indemnified Person shall give the Company prompt written notice (an “Indemnification Notice”) of any third party Action it has actual knowledge of that might give rise to Losses, which notice shall set forth a description of those elements of such Action of which such Indemnified Person has knowledge; provided, that any delay or failure to give such Indemnification Notice shall not affect the indemnification obligations of the Company hereunder except to the extent the Company is materially prejudiced by such delay or failure.
Claims/Disputes. In the event of any demand by Contractor for (A) a time extension, including, without limitation, for relief from damages or penalties for delay assessed by the District under the Agreement, (B) payment by the District of money or damages arising from work done by, or on behalf of, the Contractor pursuant to the Agreement and payment of which is not otherwise expressly provided for or to which Contractor is not otherwise entitled to, or (C) an amount of payment disputed by the District, the parties shall attempt to resolve the dispute by those procedures set forth in Public Contract Code section 9204 and/or Article 1.5 (commencing with section 20104) of Chapter 1, Part, 3, Division 2, of the Public Contract Code, if applicable, the provisions of which are each attached hereto and incorporated herein by this reference. If a claim, or any portion thereof, remains in dispute upon satisfaction of all applicable dispute resolution requirements, the Contractor shall comply with all claims presentation requirements as provided in Chapter 1 (commencing with section 900) and Chapter 2 (commencing with section 910) of Part 3 of Division 3.6 of Title 1 of Government Code as a condition precedent to the Contractor’s right to bring a civil action against the District. For purposes of those provisions, the running of the time within which a claim must be presented to the District shall be tolled from the time the Contractor submits its written claim until the time the claim is denied, including any time utilized by any applicable meet and confer process. Pending resolution of the dispute, Contractor and its subcontractors shall continue to perform the Work under the Agreement and shall not cause a delay of the Work during any dispute, claim, negotiation, mediation, or arbitration proceeding, except by written agreement of the District.
Claims/Disputes. The Contractor agrees to prosecute the work continuously and diligently and that compensation or extension of time resulting from delays, not the fault of the Contractor shall be settled by agreement with City Purchasing Agent or his/her designee. The City Purchasing Agent or his/her designee shall in all cases determine the amount or quantity and acceptability of the work and materials which are to be paid for under the Agreement, shall decide all questions in relation to said work and the performance thereof, and shall, in all cases, decide questions which may arise relative to the fulfillment of the Agreement or to the obligations of the Contractor thereunder. To prevent disputes and litigation, where the Contractor is not satisfied with the decision of the City Purchasing Agent or his/her designee, the Contractor shall submit the claim to the Board of Estimates of Baltimore City, which will decide any dispute between the Contractor and the City, and its determination, decision and/or estimate shall be a condition precedent to the right of the Contractor to receive any monies under the Agreement, and is subject to review on the record by a court of competent jurisdiction.
Claims/Disputes. A. Any claims by Contractor relating to this Agreement, must be submitted to the NYSEG/RG&E in writing within fourteen (14) calendar days of initial occurrence of the basis for the claim. Failure to provide such notification shall be deemed waiver of such claim.
B. The notice of claim shall include the particulars and shall specify the cause or other basis of the claim, and shall include substantiation of the amount and/or extension to which the Contractor considers itself to be entitled in connection with the Agreement.
C. The Parties agree to hold a meeting promptly to attempt in good faith to negotiate a resolution of the dispute, such meeting to be attended by representatives of the Parties with decision-making authority regarding the dispute. If, within twenty-one (21) days after such meeting, the Parties have not succeeded in negotiating a resolution of the dispute, either Party may refer the dispute to a court under Article 19 which is to be the sole legally binding forum available to the Parties for resolution of a dispute hereunder.
Claims/Disputes or controversies concerning the validity, construction, or effect of any patent licensed hereunder shall be resolved in any court having jurisdiction thereof.
Claims/Disputes. 13.1 If required the Managers shall handle and settle claims arising out of the Management Services hereunder and keep the Owners informed regarding any incident of which the Managers become aware which gives or may give rise to claims or disputes involving third parties.
13.2 The Managers shall, as instructed by the Owners, bring or defend actions, suits or proceedings in connection with matters entrusted to the Managers according to this Agreement.
13.3 The Managers shall have power to obtain legal or technical or other outside expert advice in relation to the handling and settlement of claims and disputes or all other matters affecting the interests of the Owners in respect of the Vessel.
13.4 The Owners shall pay to the Managers a fee for time spent by the Managers in carrying out their obligations under Clause 13 and such fee shall be charged at the rate of US$850 per man per day of 8 hours. Where the Approved Broker has been appointed pursuant to Clause 3.4 for the placing of insurances no additional fee will be charged for insurance claims handling. In addition any costs incurred by the Managers in carrying out their obligations according to Clause 13 shall be reimbursed by the Owners.
13.5 The Owners acknowledge that the Managers use MTI Network for crisis management response and agree to reimburse any fees additional to the annual retainer of MTI Network (as included in the budget) which may be incurred.
Claims/Disputes. In accordance with Section 2.2-4363, VA Code Xxx., this provision shall be followed for consideration and handling of all claims by the Contractor under this contract. Section 2.2-4365, VA Code Xxx., is not applicable to this Contract, and under no circumstances is this paragraph to be construed as an administrative appeals procedure governed by Section 2.2-4365, VA Code Xxx. Notice of the intent to submit a claim setting forth the basis for any claim shall be submitted in writing within ten (10) days after the II.5 (Continued) occurrence of the event giving rise to the claim, or within ten (10) days of discovering the condition giving rise to the claim, whichever is later. In no event, shall any claim arising out of this Contract be filed after the submission of the request for Final Payment by the Contractor. Claims by the Contractor with respect to this Contract shall be submitted in writing in the first instance for consideration by the Contract Administrator. The decision of the Contract Administrator shall be rendered in writing within forty-five (45) days from the receipt of the claim from the Contractor. If the Contractor is not satisfied with the decision or resolution of the Contract Administrator, the Contractor may file a formal dispute with regards to the claim with the Prince Xxxxxxx County Director of Finance, which claim shall be received within thirty (30) days of the date of decision of the Contract Administrator. The Director of Finance shall reduce his or her decision to writing and shall mail or otherwise furnish a copy of this decision to the Contractor within forty-five (45) days of the receipt of the claim from the Contractor. The decision of the Director of Finance shall be final on behalf of Prince Xxxxxxx County unless the Contractor submits the claim to the County Executive within thirty (30) days of the Director of Finance's decision. The Contractor may submit the claim to the County Executive by mailing or otherwise furnishing the Purchasing Manager a copy of the claim and a request for the County Executive's determination. The County Executive's decision on the claim shall be rendered in writing to the Contractor within forty-five (45) days of the Purchasing Manager's receipt of the request from the Contractor, and shall be final and binding on behalf of Prince Xxxxxxx County, unless the Contractor submits the claim for determination by the Board of County Supervisors by mailing or otherwise furnishing the Purchasing Manager ...
Claims/Disputes. A. Any claims by Supplier relating to this Agreement, must be submitted to the Customer in writing within fourteen (14) calendar days of initial occurrence of the basis for the claim. Failure to provide such notification shall be deemed waiver of such claim.
B. The notice of claim shall include the particulars and shall specify the cause or other basis of the claim, and shall include substantiation of the amount and/or extension to which the Supplier considers itself to be entitled in connection with the Agreement.
C. dispute or claims by the Supplier shall not affect the diligent prosecution by Supplier of the Services.
D. The Parties agree to hold a meeting promptly to attempt in good faith to negotiate a resolution of the dispute, such meeting to be attended by representatives of the Parties with decision-making authority regarding the dispute. If, within twenty-one (21) days after such meeting, the Parties have not succeeded in negotiating a resolution of the dispute, either Party may refer the dispute to a court under Article 41 which is to be the sole legally binding forum available to the Parties for resolution of a dispute hereunder.
