Construction Planning Meeting Sample Clauses

Construction Planning Meeting. 5.1.1. Within ten (10) Business Days of receipt of the Facility Study report, the Interconnection Customer shall request a Construction Planning Meeting, where failure to comply shall result in the Interconnection Request being deemed withdrawn. The Construction Planning Meeting request shall be in writing and shall include the Interconnection Customer’s reasonably requested date for completion of the construction of the Upgrades and Interconnection Facilities. 5.1.2. The Construction Planning Meeting shall be scheduled within ten (10) Business Days of the Section 5.1.1 request from the Interconnection Customer, or as otherwise mutually agreed to by the parties. 5.1.3. The purpose of the Construction Planning Meeting is to identify the tasks for each party and discuss and determine the milestones for the construction of the Upgrades and Interconnection Facilities. Agreed upon milestones shall be specific as to scope of action, responsible party, and date of deliverable and shall be recorded in the Interconnection Agreement (see Appendix 4 to Attachment 10) to be developed by the utility and provided to Interconnection Customer pursuant to Section 5.2.1 below.
Sample 1Sample 2Sample 3See All (10)
AutoNDA by SimpleDocs
Construction Planning Meeting. 5.1.1. Within ten (10) Business Days of receipt of the Facilities Study Report, the Interconnection Customer shall request a Construction Planning Meeting, where failure to comply shall result in the Interconnection Request being deemed withdrawn. The Construction Planning Meeting request shall be in writing and shall include the Interconnection Customer’s reasonably requested date for completion of the construction of the Upgrades and Interconnection Facilities. 5.1.2. The Construction Planning Meeting shall be scheduled within ten (10) Business Days of the Section 5.1.1 request from the Interconnection Customer, or as otherwise mutually agreed to in writing by the parties. 5.1.3. The purpose of the Construction Planning Meeting is to identify the tasks for each party and discuss and determine the milestones for the construction of the Upgrades and Interconnection Facilities. Agreed upon milestones shall be specific as to scope of action, responsible party, and date of deliverable and shall be recorded in the Interconnection Agreement (see Appendix 4 to Attachment 9) to be provided to Interconnection Customer pursuant to Section 5.2.1 below. 5.1.4. If the Utility cannot complete the installation of the required Upgrades and Interconnection Facilities within two (2) months of the Interconnection Customer’s reasonably requested In-Service Date, the Interconnection Customer shall have the option of payment for work outside of normal business hours or hiring a Utility-approved subcontractor to perform the distribution Upgrades. Any Utility-approved subcontractor performance remains subject to Utility oversight during construction. The Utility shall make a list of Utility-approved subcontractors available to the Interconnection Customer promptly upon request.
Sample 1Sample 2See All (7)
Construction Planning Meeting. 5.1.1 Within ten (10) Business Days of receipt of the Facility Study report, the Interconnection Customer shall request a Construction Planning Meeting, where failure to comply shall result in the Interconnection Request being deemed withdrawn. The Construction Planning Meeting request shall be in writing and shall include the Interconnection Customer’s reasonably requested date for completion of the construction of the Upgrades and Interconnection Facilities.
Sample 1Sample 2
Construction Planning Meeting. 5.1.1 Within ten (10) Business Days of receipt of the Facilities Study Report, the Interconnection Customer shall request a Construction Planning Meeting, where failure to comply shall result in the Interconnection Request being deemed withdrawn. The Construction Planning Meeting request shall be in writing and shall include the Interconnection Customer’s reasonably requested date for completion of the construction of the Upgrades and Interconnection Facilities. 5.1.2 Where a Utility administers a Definitive Interconnection Study Process, all Interconnection Customers must also satisfy the requirements of Readiness Milestone 4 (M4) within ten (10) Business Days of receipt of the Facilities Study Report. Interconnection Customers that do not provide M4 (or provide security in lieu of the Readiness Milestone by the required date) shall be deemed withdrawn from the Queue and be subject to a Withdrawal Penalty pursuant to Sections 6.3.4. 5.1.3 The Construction Planning Meeting shall be scheduled within ten (10) Business Days of the Section 5.1.1 request from the Interconnection Customer, or as otherwise mutually agreed to in writing by the parties. 5.1.4 The purpose of the Construction Planning Meeting is to identify the tasks for each party and discuss and determine the milestones for the construction of the Upgrades and Interconnection Facilities. Agreed upon milestones shall be specific as to scope of action, responsible party, and date of deliverable and shall be recorded in the Interconnection Agreement (see Appendix 4 to Attachment 9) to be provided to Interconnection Customer pursuant to Section 5.2.1 below. 5.1.5 If the Utility cannot complete the installation of the required Upgrades and Interconnection Facilities within two (2) months of the Interconnection Customer’s reasonably requested In-Service Date, the Interconnection Customer shall have the option of payment for work outside of normal business hours or hiring a Utility-approved subcontractor to perform the distribution Upgrades. Any Utility-approved subcontractor performance remains subject to Utility oversight during construction. The Utility shall make a list of Utility-approved subcontractors available to the Interconnection Customer promptly upon request.
Sample 1Sample 2
Construction Planning Meeting. 5.1.1 Within ten (10) Business Days of receipt of the FacilityFacilities Study reportReport, the Interconnection Customer shall request a Construction Planning Meeting, where failure to comply shall result in the Interconnection Request being deemed withdrawn. The Construction Planning Meeting request shall be in writing and shall include the Interconnection Customer’s reasonably requested date for completion of the construction of the Upgrades and Interconnection Facilities. Utilities: Removed the proposed revision from CCEBA regarding Grid Enhancing Technology. The Utilities are not able to accommodate CCEBA’s proposed additions at this time. SC Generator Interconnection Procedures 27 5.1.2 The Construction Planning Meeting shall be scheduled within ten (10) Business Days of the Section 5.1.1 request from the Interconnection Customer, or as otherwise mutually agreed to in writing by the parties. 5.1.3 The purpose of the Construction Planning Meeting is to identify the tasks for each party and discuss and determine the milestones for the construction of the Upgrades and Interconnection Facilities. Agreed upon milestones shall be specific as to scope of action, responsible party, and date of deliverable and shall be recorded in the Interconnection Agreement (see Appendix 4 to Attachment 10) to be developed by the utility and provided to Interconnection Customer pursuant to Section 5.2.1 below.
Sample 1

Related to Construction Planning Meeting

  • Preconstruction Meeting Furnish the names of the Certified Erosion and Sediment Control/Stormwater Supervisor, Certified Foremen, Certified Installers and Certified Designer and notify the Engineer of changes in certified personnel over the life of the contract within 2 days of change. Any company performing work for the North Carolina Department of Transportation has the ethical responsibility to fully disclose any reprimand or dismissal of an employee resulting from improper testing or falsification of records.

  • Safety Meetings Accident investigation.

  • Construction Change Directives 1.1.1, 3.4.2, 3.11, 3.12.8, 4.2.8, 7.1.1, 7.1.2, 7.1.3, 7.3, 9.3.1.1 Construction Schedules, Contractor’s 3.10, 3.11, 3.12.1, 3.12.2, 6.1.3, 15.1.6.2

  • Membership Meetings At the request of the Union the University agrees to grant a two (2) hour period twice a calendar year for purposes of a regular membership meeting. The University agrees to grant time off from work without loss of pay to those Employees regularly scheduled to work during that time.

  • Convening meetings The chairperson of a Consortium Body shall convene meetings of that Consortium Body. Ordinary meeting Extraordinary meeting General Assembly At least once a year At any time upon written request of the Executive Board or 1/3 of the Members of the General Assembly Executive Board At least quarterly At any time upon written request of any Member of the Executive Board

  • Member Meetings (a) There shall be no meetings of the Members unless called by the Board or as otherwise specifically required by the Delaware Act. No Members or group of Members, acting in its or their capacity as Members, shall have the right to call a meeting of the Members. (b) All acts of Members to be taken hereunder shall be taken in the manner provided in this Agreement. If authorized by the Board, and subject to such guidelines and procedures as the Board may adopt, if a meeting of the Members is called Members and proxyholders not physically present at a meeting of Members may by means of remote communication participate in such meeting and be deemed present in person and vote at such meeting. (c) A majority of the Shares present at such meeting, either in person or by proxy, and entitled to vote thereat, shall constitute a quorum for the purpose of such meeting, unless any such matter to be acted upon requires the approval of two-thirds of the Voting shares, in which case two-thirds of the Shares present at such meeting, either in person or by proxy, and entitled to vote thereat, shall constitute a quorum for the purpose of such meeting. The Delaware Court of Chancery may issue such orders as may be appropriate, including orders designating the time and place of such meeting, the record date for determination of Members entitled to vote, and the form of notice of such meeting. (d) No Members or group of Members, acting in its or their capacity as Members, shall have the right to call a meeting of the Members.

  • Contract Negotiation Meetings When operational requirements permit, the Employer will grant leave without pay to an employee for the purpose of attending contract negotiation meetings on behalf of the Alliance. Preparatory Contract Negotiation Meetings

  • Regulatory and Special Allocations Notwithstanding the provisions of Section 6.1: (a) If there is a net decrease in Company Minimum Gain (determined according to Treasury Regulations Section 1.704-2(d)(1)) during any Fiscal Year, each Member shall be specially allocated income and gain for such Fiscal Year (and, if necessary, subsequent Fiscal Years) in an amount equal to such Member’s share of the net decrease in Company Minimum Gain, determined in accordance with Treasury Regulations Section 1.704-2(g). The items to be so allocated shall be determined in accordance with Treasury Regulations Sections 1.704-2(f)(6) and 1.704-2(j)(2). This Section 6.2(a) is intended to comply with the “minimum gain chargeback” requirement in Treasury Regulation Section 1.704-2(f) and shall be interpreted consistently therewith. (b) Member Nonrecourse Deductions shall be allocated in the manner required by Treasury Regulations Section 1.704-2(i). Except as otherwise provided in Treasury Regulations Section 1.704-2(i)(4), if there is a net decrease in Member Nonrecourse Debt Minimum Gain during any Fiscal Year, each Member that has a share of such Member Nonrecourse Debt Minimum Gain shall be specially allocated income and gain for such Fiscal Year (and, if necessary, subsequent Fiscal Years) in an amount equal to that Member’s share of the net decrease in Member Nonrecourse Debt Minimum Gain. Items to be allocated pursuant to this paragraph shall be determined in accordance with Treasury Regulations Sections 1.704-2(i)(4) and 1.704-2(j)(2). This Section 6.2(b) is intended to comply with the “minimum gain chargeback” requirements in Treasury Regulations Section 1.704-2(i)(4) and shall be interpreted consistently therewith. (c) In the event any Member unexpectedly receives any adjustments, allocations or Distributions described in Treasury Regulations Section 1.704-1(b)(2)(ii)(d)(4), (5) or (6), income and gain shall be specially allocated to such Member in an amount and manner sufficient to eliminate the Adjusted Capital Account Deficit created by such adjustments, allocations or Distributions as quickly as possible. This Section 6.2(c) is intended to comply with the qualified income offset requirement in Treasury Regulations Section 1.704-1(b)(2)(ii)(d) and shall be interpreted consistently therewith. (d) The allocations set forth in paragraphs (a), (b) and (c) above (the “Regulatory Allocations”) are intended to comply with certain requirements of the Treasury Regulations under Code Section 704. Notwithstanding any other provisions of this Article VI (other than the Regulatory Allocations), the Regulatory Allocations shall be taken into account in allocating Net Income and Net Losses among Members so that, to the extent possible, the net amount of such allocations of Net Income and Net Losses and other items and the Regulatory Allocations to each Member shall be equal to the net amount that would have been allocated to such Member if the Regulatory Allocations had not occurred. (e) The Company and the Members acknowledge that allocations like those described in Proposed Treasury Regulation Section 1.704-1(b)(4)(xii)(c) (“Forfeiture Allocations”) result from the allocations of Net Income and Net Loss provided for in this Agreement. For the avoidance of doubt, the Company is entitled to make Forfeiture Allocations and, once required by applicable final or temporary guidance, allocations of Net Income and Net Loss shall be made in accordance with Proposed Treasury Regulation Section 1.704-1(b)(4)(xii)(c) or any successor provision or guidance.

  • Condominiums/Planned Unit Developments If the Mortgaged Property is a condominium unit or a planned unit development (other than a de minimis planned unit development) such condominium or planned unit development project such Mortgage Loan was originated in accordance with, and the Mortgaged Property meets the guidelines set forth in the Originator's Underwriting Guidelines;

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!