Contractor Insolvency Sample Clauses

Contractor Insolvency. Contractor shall notify Covered California immediately in writing in the event that Contractor files any federal bankruptcy action or state receivership action, any federal bankruptcy or state receivership action is commenced against Contractor, Contractor is adjudicated bankrupt, or a receiver is appointed and qualifies. In case any of the foregoing events occurs, Covered California may terminate this Agreement upon five (5) days written notice. If Covered California does so, Covered California shall have the right to recover damages from Contractor as though the Agreement had been terminated for Contractor default.
Sample 1Sample 2Sample 3See All (35)
AutoNDA by SimpleDocs
Contractor Insolvency. Contractor shall notify the Exchange immediately in writing in the event that Contractor files any federal bankruptcy action or state receivership action, any federal bankruptcy or state receivership action is commenced against Contractor, Contractor is adjudicated bankrupt, or a receiver is appointed and qualifies. In case any of the foregoing events occurs, the Exchange may terminate this Agreement upon five (5) days written notice. If the Exchange does so, the Exchange shall have the right to recover damages from Contractor as though the Agreement had been terminated for Contractor default.
Sample 1Sample 2Sample 3See All (25)
Contractor Insolvency. Contractor shall notify CalPERS immediately in writing in the event that Contractor files any federal bankruptcy action or state receivership action, any federal bankruptcy or state receivership action is commenced against Contractor, Contractor is adjudicated bankrupt, or a receiver is appointed and qualifies. In case any of the foregoing events occurs, CalPERS may terminate this Agreement upon five (5) days written notice. If CalPERS does so, CalPERS shall have the right to recover damages from Contractor as though the Agreement had been terminated for Contractor default, and CalPERS shall pay Contractor for satisfactory services rendered on the same basis that would apply under this Agreement in case of a termination by CalPERS for Contractor’s default.
Sample 1Sample 2See All (4)
Contractor Insolvency. In the event DFR determines Contractor may be unable to meet its obligations hereunder because the Contractor ceases conducting business in the normal course, becomes insolvent, makes a general assignment for the benefit of creditors, suffers or permits the appointment of a receiver for its business or assets or avails itself of or becomes subject to any proceeding under the Federal Bankruptcy Act or any statute of any state relating to insolvency or the protection of rights of creditors, the State, DFR and Contractor shall work together in good faith to minimize any impact on Enrollees resulting from such situation. The State may terminate this Contract upon five (5) days written notice of any DFR determination of Contractor insolvency.
Sample 1Sample 2Sample 3
Contractor Insolvency. 5 the Contractor’s aggregate liability to the Principal equals the amount set out in Contract Information item 23; .6 the Contractor’s liability to the Principal for liquidated damages equals the liquidated damages liability cap set out in Contract Information item 24 and the Contractor has not, prior to such cap being reached, notified the Principal that it agrees to refresh such cap and continue to pay liquidated damages up to such refreshed cap; or .7 the Contractor has notified the Principal that it agrees to refresh the liquidated damages liability cap set out in Contract Information item 24, and the Contractor’s liability to the Principal for liquidated damages equals or exceeds the refreshed cap. Contractor Warranty Deed The Contractor warranty deed in the form set out in Schedule 35. Contractor’s Authorised Person The person appointed to act on behalf of the Contractor under clause 3, named in Contract Information item 9 or as subsequently notified to the Principal. Contractor’s Documents Drawings, specifications, calculations and other documents and information, meeting the requirements of clause 61, which the Contractor must produce to design and construct the Works in accordance with the Contract. Contractor’s Personnel
Sample 1
Contractor Insolvency. Should Contractor become insolvent or make an assignment for the benefit of creditors or be adjudicated a bankrupt or admit in writing his inability to pay his debts generally as the same become due, or should any proceedings be instituted by Contractor under and State or Federal law for relief of debtors or for the appointment of a receiver, trustee or liquidator of Contractor, or should a voluntary petition in bankruptcy or for a reorganization or for an adjudication of Contractor as an insolvent or a bankrupt be filed, or should an attachment be levied upon Contractor's equipment and not removed within five (5) days therefrom, then upon the occurrence of any such event, Amoco shall thereupon have the right to cancel this contract and terminate immediately all work then being performed by Contractor hereunder. WITNESS THE SIGNATURES of the parties hereto the day and year first above written. Amoco Production Company* Environmental Protection Company* By:/s/J.X. Xxxxxx,Xttorney -in-Fact By:/s/W. Xxxxx, President /s/Waxxxx X. Xxxxx, individually *Subject to -the attached Addendum between the parties, dated June:26, 1992. Environmental Protection Company State of California County of San Mateo On June 4, 1992 before me, a Notary Public in and for the State of California, personally appeared W. Xxxxx xersonally known to me (or proved to me on the basis of satisfactory evidence) to be the person (s) whose name (s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. Witness my hand and official seal. /s/W. X. Xxxxxxxx [OFFICIAL NOTARY SEAL W. X. Xxxxxxxx Notary Public California SAN MATEO COUNTY My Comm. Expires JUL 10, 1995] Waxxxx X. Xxxxx, Individual State of California County of San Mateo On June 4, 1992 before me, a Notary Public in and for the State of California, personally appeared W. Xxxxx xersonally known to me (or proved to me on the basis of satisfactory evidence) to be the person (s) whose name (s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. Witness my hand a...
Sample 1
Contractor Insolvency. This Agreement shall terminate effective the day immediately preceding the day on which: (A) there is a filing by or against Contractor to have Contractor adjudged bankrupt or there is a petition for reorganization or arrangement of Contractor under any law relating to bankruptcy; (B) Contractor applies for, consents to, or has an order, judgment, or decree entered by a court for approval of a petition for or appointment of a receiver, trustee, custodian, or liquidator of all or a substantial part of Contractor’s assets; (C) Contractor is unable to, fails to, or admits in writing its inability generally to pay its debts or obligations as they become due; and/or (D) Contractor makes a general assignment for the benefit of creditors. Contractor shall provide FCSS with written notice within 15 days of the occurrence of any of the aforementioned events.
Sample 1
AutoNDA by SimpleDocs
Contractor Insolvency. Upon the appointment of a receiver for the Contractor, or if the Contractor makes a general assignment for the benefit of creditors, the Town may terminate this Agreement, without prejudice to any right or remedy otherwise available to the Town, upon giving three Days’ written notice to the Contractor. If an order for relief is entered under the bankruptcy code with respect to the Contractor, the Town may terminate this Agreement by giving three Days’ written notice to the Contractor unless the Contractor or the trustee does all of the following:
Sample 1
Contractor Insolvency 
Sample 1Sample 2Sample 3

Related to Contractor Insolvency

  • Bankruptcy; Insolvency The Lessee agrees that in the event all or a substantial portion of the Lessee’s assets are placed in the hands of a receiver or a Trustee, and such status continues for a period of 30 days, or should the Lessee make an assignment for the benefit of creditors or be adjudicated bankrupt; or should the Lessee institute any proceedings under the bankruptcy act or any amendment thereto, then such Lease or interest in and to the leased Premises shall not become an asset in any such proceedings and, in such event, and in addition to any and all other remedies of the Lessor hereunder or by law provided, it shall be lawful for the Lessor to declare the term hereof ended and to re-enter the leased land and take possession thereof and all improvements thereon and to remove all persons therefrom and the Lessee shall have no further claim thereon.

  • Involuntary Insolvency Proceedings The appointment of a receiver, trustee, custodian or officer performing similar functions for the Company or any Subsidiary or any of the Company's or any Subsidiary's assets, including, without limitation, the appointment of or taking possession by a "custodian" as defined in the federal Bankruptcy Code; or the filing against the Company or any Subsidiary of a request or petition for liquidation, reorganization, arrangement, adjudication as a bankrupt or other relief under the bankruptcy, insolvency or similar laws of the United States of America or any state or territory thereof or any foreign jurisdiction, now or hereafter in effect; or the institution against the Company or any Subsidiary of any other type of insolvency proceeding (under the federal Bankruptcy Code or otherwise) or of any formal or informal proceeding for the dissolution or liquidation of, settlement of claims against or winding up of affairs of the Company or any Subsidiary, and the failure to have such appointment vacated or such filing, petition or proceeding dismissed within ninety (90) days after such appointment, filing or institution.

  • Death or Insolvency The dissolution of Borrower (regardless of whether election to continue is made), any member withdraws from Borrower, or any other termination of Borrower’s existence as a going business or the death of any member, the insolvency of Borrower, the appointment of a receiver for any part of Borrower’s property, any assignment for the benefit of creditors, any type of creditor workout, or the commencement of any proceeding under any bankruptcy or insolvency laws by or against Borrower. Defective Collateralization. This Agreement or any of the Related Documents ceases to be in full force and effect (including failure of any collateral document to create a valid and perfected security interest or lien) at any time and for any reason. Creditor or Forfeiture Proceedings. Commencement of foreclosure or forfeiture proceedings, whether by judicial proceeding, self-help, repossession or any other method, by any creditor of Borrower or by any governmental agency against any collateral securing the Loan. This includes a garnishment of any of Borrower’s accounts, including deposit accounts, with Lender. However, this Event of Default shall not apply if there is a good faith dispute by Borrower as to the validity or reasonableness of the claim which is the basis of the creditor or forfeiture proceeding and if Borrower gives Lender written notice of the creditor or forfeiture proceeding and deposits with Lender monies or a surety bond for the creditor or forfeiture proceeding, in an amount determined by Lender, in its sole discretion, as being an adequate reserve or bond for the dispute. Events Affecting Guarantor. Any of the preceding events occurs with respect to any Guarantor of any of the Indebtedness or any Guarantor dies or becomes incompetent, or revokes or disputes the validity of, or liability under, any Guaranty of the Indebtedness. BUSINESS LOAN AGREEMENT (ASSET BASED)

  • Bankruptcy or Insolvency If the Borrower, Grantor or any Guarantor: (i) becomes insolvent, or makes a transfer in fraud of creditors, or makes an assignment for the benefit of creditors, or admits in writing its inability to pay its debts as they become due; (ii) generally is not paying its debts as such debts become due; (iii) has a receiver, trustee or custodian appointed for, or take possession of, all or substantially all of the assets of such party or any of the Collateral, either in a proceeding brought by such party or in a proceeding brought against such party and such appointment is not discharged or such possession is not terminated within sixty (60) days after the effective date thereof or such party consents to or acquiesces in such appointment or possession; (iv) files a petition for relief under the United States Bankruptcy Code or any other present or future federal or state insolvency, bankruptcy or similar laws (all of the foregoing hereinafter collectively called "Applicable Bankruptcy Law") or an involuntary petition for relief is filed against such party under any Applicable Bankruptcy Law and such involuntary petition is not dismissed within sixty (60) days after the filing thereof, or an order for relief naming such party is entered under any Applicable Bankruptcy Law, or any composition, rearrangement, extension, reorganization or other relief of debtors now or hereafter existing is requested or consented to by such party; (v) fails to have discharged within a period of sixty (60) days any attachment, sequestration or similar writ levied upon any property of such party; or (vi) fails to pay within thirty (30) days any final money judgment against such party.

  • Involuntary Insolvency Without consent by Grantee, a court or government authority enters an order, and such order is not vacated within ten (10) days, (i) appointing a custodian, receiver, trustee or other officer with similar powers with respect to Grantee or with respect to any substantial part of Grantee's property, (ii) constituting an order for relief or approving a petition for relief or reorganization or arrangement or any other petition in bankruptcy or for liquidation or to take advantage of any bankruptcy, insolvency or other debtors' relief law of any jurisdiction or (iii) ordering the dissolution, winding-up or liquidation of Grantee.

  • Voluntary Insolvency Proceedings If the Company or any Subsidiary (i) shall file a petition or request for liquidation, reorganization, arrangement, adjudication as a bankrupt, relief as a debtor or other relief under the bankruptcy, insolvency or similar laws of the United States of America or any state or territory thereof or any foreign jurisdiction, now or hereafter in effect; (ii) shall make a general assignment for the benefit of creditors; (iii) shall consent to the appointment of a receiver or trustee for the Company or any Subsidiary or any of the Company's or any Subsidiary's assets, including, without limitation, the appointment of or taking possession by a "custodian" as defined in the federal Bankruptcy Code; (iv) shall make any, or send notice of any intended, bulk sale; or (v) shall execute a consent to any other type of insolvency proceeding (under the federal Bankruptcy Code or otherwise) or any formal or informal proceeding for the dissolution or liquidation of, or settlement of claims against or winding up of affairs of, the Company or any Subsidiary.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!